HomeMy WebLinkAbout20181249 Ver 1_Attachment 5- NCDOT Projects List_20181217PROJECTS LIST
NORTH CAROLINA BOARD OF TRANSPORTATION
RALEIGH, NORTH CAROLINA
December 5-6, 2018
Delegated Authority ................................................................................... Secretary Trogdon
(Item C) Award of Highway Construction Contracts from November 2018 Letting
(Item D) Award of Contracts to Private Firms for Engineering Services
(Item E)
(Item H)
(Item L)
Funds for Secondary Road Improvement Projects —
Highway Fund and Highway Trust Fund
Funds for Division-wide Small Construction,
Statewide Contingency, Public Access, and Economic Development
Funds for Specific Spot Safety Improvement Projects
Action................................................................................................................ Chairman Fox
(Item G) Additions, Abandonments, and Road Name Changes to State
Secondary Road System
(Item I) Public Transportation Program
(Item I-1) Public Transportation (No Item this month)
(Item I-1A) Public Transportation (No Item this month)
(Item I-2) Rail Program (No Item this month)
(Item I-3) Bicycle and Pedestrian (No Item this month)
(Item I-4) Aviation
(Item J)
(Item K)
Specific State Funds for Construction Projects (Item K now replaces Item J)
North Carolina Highway Trust Funds
(Item M) Funds for Specific Federal-Aid Projects
(Item N)
(Item O)
(Item P)
(Item R)
(Item S)
(Item T)
(Item V)
Revisions to the 2018-2027 STIP
Municipal and Special Agreements
Municipal Street System Changes
Right of Way Resolutions and Ordinances
Maintenance Allocations (No Item this Month)
Submission of Comprehensive Transportation Plans for Mutual
Adoption by the Board of Transportation
(No Item this month)
NCDOT Board of Transportation Agenda
ITEM C
November 2018
According to Executive Order No. 2 and G.S. 143B-350(g), the
Board is requested to concur with staff recommendations and
delegate authority to the Secretary to award the following
highway construction projects.
HIGHWAY LETTING
NORTH CAROLINA DEPARTMENT OF TRANSPORTATION
DIVISION OF HIGHWAYS
RALEIGH N.C.
NOVEMBER 20, 2018
DIVISION 00003
C204271
2019CPT.03.02.10671, 2019CPT.03.02.20671
STATE FUNDED
ONSLOW
PROPOSAL LENGTH 36.510 MILES
TYPE OF WORK MILLING, RESURFACING, AND SHOULDER RECONSTRUCTION.
LOCATION 1 SECTION OF US-17 AND 25 SECTIONS OF SECONDARY ROADS.
EST CONST PROGRESS.... FY-2019..49% OF BID
FY-2020..51% OF BID
RPN 003 3 BIDDER(S) DBE GOAL 7.00 %
ESTIMATE 8,600,731.09
DATE AVAILABLE JAN 08 2019
INTER COMPLETION MAY 10 2019 COMPLETE ALL WORK REQUIRED ON MAP #1
FINAL COMPLETION MAY 15 2020
PAGE : 1 of 10
ITEM C
$ TOTALS % DIFF
ONSLOW GRADING & PAVING INC JACKSONVILLE, NC 8,657,315.46 +0.7
BARNHILL CONTRACTING COMPANY ROCKY MOUNT, NC 8,904,098.75 +3.5
ROSE BROTHERS PAVING CO INC AHOSKIE, NC 9,974,938.87 +16.0
HIGHWAY LETTING
NORTH CAROLINA DEPARTMENT OF TRANSPORTATION
DIVISION OF HIGHWAYS
RALEIGH N.C.
NOVEMBER 20, 2018
DIVISION 00005
C204263
176P.5.R.96
STATE FUNDED
WAKE
B-4833
PROPOSAL LENGTH 0.259 MILES
TYPE OF WORK GRADING, DRAINAGE, PAVING, AND STRUCTURE.
LOCATION BRIDGE NO 376 OVER LITTLE BLACK CREEK ON SR-1761 (WIMBERLY ROAD).
EST CONST PROGRESS.... FY-2019..100% OF BID
RPN 004
5 BIDDER(S) DBE GOAL 7.00 %
ESTI MATE 1,164,138.53
PAGE:2of10
ITEM C
DATE AVAILABLE DEC 31 2018 THRU MAY 01 2019
INTER COMPLETION COMPLETE ALL WORK EXCEPT PLANTING, REFORESTATION OR PERMANENT
VEGETATION ESTABLISHMENT 180 DAYS AFTER START DATE
FINAL COMPLETION 360 DAY(S) AFTER START DATE
NATIONAL BRIDGE BUILDERS LLC KERNERSVILLE, NC
DANE CONSTRUCTION INC MOORESVILLE, NC
FSC II LLC DBA FRED SMITH COMPANY RALEIGH, NC
UNITED CONTRACTORS, INC. DBA UNITED CONTRACTORS INC. OF IOWA JC
S T WOOTEN CORPORATION WILSON, NC
$ TOTALS
1,080,185.80
1,104, 839.50
1,215,121.00
1,344,753.69
1,395,208.94
% DIFF
-7.2
-5.1
+4.4
+15.5
+19.8
HIGHWAY LETTING
NORTH CAROLINA DEPARTMENT OF TRANSPORTATION
DIVISION OF HIGHWAYS
RALEIGH N.C.
NOVEMBER 20, 2018
DIVISION 00005
C204267
2020 C PT. 05. 08. 20731.1
STATE FUNDED
PERSON
PROPOSAL LENGTH 25.610 MILES
TYPE OF WORK MILLING, RESURFACING, AND SHOULDER GRADING.
LOCATION
15 SECTIONS OF SECONDARY ROADS.
EST CONST PROGRESS.... FY-2019..69% OF BID
FY-2020..31% OF BID
1:7�►<IZIF",
2 BIDDER(S) DBE GOAL 9.00 %
ESTIMATE 4,555,795.98
DATE AVAILABLE DEC 31 2018
FINAL COMPLETION NOV 30 2019
PAGE:3of10
ITEM C
$ TOTALS % DIFF
CAROLINASUNROCK LLC RALEIGH, NC 4,123,554.26 -9.5
ADAMS CONSTRUCTION COMPANY ROANOKE, VA 4,986,765.00 +9.5
HIGHWAY LETTING
NORTH CAROLINA DEPARTMENT OF TRANSPORTATION
DIVISION OF HIGHWAYS
RALEIGH N.C.
NOVEMBER 20, 2018
DIVISION 00005
C204197
35516.3. GV 1
NHP-0540(043)
JOHNSTON, WAKE
R-2828
PROPOSAL LENGTH 8.617 MILES
TYPE OF WORK DESIGN BUILD.
PAGE:4of10
ITEM C
LOCATION NC-540 - TRIANGLE EXPRESSWAY SOUTHEAST EXTENSION FROM EAST OF US-401
(FAYETTEVILLE RD) TO EAST OF I-40.
EST CONST PROGRESS.... FY-2019..11% OF BID
FY-2020..29% OF BID
FY-2021..28% OF BID
FY-2022..19% OF BID
FY-2023..12% OF BID
FY-2024..01% OF BID
RPN 009 3 BIDDER(S) DBE GOAL 10.00 %
ESTIMATE 355,208,000.00
DATE AVAILABLE DEC 31 2018
INTER COMPLETION SEP 01 2023 COMPLETE ALL WORK REQUIRED OF ITS/AET INFRASTRUCTURE ONE
HUNDRED TWENTY (120) DAYS PRIOR TO PROJECT'S COMPLETION DATE
FINAL COMPLETION JAN 01 2024
PROPOSAL
THE LANE-BLYTHE
CONSTRUCTION JV
THE ARCHER-UNITED JV
ZACHRY-S.T.
WOOTEN-WRIGHT
PROPOSAL
QUALITYADJUSTED PRICE RANKING
TECH QUALITY ACTUAL ACT % QUALITY CONT AWARD
SCORE CREDIT CONTAMT DIFF VALUE BASIS
% (PRICE (ADJ PRICE)
PROP)
96.40 22.00 403,200,000.00 +13.5 88,704,000.00 314,496,000.00
92.30 18.58 402,282,800.00 +13.3 74,744,144.24 327,538,655.76
86.70 13.91 399,348,360.00 +12.4 55,549,356.88 343,799,003.12
THE LANE-BLYTHE CONSTRUCTION JV
THE ARCHER-UNITED JV
ZACHRY-S.T. WOOTEN-WRIGHT BROTHERS JV
PROPOSED COMPLETION
DATE
NOV 24 2022
OCT 03 2023
JUN 29 2023
ADJ %
DIFF
-11.5
-7.8
-3.2
HIGHWAY LETTING PAGE : 5 of 10
NORTH CAROLINA DEPARTMENT OF TRANSPORTATION ITEM C
DIVISION OF HIGHWAYS
RALEIGH N.C.
NOVEMBER 20, 2018
DIVISION 00009
C204175
45901.3.1
NHPIM-0040(073)
FORSYTH
I-5952
PROPOSAL LENGTH 6.226 MILES
TYPE OF WORK DRAINAGE, CONC MEDIAN BARRIER, AND PAVEMENT REHABILITATION.
LOCATION I-40 FROM SR-1101 (HARPER RD) IN CLEMMONS TO EAST OF US-421/ I-40 BUS IN
W INSTON-SALEM.
EST CONST PROGRESS.... FY-2019..30% OF BID
FY-2020..62% OF BID
FY-2021..08% OF BID
RPN 006 2 BIDDER(S) DBE GOAL 6.00 %
ESTIMATE 16,230,913.60
DATE AVAILABLE MAR 01 2019
FINAL COMPLETION OCT 01 2020
$ TOTALS % DIFF
SHARPE BROTHERS A DIVISION OF VECELLIO & GROGAN INC GREENSBOF 17,558,977.21 +8.2
APAC - ATLANTIC INC THOMPSON ARTHUR DIVISION GREENSBORO, NC 21,736,932.75 +33.9
HIGHWAY LETTING
NORTH CAROLINA DEPARTMENT OF TRANSPORTATION
DIVISION OF HIGHWAYS
RALEIGH N.C.
NOVEMBER 20, 2018
DIVISION 00010
C204259
156PR.43, 39922.3.1
STATE FUNDED
STANLY
B-4974
PROPOSAL LENGTH 0.327 MILES
TYPE OF WORK DESIGN BUILD.
LOCATION BRIDGES 830050 AND 830051 OVER THE PEE DEE RIVER ON NC-24/NC-27/NC-73.
RPN 010
EST CONST PROGRESS.... FY-2019..27% OF BID
FY-2020..44% OF BID
FY-2021..26% OF BID
FY-2022..03% OF BID
3 BIDDER(S) DBE GOAL 0.00%
ESTIMATE 17,784,950.00
PAGE:6of10
ITEM C
DATE AVAILABLE JAN 03 2019
INTER COMPLETION MAY 20 2019 COMPLETE DEFINED BRIDGE REHABILITATION WORK ON BRIDGE 830050
PRIOR TO PLACING TRAFFIC IN A TWO-LANE, TWO-WAY PATTERN
FINAL COMPLETION SEP 01 2021
QUALITYADJUSTED PRICE RANKING
PROPOSAL TECH QUALITY ACTUAL ACT % QUALITY
SCORE CREDIT CONTAMT DIFF VALUE
% (PRICE
PRnPI
PCL CIVIL 90.50 10.25 20,154,128.00 +13.3 2,065,798.12
CONSTRUCTORSINC
* IMPROPER BID BOND FORM
* INCORRECT CONTRACT NUMBER
LEE CONSTRUCTION 7g.00 4.50 29,901,550.00 +68.1 1,345,569.75
COMPANY OF THE
CROWDER 77.00 3.50 37,652,150.00 +111.7 1,317,825.25
CONSTRUCTION
* IMPROPER BID BOND FORM
* TITLE NOT MARKED THROUGH ON CORP SIGNATUR
PROPOSAL
PCL CIVIL CONSTRUCTORS INC
LEE CONSTRUCTION COMPANY OF THE CAROL
PROPOSED COMPLETION
DATE
APR 30 2021
AUG 15 2021
CONT AWARD ADJ %
BASIS DIFF
(ADJ PRICE)
18,088,329.88 +1.7
28,555,980.25 +60.6
36,334,324.75 +104.3
HIGHWAY LETTING PAGE : 7 of 10
NORTH CAROLINA DEPARTMENT OF TRANSPORTATION ITEM C
DIVISION OF HIGHWAYS
RALEIGH N.C.
�:Z�lli�y_1�
NOVEMBER 20, 2018
PROPOSED COMPLETION
DATE
CROWDER CONSTRUCTION COMPANY SEP 01 2021
HIGHWAY LETTING
NORTH CAROLINA DEPARTMENT OF TRANSPORTATION
DIVISION OF HIGHWAYS
RALEIGH N.C.
NOVEMBER 20, 2018
DIVISION 00012
C204262
45342.3.14
HS I P-0279(10)
GASTON
W-5212N
PROPOSAL LENGTH 7.850 MILES
TYPE OF WORK GRADING, DRAINAGE, PAVING, CULVERTS, AND RESURFACING.
LOCATION
NC-279 FROM SR-1438 TO NC-275.
EST CONST PROGRESS.... FY-2019..38% OF BID
FY-2020..53% OF BID
FY-2021..09% OF BID
RPN 007
2 BIDDER(S) DBE GOAL 12.00 %
ESTIMATE 13,612,479.31
PAGE:8of10
ITEM C
DATE AVAILABLE JAN 02 2019
INTER COMPLETION NOV 01 2020 COMPLETE ALL WORK EXCEPT PLANTING, REFORESTATION OR
PERMANENT VEGETATION ESTABLISHMENT
FINAL COMPLETION APR 30 2021
$ TOTALS % DIFF
SLOAN CONSTRUCTION A DIVISION OF REEVES CONSTRUCTION CO DUNC, 15,853,698.43 +16.5
BLYTHE CONSTRUCTION INC CHARLOTTE, NC 18,149,579.52 +33.3
HIGHWAY LETTING
NORTH CAROLINA DEPARTMENT OF TRANSPORTATION
DIVISION OF HIGHWAYS
RALEIGH N.C.
NOVEMBER 20, 2018
DIVISION 00013
C204232
156PR.28
STATE FUNDED
MADISON, MITCHELL
PROPOSAL LENGTH 0.350 MILES
TYPE OF WORK BRIDGE PRESERVATION.
PAGE:9of10
ITEM C
LOCATION SR-1151 OVER FRENCH BROAD RIVER, SR-1346 OVER BIG LAUREL CREEK, AND NC-226
OVER NORTH TOE RIVER.
EST CONST PROGRESS.... FY-2019..42% OF BID
FY-2020..53% OF BID
FY-2021..05% OF BID
RPN 008
7 BIDDER(S) DBE GOAL 0.00%
ESTIMATE 4,893,846.30
DATE AVAILABLE DEC 31 2018
FINAL COMPLETION SEP 01 2020
SOUTHERN ROAD & BRIDGE LLC TARPON SPRINGS, FL
AMERICAN CONTRACTING & SERVICES INC JEFFERSONVILLE, IN
GLF CONSTRUCTION CORPORATION MIAMI, FL
LANFORD BROTHERS CO INC ROANOKE, VA
BUCKEYE BRIDGE LLC CANTON, NC
NHM CONSTRUCTORS LLC ASHEVILLE, NC
PROSHOT CONCRETE INC FLORENCE, AL
$ TOTALS
3,458,720.75
3,493,408.50
3,516,326.50
3,530,618.81
3,590,816.00
4,470,426.70
6,038,243.01
% DIFF
-29.3
-28.6
-28.1
-27.9
-26.6
-8.7
+23.4
HIGHWAY LETTING
NORTH CAROLINA DEPARTMENT OF TRANSPORTATION
DIVISION OF HIGHWAYS
RALEIGH N.C.
NOVEMBER 20, 2018
DIVISION 00014
C204130
176P.14.R.154, 50192.3.1
STATE FUNDED
MACON
R-5734A
PROPOSAL LENGTH 1.113 MILES
TYPE OF WORK GRADING, DRAINAGE, PAVING, SIGNAL, CULVERT, AND STRUCTURE.
PAGE:10of10
ITEM C
LOCATION US-23/441 FROM US-64 TO SR-1652 (WIDE HORIZON DR)/SR-1152 (BELDEN CIR) & BRIDGE
NO. 314 OVER CARTOOGECHAYE CREEK.
EST CONST PROGRESS.... FY-2019..38% OF BID
FY-2020..53% OF BID
FY-2021..09% OF BID
RPN 002 3 BIDDER(S) DBE GOAL 7.00 %
ESTIMATE 11,678,325.14
DATE AVAILABLE JAN 02 2019
INTER COMPLETION NOV 01 2020 COMPLETE ALL WORK EXCEPT PLANTING, REFORESTATION, OR
PERMANENT VEGETATION ESTABLISHMENT
OCT 01 2019 COMPLETE ALL WORK REQUIRED FOR STEPS #1 THRU #4 FOR
17P6.14.R.154
FINAL COMPLETION APR 30 2021
BUCHANAN AND SONS INC WHITTIER, NC
WATSON CONTRACTING INC FRANKLIN, NC
NHM CONSTRUCTORS LLC ASHEVILLE, NC
ESTIMATE TOTAL
LETTING TOTAL
$ TOTALS % DIFF
14,032,805.00 +20.2
15,600,000.00 +33.6
16,036,716.79 +37.3
433, 729,179.95
488,119,384.91 +12.5
ITEM D
Page 1 of 14
NCDOT December 2018
Board of Transportation Agenda
According to Executive Order No. 2 and G. S. 143B-350 (g) the Board is requested to
concur with staff recommendations and delegate authority to the Secretary to award
contracts to private firms for engineering services.
Professional Services Management
Chief Operating Officer
Chief Engineer
Deputy Chief Engineer
Facilities Management
The following is a supplemental contract to a previous contract approved by the Board with the
same engineering firm. This supplemental contract was necessary due to approved additional
work that was unknown at the inception and is required of the firm to complete the project. Our
staff has completed the actions in accordance with the policies and procedures adopted by the
Board on May 7, 2009. This is for information only.
STATEWIDE
Project:
Scope of Work:
Estimated Construction Cost
Firm:
Original Engineering Fee:
Supplemental Fee:
Supplemental Work:
SPSF Utilization:
51208 Statewide
Roadway Lighting Project
Inspection Services
$32,303,412.00
LJB Inc, Miamisburg, OH
$1,500,000.00
$750,000.00
Inspection Services
100%
Design-Build
The Secretary of Transportation awarded a Design-Build contract in October 2018 to widen I-440
/ US 1 from south of SR 1313 (Walnut Street) to SR 1728 (Wade Avenue), a distance of
approximately 6.5 miles, providing a six-lane divided facility with reconfigured interchanges, in
Wake County. The project will also provide grade separations on Beryl Road, Norfolk Southern
Railway / North Carolina Railroad / CSX Railroad and NC 54 (Hillsborough Street) at SR 1664
(Blue Ridge Road). In accordance with the policies and procedures adopted by the Board, a
Design-Build team who was not awarded the project can request payment of a stipend to recover
part of the expense of preparation of their proposal. We have received a request for payment of
the stipend from the following firms. These are for information only.
Project:
Firm:
Stipend Amount:
SPSF Utilization:
(35869.3.1 & 35868.3.4) (U-2719 / U-4437)
Archer Western Construction LLC, Raleigh, NC
$125,000.00
0%
December 6, 2018
ITEM D
Page 2 of 14
Project:
Firm:
Stipend Amount:
SPSF Utilization:
(35869.3.1 & 35868.3.4) (U-2719 / U-4437)
Granite Construction Company, Watsonville, CA
$125,000.00
0%
Materials &Tests Unit
The following is a supplemental contract to a previous contract approved by the Board with the
same engineering firm. This supplemental contract was necessary due to approved additional
work that was unknown at the inception and is required of the firm to complete the project. Our
staff has completed the actions in accordance with the policies and procedures adopted by the
Board on May 7, 2009. This is for information only.
STATEWIDE
Description of work:
Firm:
Original Engineering Fee
Supplemental Fee:
SPSF Utilization:
2017 Inspection, Testing, and Analysis of Materials
and Pavements LSC
Brannan Inspection Services Inc, Selma, NC
$850,000.00
$1,000,000.00
0%
Divisions
Divisions 1-4, and 6
The following are supplemental contracts to previous contracts approved by the Board with the
same engineering firms. These supplemental contracts were necessary due to approved
additional work that was unknown at the inception and is required of the firms to complete the
project. Our staff has completed the actions in accordance with the policies and procedures
adopted by the Board on May 7, 2009. This is for information only.
DIVISIONS 1-4, and 6
Description of Work:
Firm:
Original Engineering Fee:
Previous Supplemental Fee
Supplemental Fee:
SPSF Utilization:
2015 Eastern Region Highway Divisions (Divisions 1,
2, 3, 4, and 6) Planning and Design LSC
Atkins North America Inc, Raleigh, NC
$3,000,000.00
$4,000,000.00
Time extension only (6 months)
N/A
December 6, 2018
ITEM D
Page 3 of 14
Description of Work:
Firm:
Original Engineering Fee:
Previous Supplemental Fee
Supplemental Fee:
SPSF Utilization:
DBE/WBE/SPSF Utilization
SPSF Utilization:
DBE/WBE/SPSF Utilization
2015 Eastern Region Highway Divisions (Divisions 1,
2, 3, 4, and 6) Planning and Design LSC
Calyx Engineers and Consultants Inc, Raleigh, NC
$3,000,000.00
$7,000,000.00
$1,000,000.00 & Time extension (6 months)
Carolina Land Acquisitions Inc
1 % / $10,000.00
Ecological Engineering LLP
5% / $50,000.00
Hinde Engineering Inc
2% / $20,000.00
Planning Communities, LLC
2% / $20,000.00
SPSF Utilization: Ramey Kemp & Associates, Inc.
2% / $20,000.00
SPSF Utilization: Commonwealth Heritage Group Inc
1 % / $10,000.00
Description of Work:
Firm:
Original Engineering Fee:
Previous Supplemental Fee
Supplemental Fee:
SPSF Utilization:
Description of Work:
Firm:
Original Engineering Fee:
Previous Supplemental Fee
Supplemental Fee:
SPSF Utilization:
Description of Work:
Firm:
Original Engineering Fee:
Previous Supplemental Fee
Supplemental Fee:
SPSF Utilization:
Description of Work:
Firm:
Original Engineering Fee:
Previous Supplemental Fee
Supplemental Fee:
SPSF Utilization:
2015 Eastern Region Highway Divisions (Divisions 1,
2, 3, 4, and 6) Planning and Design LSC
CDM Smith Inc, Raleigh, NC
$3,000,000.00
$5,000,000.00
Time extension only (6 months)
N/A
2015 Eastern Region Highway Divisions (Divisions 1,
2, 3, 4, and 6) Planning and Design LSC
HDR Engineering Inc of the Carolinas, Chicago, IL
$3,000,000.00
$8,000,000.00
Time extension only (6 months)
N/A
2015 Eastern Region Highway Divisions (Divisions 1,
2, 3, 4, and 6) Planning and Design LSC
HNTB of North Carolina PC, Raleigh, NC
$3,000,000.00
$14,000,000.00
Time extension only (6 months)
N/A
2015 Eastern Region Highway Divisions (Divisions 1,
2, 3, 4, and 6) Planning and Design LSC
H. W. Lochner, Inc., Raleigh, NC
$3,000,000.00
$2,000,000.00
Time extension only (6 months)
N/A
December 6, 2018
ITEM D
Page 4 of 14
Description of Work:
Firm:
Original Engineering Fee:
Previous Supplemental Fee
Supplemental Fee:
DBE/WBE/SPSF Utilization;
DBE/WBE/SPSF Utilization
SPSF Utilization:
DBE/MBE/SPSF Utilization
DBE/WBE/SPSF Utilization
SPSF:
Description of Work:
Firm:
Original Engineering Fee:
Previous Supplemental Fee
Supplemental Fee:
SPSF Utilization:
Description of Work:
Firm:
Original Engineering Fee:
Previous Supplemental Fee
Supplemental Fee:
SPSF Utilization:
Description of Work:
Firm:
Original Engineering Fee:
Previous Supplemental Fee
Supplemental Fee:
SPSF Utilization:
Description of Work:
Firm:
Original Engineering Fee:
Previous Supplemental Fee
Supplemental Fee:
SPSF Utilization:
2015 Eastern Region Highway Divisions (Divisions 1,
2, 3, 4, and 6) Planning and Design LSC
Kimley-Horn & Associates Inc, Raleigh, NC
$3,000,000.00
$5,000,000.00
$1,000,000.00 and Time extension (6 months)
CH Engineering PLLC
8% / $80,000.00
Three Oaks Engineering
6% / $60,000.00
Carolina Land Acquisitions Inc
5% / $50,000.00
Vistabution LLC
5% / $50,000.00
New South Associates Inc
2% / $20,000.00
SpanishSpeaking, LLC
2% / $20,000.00
2015 Eastern Region Highway Divisions (Divisions 1,
2, 3, 4, and 6) Planning and Design LSC
Michael Baker Engineering, Inc., Cary, NC
$3,000,000.00
$15,000,000.00
Time extension only (6 months)
N/A
2015 Eastern Region Highway Divisions (Divisions 1,
2, 3, 4, and 6) Planning and Design LSC
Mott MacDonald I&E LLC, Pittsburgh, PA
$3,000,000.00
$2,000,000.00
Time extension only (6 months)
N/A
2015 Eastern Region Highway Divisions (Divisions 1,
2, 3, 4, and 6) Planning and Design LSC
Parsons Transportation Group, Raleigh, NC
$3,000,000.00
$2,000,000.00
Time extension only (6 months)
N/A
2015 Eastern Region Highway Divisions (Divisions 1,
2, 3, 4, and 6) Planning and Design LSC
RS&H Architects-Engineers-Planners, Inc., Charlotte,
NC
$3,000,000.00
$7,000,000.00
Time extension only (6 months)
N/A
December 6, 2018
ITEM D
Page 5 of 14
Description of Work:
Firm:
Original Engineering Fee:
Previous Supplemental Fee
Supplemental Fee:
SPSF Utilization:
Description of Work:
Firm:
Original Engineering Fee:
Previous Supplemental Fee
Supplemental Fee:
SPSF Utilization:
Description of Work:
Firm:
Original Engineering Fee:
Previous Supplemental Fee
Supplemental Fee:
SPSF Utilization:
Description of Work:
Firm:
Original Engineering Fee:
Previous Supplemental Fee
Supplemental Fee:
DBE/WBE/SPSF Utilization:
Description of Work:
Firm:
Original Engineering Fee:
Previous Supplemental Fee
Supplemental Fee:
SPSF Utilization:
Description of Work:
Firm:
Original Engineering Fee:
Previous Supplemental Fee
Supplemental Fee:
SPSF Utilization:
2015 Eastern Region Highway Divisions (Divisions 1,
2, 3, 4, and 6) Planning and Design LSC
Rummel Klepper & Kahl LLP, Raleigh, NC
$3,000,000.00
$12,000,000.00
Time extension only (6 months)
N/A
2015 Eastern Region Highway Divisions (Divisions 1,
2, 3, 4, and 6) Planning and Design LSC
Sepi Engineering & Construction Inc., Raleigh, NC
$3,000,000.00
$8,000,000.00
Time extension only (6 months)
N/A
2015 Eastern Region Highway Divisions (Divisions 1,
2, 3, 4, and 6) Planning and Design LSC
Stantec Consulting Services Inc, Raleigh, NC
$3,000,000.00
$12,000,000.00
Time extension only (6 months)
N/A
2015 Eastern Region Highway Divisions (Divisions 1,
2, 3, 4, and 6) Planning and Design LSC
STV Engineers, Inc., Charlotte, NC
$3,000,000.00
$3,000,000.00
$1,000,000.00 and Time extension (6 months)
Falcon Engineering Inc
5% / $50,000.00
2015 Eastern Region Highway Divisions (Divisions 1,
2, 3, 4, and 6) Planning and Design LSC
Summit Design and Engineering Services PLLC,
Hillsborough, NC
$3,000,000.00
$4,000,000.00
Time extension only (6 months)
N/A
2015 Eastern Region Highway Divisions (Divisions 1,
2, 3, 4, and 6) Planning and Design LSC
TGS Engineers, Shelby, NC
$3,000,000.00
$2,000,000.00
Time extension only (6 months)
N/A
December 6, 2018
ITEM D
Page 6 of 14
Description of Work:
Firm:
Original Engineering Fee:
Previous Supplemental Fee
Supplemental Fee:
SPSF Utilization:
Description of Work:
Firm:
Original Engineering Fee:
Previous Supplemental Fee
Supplemental Fee:
SPSF Utilization:
Description of Work:
Firm:
Original Engineering Fee:
Previous Supplemental Fee
Supplemental Fee:
SPSF Utilization:
2015 Eastern Region Highway Divisions (Divisions 1,
2, 3, 4, and 6) Planning and Design LSC
The Louis Berger Group Inc, Morristown, NJ
$3,000,000.00
$2,000,000.00
Time extension only (6 months)
N/A
2015 Eastern Region Highway Divisions (Divisions 1,
2, 3, 4, and 6) Planning and Design LSC
VHB Engineering NC, P.C., Watertown, MA
$3,000,000.00
$8,000,000.00
Time extension only (6 months)
N/A
2015 Eastern Region Highway Divisions (Divisions 1,
2, 3, 4, and 6) Planning and Design LSC
Wetherill Engineering, Inc., Raleigh, NC
$3,000,000.00
$12,000,000.00
Time extension only (6 months)
N/A
Division 14
The following is a supplemental contract to a previous contract approved by the Board with the
same engineering firm. This supplemental contract was necessary due to approved additional
work that was unknown at the inception and is required of the firm to complete the project. Our
staff has completed the actions in accordance with the policies and procedures adopted by the
Board on May 7, 2009. This is for information only.
DIVISION 14
Description of work:
Firm:
Original Engineering Fee:
Supplemental Fee:
DBE/WBE/SPSF Utilization
SPSF Utilization:
DBE/MBE/SPSF Utilization
SPSF Utilization:
2018 Western Divisions' Planning & Design
Engineering Services Consultant (P&DSC) and
General Engineering Services Consultant (GESC) LSC
HNTB of North Carolina PC, Raleigh, NC
$6,000,000.00
$3,000,000.00
CH Engineering PLLC
5% / $150,000.00
Hinde Engineering Inc
5% / $150,000.00
MA Engineering Consultants Inc
5% / $150,000.00
MI Engineering PLLC
5% / $150,000.00
December 6, 2018
ITEM D
Page 7 of 14
Divisions - Statewide
The following are supplemental contracts to previous contracts approved by the Board with the
same engineering firms. These supplemental contracts were necessary due to approved
additional work that was unknown at the inception and is required of the firms to complete the
project. Our staff has completed the actions in accordance with the policies and procedures
adopted by the Board on May 7, 2009. This is for information only.
STATEWIDE
Description of work:
Firm:
Original Engineering Fee:
Previous Supplemental Fee
Supplemental Fee:
SPSF Utilization:
Description of work:
Firm:
Original Engineering Fee
Supplemental Fee:
SPSF Utilization:
2017 Statewide On-Call Construction Engineering &
Inspection Services LSC
Summit Design and Engineering Services PLLC,
Hillsborough, NC
$15,000,000.00
$10,000,000.00
$10,000,000.00
100%
2017 Statewide On-Call Construction Engineering &
Inspection Services LSC
Volkert Inc, Birmingham, AL
$15,000,000.00
$10,000,000.00
0%
Technical Services
Roadway Design Unit
The following are supplemental contracts to previous contracts approved by the Board with the
same engineering firms. These supplemental contracts were necessary due to approved
additional work that was unknown at the inception and is required of the firms to complete the
project. Our staff has completed the actions in accordance with the policies and procedures
adopted by the Board on May 7, 2009. This is for information only.
STATEWIDE
Description of work:
Firm:
Original Engineering Fee
Supplemental Fee:
SPSF Utilization:
SPSF Utilization:
DBE/WBE/SPSF Utilization
2016 Planning and Design LSC
AECOM Technical Services of North Carolina Inc,
Chicago, IL
$8,000,000.00
$3,000,000.00 and Time extension (6 months)
Summit Design and Engineering Services PLLC
2.5% / $75,000.00
Mattern & Craig Inc
1 % / $30,000.00
CH Engineering PLLC
1.5% / $45,000.00
December 6, 2018
ITEM D
Page 8 of 14
Description of work:
Firm:
Original Engineering Fee:
Previous Supplemental Fee
Supplemental Fee:
SPSF Utilization:
SPSF Utilization:
DBE/WBE/SPSF Utilization
2016 Planning and Design LSC
Atkins North America Inc, Raleigh, NC
$5,000,000.00
$3,000,000.00 and Time extension (6 months)
$3,000,000.00
Hinde Engineering Inc
3% / $90,000.00
MI Engineering PLLC
3% / $90,000.00
Planning Communities, LLC
5% / $150,000.00
Description of work: 2016 Planning and Design LSC
Firm: Calyx Engineers and Consultants Inc, Raleigh, NC
Original Engineering Fee: $8,000,000.00
Supplemental Fee: Time extension only (6 months)
SPSF Utilization: N/A
Description of work:
Firm:
Original Engineering Fee
Supplemental Fee:
SPSF Utilization:
Description of work:
Firm:
Original Engineering Fee
Supplemental Fee:
SPSF Utilization:
SPSF Utilization:
DBE/WBE/SPSF Utilization
SPSF Utilization:
SPSF Utilization:
DBE/MBE/SPSF Utilization
DBE/WBE/SPSF Utilization
Description of work:
Firm:
Original Engineering Fee
Supplemental Fee:
SPSF Utilization:
2016 Planning and Design LSC
Dewberry Engineers Inc, Raleigh, NC
$8,000,000.00
Time extension only (6 months)
N/A
2016 Planning and Design LSC
DRMP Inc, Charlotte, NC
$3,000,000.00
$2,000,000.00 and Time extension (6 months)
Hinde Engineering Inc
2% / $40,000.00
Patriot Transportation Engineering PLLC
5% / $100,000.00
Planning Communities, LLC
7% / $140,000.00
SpanishSpeaking, LLC
1 % / $20,000.00
Sungate Design Group PA
6% / $120,000.00
Tech Engineering Group PLLC
2% / $40,000.00
Three Oaks Engineering
8% / $160,000.00
2016 Planning and Design LSC
HDR Engineering Inc of the Carolinas, Chicago, IL
$8,000,000.00
Time extension only (6 months)
N/A
December 6, 2018
ITEM D
Page 9 of 14
Description of work:
Firm:
Original Engineering Fee
Supplemental Fee:
SPSF Utilization:
Description of work:
Firm:
Original Engineering Fee
Supplemental Fee:
SPSF Utilization:
SPSF Utilization:
DBE/WBE/SPSF Utilization
DBE/MBE/SPSF Utilization
DBE/MBE/SPSF Utilization
SPSF Utilization:
Description of work:
Firm:
Original Engineering Fee:
Supplemental Fee:
DBE/WBE/SPSF Utilization
SPSF Utilization:
Description of work:
Firm:
Original Engineering Fee:
Supplemental Fee:
DBE/WBE/SPSF Utilization
DBE/WBE/SPSF Utilization
DBE/WBE/SPSF Utilization
SPSF Utilization:
DBE/MBE/SPSF Utilization
SPSF Utilization:
2016 Planning and Design LSC
HNTB of North Carolina PC, Raleigh, NC
$8,000,000.00
Time extension only (6 months)
N/A
2016 Planning and Design LSC
Johnson Mirmiran & Thompson Inc, Hunt Valley, MD
$3,000,000.00
$2,000,000.00 and Time extension (6 months)
MI Engineering PLLC
12% / $240,000.00
Ramey Kemp & Associates, Inc.
4% / $80,000.00
Southeastern Right of Way LLC
2% / $40,000.00
Neighborhood Solutions LLC
2% / $40,000.00
Baseline Mobility Group Inc
2% / $40,000.00
LJB Inc
4% / $80,000.00
2016 Planning and Design LSC
KCI Associates of North Carolina PA, Baltimore, MD
$5,000,000.00
$3,000,000.00 and Time extension (6 months)
Planning Communities, LLC
20% / $600,000.00
Sungate Design Group PA
15% / $450,000.00
2016 Planning and Design LSC
Kimley-Horn & Associates Inc, Raleigh, NC
$8,000,000.00
$3,000,000.00 and Time extension (6 months)
CH Engineering PLLC
10% / $300,000.00
Falcon Engineering Inc
5% / $150,000.00
Wetherill Engineering, Inc.
8% / $240,000.00
Patriot Transportation Engineering PLLC
4% / $120,000.00
Neighborhood Solutions LLC
2% / $60,000.00
SpanishSpeaking, LLC
1 % / $30,000.00
December 6, 2018
ITEM D
Page 10 of 14
Description of work:
Firm:
Original Engineering Fee
Supplemental Fee:
SPSF Utilization:
Description of work:
Firm:
Original Engineering Fee:
Supplemental Fee:
DBE/MBE/SPSF Utilization
SPSF Utilization:
DBE/MBE/SPSF Utilization
Description of work:
Firm:
Original Engineering Fee
Supplemental Fee:
SPSF Utilization:
DBE/MBE/SPSF Utilization
SPSF Utilization:
DBE/WBE/SPSF Utilization
DBE/MBE/SPSF Utilization
Description of work:
Firm:
Original Engineering Fee
Supplemental Fee:
SPSF Utilization:
Description of work:
Firm:
Original Engineering Fee:
Supplemental Fee:
DBE/MBE/SPSF Utilization
SPSF Utilization:
DBE/WBE/SPSF Utilization
DBE/MBE/SPSF Utilization
2016 Planning and Design LSC
H. W. Lochner, Inc., Raleigh, NC
$8,000,000.00
Time extension only (6 months)
N/A
2016 Planning and Design LSC
Mead & Hunt Inc, Raleigh, NC
$3,000,000.00
$2,000,000.00 and Time extension (6 months)
John Davenport Engineering Inc
13% / $260,000.00
EEE Consulting Inc
4% / $80,000.00
Neighborhood Solutions LLC
5% / $100,000.00
2016 Planning and Design LSC
Moffatt & Nichol Incorporated, Raleigh, NC
$5,000,000.00
$3,000,000.00 and Time extension (6 months)
Clearbox Forecast Group PLLC
1 % / $30,000.00
John Davenport Engineering Inc
4.5% / $135,000.00
Joyner Keeny PLLC
2.5% / $75,000.00
Falcon Engineering Inc
2% / $60,000.00
Vistabution LLC
4% / $120,000.00
2016 Planning and Design LSC
Mott MacDonald I&E LLC, Pittsburgh, PA
$5,000,000.00
Time extension only (6 months)
N/A
2016 Planning and Design LSC
Rummel Klepper & Kahl LLP, Raleigh, NC
$8,000,000.00
$3,000,000.00 and Time extension (6 months)
Accelerate Engineering PLLC
1 % / $30,000.00
Patriot Transportation Engineering PLLC
1 % / $30,000.00
Falcon Engineering Inc
4% / $120,000.00
MM/I and Associates LLC
1 % / $30,000.00
December 6, 2018
ITEM D
Page 11 of 14
Description of work:
Firm:
Original Engineering Fee
Supplemental Fee:
SPSF Utilization:
DBE/WBE/SPSF Utilization
SPSF Utilization:
SPSF Utilization:
SPSF Utilization:
SPSF Utilization
Description of work:
Firm:
Original Engineering Fee:
Supplemental Fee:
DBE/MBE/SPSF Utilization
Description of work:
Firm:
Original Engineering Fee
Supplemental Fee:
SPSF Utilization:
Description of work:
Firm:
Original Engineering Fee
Supplemental Fee:
SPSF Utilization:
DBE/WBE/SPSF Utilization
SPSF Utilization:
DBE/WBE/SPSF Utilization
SPSF Utilization:
SPSF Utilization:
Description of work:
Firm:
Original Engineering Fee
Supplemental Fee:
SPSF Utilization:
2016 Planning and Design LSC
RS&H Architects-Engineers-Planners, Inc., Charlotte,
NC
$8,000,000.00
$3,000,000.00 and Time extension (6 months)
Carolina Ecosystems Inc
2.5% / $75,000.00
Planning Communities, LLC
2.5% / $75,000.00
Commonwealth Heritage Group Inc
2% / $60,000.00
Progressive Design Group, Inc.
4% / $120,000.00
Clearbox Forecast Group PLLC
1 % / $30,000.00
Angler Environmental
2% / $60,000.00
2016 Planning and Design LSC
Simpson Engineers & Associates PC, Cary, NC
$5,000,000.00
Time extension only (6 months)
N/A
2016 Planning and Design LSC
Stantec Consulting Services Inc, Raleigh, NC
$5,000,000.00
Time extension only (6 months)
N/A
2016 Planning and Design LSC
Stewart, Philadelphia, PA
$5,000,000.00
$3,000,000.00 and Time extension (6 months)
Patriot Transportation Engineering PLLC
8% / $240,000.00
Ecological Engineering LLP
15% / $450,000.00
Ramey Kemp & Associates, Inc.
6% / $180,000.00
Planning Communities, LLC
4% / $120,000.00
MI Engineering PLLC
3% / $90,000.00
Municipal Engineering Services Company PA
2% / $60,000.00
2016 Planning and Design LSC
STV Engineers, Inc., Charlotte, NC
$8,000,000.00
Time extension only (6 months)
N/A
December 6, 2018
ITEM D
Page 12 of 14
Description of work:
Firm:
Original Engineering Fee
Supplemental Fee:
SPSF Utilization:
Description of work:
Firm:
Original Engineering Fee
Supplemental Fee:
SPSF Utilization:
Description of work:
Firm:
Original Engineering Fee:
Supplemental Fee:
DBE/WBE/SPSF Utilization
Description of work:
Firm:
Original Engineering Fee
Supplemental Fee:
SPSF Utilization:
Description of work:
Firm:
Original Engineering Fee
Supplemental Fee:
SPSF Utilization:
SPSF Utilization:
SPSF Utilization:
DBE/WBE/SPSF Utilization
SPSF Utilization:
2016 Planning and Design LSC
Summit Design and Engineering Services PLLC,
Hillsborough, NC
$3,000,000.00
Time extension only (6 months)
N/A
2016 Planning and Design LSC
TGS Engineers, Shelby, NC
$8,000,000.00
Time extension only (6 months)
N/A
2016 Planning and Design LSC
Three Oaks Engineering, Durham, NC
$5,000,000.00
$3,000,000.00 and Time extension (6 months)
100%
2016 Planning and Design LSC
VHB Engineering NC, P.C., Watertown, MA
$8,000,000.00
Time extension only (6 months)
N/A
2016 Planning and Design LSC
WSP USA Inc, Raleigh, NC
$5,000,000.00
$3,000,000.00 and Time extension (6 months)
Carolina Ecosystems Inc
3% / $90,000.00
Utility Coordination Consultants
3% / $90,000.00
EEE Consulting Inc
2% / $60,000.00
Morton & Morton Design Services PLLC
1 % / $30,000.00
SpanishSpeaking, LLC
1 % / $30,000.00
December 6, 2018
ITEM D
Page 13 of 14
Turnpike Authority
Turnpike Authority
The following is a supplemental contract to a previous contract approved by the Board with the
same engineering firm. This supplemental contract was necessary due to approved additional
work that was unknown at the inception and is required of the firm to complete the project. Our
staff has completed the actions in accordance with the policies and procedures adopted by the
Board on May 7, 2009. This is for information only.
STATEWIDE
Description of work:
Firm:
Original Engineering Fee:
Previous Supplemental Fee
Supplemental Fee:
SPSF Utilization:
2015-2018 Traffic & Revenue Services LSC
Stantec Consulting Services Inc, Raleigh, NC
$3,000,000.00
$2,000,000.00
$2,000,000.00
Patriot Transportation Engineering PLLC
3% / $60,000.00
Turnpike Authority
The following is a supplemental contract to a previous contract approved by the Board with the
same engineering firm. This supplemental contract was necessary due to approved additional
work that was unknown at the inception and is required of the firm to complete the project. Our
staff has completed the actions in accordance with the policies and procedures adopted by the
Board on May 7, 2009. This is for information only.
STATEWIDE
Description of work:
Firm:
Original Engineering Fee:
Previous Supplemental Fee:
Supplemental Fee:
SPSF Utilization:
2015-2018 Toll Operation Services LSC
Atkins North America Inc, Raleigh, NC
$3,000,000.00
$3,000,000.00
$2,500,000.00
0%
December 6, 2018
ITEM D
Page 14 of 14
Turnpike Authority
The following is a supplemental contract to a previous contract approved by the Board with the
same engineering firm. This supplemental contract was necessary due to approved additional
work that was unknown at the inception and is required of the firm to complete the project. Our
staff has completed the actions in accordance with the policies and procedures adopted by the
Board on May 7, 2009. This is for information only.
STATEWIDE
Description of work:
Firm:
Original Engineering Fee
Supplemental Fee:
DBE/WBE Utilization:
SPSF Utilization:
On-Call General Professional and Engineering
Services for oversight of Public Private Partnership
and other Innovatively Delivered Projects
RS&H Architects-Engineers-Planners, Inc., Charlotte,
NC
$2,000,000.00
$2,000,000.00
B Reese Advisory LLC
5% / $100,000.00
Forge Communications LLC
5% / $100,000.00
END of ITEM D.
December 6, 2018
NCDOT DECEMBER 2018 BOARD OF TRANSPORTATION AGENDA
Secondary Road Improvement Projects (Highway and Trust Funds)
According to G.S. 143B-350(g), the Board is requested to concur with staff
recommendations and delegate authority to the Secretary to approve funds for
Secondary Road Improvement projects
Item E-1
Div / County SR No. / Road Description Amount
Name
Div 7 SR 2019 Grade, Base, Drain, & Pave $380,000.00
Rockingham Jarrell Road Establish Funds
7C.079242
Div 11 Countywide Countywide Spot Stabilization, $3,475.30
Caldwell Paved Road Improvements, Safety
Projects
Increase Funds
W BS 11 C.014020
Div 14 SR 1199 Grade, Base, Drain & Pave
Clay Emily Lane Establish Funds $80,000.00
WBS 14C.022056
Item E Summary:
2
Project to Establish Funds $460,000.00
Projects to Increase Funds $3,475.30
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Additions to the State Highway System:
County Pet. No. Length Description
Added
(Miles)
Division 2
Carteret 51743 0.03 Extend SR 1170, West Beaufort Road
Pitt 51744 Davis Farm
0.10 Cox Farm Road
Pitt 51745 Wellington West
0.38 Derbyshire Lane
0.05 Hardaway Place
Pitt 51754 0.56 Sugg Parkway
Division 3
Onslow
Pender
Division 4
Johnston
Division 7
Guilford
Guilford
Guilford
Division 8
Lee
Lee
Randolph
51746 0.49
51747
0.61
0.10
51748
0.23
0.07
51749
51750
51751
0.26
0.17
0.16
51752
51753
51755
0.09
0.40
0.30
Rockford Forest
McCall Drive
Holly Hill Estates
Holly Hill Road
S. Kingfisher Lane
Taft Woods East
Extend SR 3258, Rockport Drive
Mosswood Court
Galewood Acres
Galewood Drive
Kellam's Creek
Kellam's Creek Court
Stonebridge South
Stoneway Court
Mount Joy Place (Naugle)
Mount Joy Place
Quail Ridge
Lark Lane
Patriot Woods
Patriot Woods Drive
Date of
Report
1 /23/18
7/2/18
7/12/18
5/8/18
9/7/18
9/10/18
10/3/ 18
10/18/18
9/24/18
9/12/18
7/30/18
8/15/18
9/6/18
G-1
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Additions to the State Highway System:
County Pet. No. Length Description
Added
(Miles)
Division 10
Cabarrus 51756 0.20 Bill McGee Road
Division 12
Iredell
Iredell
Iredell
Division 13
Burke
51757
51758
51759
51760
0.83
0.12
1.00
0.13
0.22
0.04
0.07
Anniston
Walking Horse Trail
Overlook Ridge Lane
Bells Crossing
S. San Augustin Drive
Abbeville Lane
Campanile Drive
The Harbour
Windy Run Lane
Lakeridge
Lakeridge Court
Date of
Report
10/8/ 18
10/17/18
7/15/18
10/31/18
10/29/18
G-2
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Abandonments from the State Highway System:
County Pet. No. Length Description
Abandoned
(Miles)
Division 2
Beaufort 51761 0.50 All of SR 1169, Sawyer Road
Division 3
Onslow 51762 0.07 All of SR 1384, Water Plant Road
Division 10
Cabarrus 51763
Cabarrus 51764
Summary:
0.03 Portion of SR 1446, Quay Road
0.17 Portion of SR 1170
Crozier Branch Road
Number of roads petitioned for addition — 24
Number of roads petitioned for abandonment - 4
Minutes Corrections:
County Requested Action
None None
Date of
Report
9/27/18
10/5/ 18
10/22/18
10/8/2018
G-3
December 6, 2018
NCDOT DECEMBER 2018 BOARD OF TRANSPORTATION AGENDA
Funds Request
Division-wide Small Construction, Statewide Contingency,
Public Access, Economic Development, High Impact/Low Cost
ITEM H
According to Executive Order No. 2 and G.S. 143B-350(g), the Board is requested to
concur with staff recommendation and delegate authority to the Secretary to approve
funds for specific Division-wide Small Construction / Statewide Contingency projects.
Count Description T pe Amount
Div 2 WBS 49032 was established (02/18) for High Impact /
Beaufort widening, resurfacing, shoulder reconstruction, Low Cost ($200,000.00)
pavement markings & markers on NC-306
from NC 33 to the Beaufort/Pamlico Co. line TOTAL ($200,000.00)
Reduce funds
Div 2 WBS 49031 was established (02/18) for High Impact /
Jones widening, resurfacing, and shoulder Low Cost ($92,808.78)
reconstruction on SR 1116 (White Oak River
Rd) from SR 1117 to SR 1115 TOTAL ($92,808.78)
Reduce funds
Div 3 Relocate two Wendell Murphy Freeway signs,
Duplin including new supports, along I-40 Contingency $12,000.00
TOTAL $12,000.00
WBS 48440
Div 4 Town of Mount Olive — Construct a connector Small
Wayne road between NC-55 and Talton St and turn Construction $95,000.00
lanes on NC-55 Public Access $75,000.00
Contingency $750,000.00
WBS 80093 TOTAL $920,000.00
Div 7 WBS 47426 was established (06/17) for
Rockingham widening, turn lanes, and resurfacing on US- Contingency $16,239.56
158 and SR 2350 (Hudson Rd) at Bethany
Charter School TOTAL $16,239.56
Increase & close
Div 9 Replace two sections of concrete median
Forsyth barrier on I-40 between US-52 and Old Small
Lexington Rd in Winston-Salem Construction $125,000.00
WBS 48439 TOTAL $125,000.00
December 6, 2018 Page 1 of 2
NCDOT DECEMBER 2018 BOARD OF TRANSPORTATION AGENDA
Funds Request
Division-wide Small Construction, Statewide Contingency,
Public Access, Economic Development, High Impact/Low Cost
ITEM H
Count Description T pe Amount
Div 12 City of Claremont — WBS 45858 was
Catawba established (06/16) to grade, drain, base, &
pave approximately 1,400 ft of industrial Contingency $141,000.00
access road for new industrial facility; Project
Longbow TOTAL $141,000.00
Increase funds
Div 14 WBS 47415 was established (06/17) to extend Small
Cherokee existing turn lanes at US-64 & NC-294 and Construction $29,806.72
US-64 at crossover just west of Murphy
TOTAL $29,806.72
Increase funds
Deletion:
Div 2, Beaufort County — WBS 46386.2.1 was established (09/15) as a Scope revision to
expand a project on SR 1306 (15th St) from US-17 Business (Carolina Ave) to Brown St &
widen to multi-lanes; associated with TIP project U-5860; ROW currently unavailable
Summary:
Number of Divisions
Number of Projects
Small Construction Commitment
Public Access Commitment
Contingency Commitment
Economic Development Commitment
High Impact/Low Cost Commitment
TOTAL:
7
8
$249,806.72
$75.000.00
$919,239.56
$0.00
($292,808.78)
$951,237.50
December 6, 2018 Page 2 of 2
Item I - 1
1 of 1
NCDOT December 2018 Board of Transportation Agenda
Public Transportation Program
Town/County Project Description Estimated
Division Cost
There will be no items presented for approval at
the December 6, 2018, Board of Transportation
meeting.
ITEM I- 1 SUMMARY — NO PROJECTS
December 6, 2018
Item I-2
1 of 1
NCDOT December 2018 Board of Transportation Agenda
Rail Program
Town/County Project Description Estimated
Division Cost
There will be no items presented for approval at
the December 6, 2018 Board of Transportation
meeting.
ITEM I-2 SUMMARY — NO PROJECTS
December 6, 2078
Item I - 3
1 of 1
NCDOT December 2018 Board of Transportation Agenda
Division of Bicycle and Pedestrian Transportation
Town/County Project Description Estimated
Division Cost
There will be no items presented for approval at
the December 6, 2018, Board of Transportation
meeting.
ITEM I- 3 SUMMARY — NO PROJECTS
December 6, 2018
Item I - 4
1 of 1
NCDOT December 2018 Board of Transportation Agenda
Aviation Program
Division
Airport
County
Division 8
Raleigh Executive
Jetport
Lee County
Project Description
Parking Lot and Access Road (Construction)
This project will reconstruct old failing terminal area parking and airfield access road
pavements. [PR# 4049]
ITEM I-4 SUMMARY — 1 PROJECT —(TOTAL STATE and FEDERAL COST) $904,500.
� Project selection and approval for award. Costs are estimated. Only eligible costs within the project
scope of work will be reimbursed.
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Strategic Transportation Investments Funds
Town/
County
Division
PROJ.
CATEGORY
Project
Description
Bertie Co. WBS 46976.1.1
Div. 1 NC 45 from Hertford County Line to Washington County Line.
R-5809 $819,333.00 has previously been approved for preliminary
DIVISION engineering. Additional funds are requested for planning and
design.
Northampton WBS 44709.1.1
Co. NC 305 from Seaboard Town Limits to Hertford County Line.
Div. 1 $737,952.00 has previously been approved for preliminary
R-5757 engineering. Additional funds are requested for planning and
DIVISION design.
Tyrrell Co. WBS 46478.3.1
Div. 1 Bridge # 7 over Alligator River on US 64. $18,250,000.00 has
B-5936 previously been approved for construction. Additional funds are
STATEWIDE needed to cover expenditures that have or will exceed the
previously authorized budget.
K-1
Estimated
Cost
$500,000.00
$600,000.00
$500,000.00
Carteret Co. WBS 44678.1.1 $1,000,000.00
Div. 2 US 70 (Arendell Street) from 4th street to SR 1175
U-5876 (Radio Island Road). $300,000.00 has previously been
STATEWIDE approved for preliminary engineering. Additional funds are
requested.
Lenoir Co. WBS 46375.2.1 $750,000.00
Div. 2 NC 148 (Harvey Parkway) from NC 58 to NC 11. $6,690,000.00
R-5703 has previously been approved for full right of way. Additional
REGIONAL funds are needed to cover expenditures that have or will exceed
the previously authorized budget.
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Strategic Transportation Investments Funds
Town/
County
Division
PROJ.
CATEGORY
Project
Description
Brunswick/ WBS 34491.2.3
New Hanover US 17 (Wilmington Bypass) from US 74-76 east of Malmo in
Cos. Brunswick County to US 421 north of Wilmington in New
Div. 3 Hanover County. $32,050,000.00 has previously been approved
R-2633B for right of way and utilities. Additional funds are requested for
STATEWIDE legal settlements. This is a Strategic Transportation
Investments Transition project. This project has previously
been identified as a Trust Fund Urban Loop project.
Brunswick Co. WBS 45942.1.1
Div. 3 US 17 at NC 211. $1,000,000.00 has previously been approved
U-5932 for preliminary engineering. Additional funds are requested.
STATEWIDE
Brunswick Co. WBS 48350.1.1
Div. 3 US 17 (Shallotte Bypass) at US 17 Business South
U-6104 (Main Street). $10,000.00 has previously been approved for
REGIONAL preliminary engineering. Additional funds are requested for
planning and design.
New Hanover WBS 40238.1.2
Co. US 17 Business (Market Street) from CSX Railroad to Cinema
Div. 3 Drive and from Jacksonville Street to north of US 117/NC 132
U-4902B (College Road). $1,750,000.00 has previously been approved
REGIONAL for preliminary engineering. Additional funds are requested.
New Hanover WBS 40238.1.3
Co. US 17 Business (Market Street) from north of US 117 / NC 132
Div. 3 (College Road) to Station Road. $3,500,000.00 has previously
U-4902C been approved for preliminary engineering. Additional funds are
STATEWIDE requested.
K-2
Estimated
Cost
$3,300,000.00
$300,000.00
$750,000.00
'.:�� ��� ��
$650,000.00
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Strategic Transportation Investments Funds
Town/
County
Division
PROJ.
CATEGORY
New Hanover
Co.
Div. 3
U-4902D
STATEWIDE
New Hanover
Co.
Div. 3
U-5710A
STATEWIDE
New Hanover
Co.
Div. 3
U-5729
REGIONAL/
STATEWIDE
New Hanover
Co.
Div. 3
U-5863
REGIONAL
Project
Description
WBS 40238.1.4
US 17 Business (Market Street) from SR 1403
(Middle Sound Loop Road) to SR 2290 (Mendenhall Drive)/
SR 2734 (Marsh Oaks Drive). $2,500,000.00 has previously
been approved for preliminary engineering. Additional funds are
requested.
W BS 50115.2.2
New location from SR 1409 (Military Cutoff Road) at
Drysdale Drive to US 74 (Eastwood Road). Initial funds are
requested for full right of way and utilities.
WBS 54020.1.1
US 421 (Carolina Beach Road) from US 421 (Burnett Avenue)
to US 117 (Shipyard Boulevard) in Wilmington. $1,600,000.00
has previously been approved for preliminary engineering.
Additional funds are requested using Statewide Tier funding.
WBS 46388.1.1
NC 133 from I-140/US 17, Wilmington Bypass to SR 1310
(Division Drive). $1,000,000.00 has previously been approved
for preliminary engineering. Additional funds are requested.
New Hanover WBS 44695.1.1
Co. NC 132 (College Road) from SR 2048 (Gordon Road) to
Div. 3 SR 1272 (New Centre Drive). $750,000.00 has previously been
U-5881 approved for preliminary engineering. Additional funds are
STATEWIDE requested.
K-3
Estimated
Cost
$775,000.00
$6,422,000.00
$200,000.00
$300,000.00
$250,000.00
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Strategic Transportation Investments Funds
Town/
County
Division
PROJ.
CATEGORY
Project
Description
New Hanover WBS 48351.1.1
Co. US 76 (Oleander Drive) at Greenville Loop Road and Greenville
Div.3 Avenue. $10,000.00 has previously been approved for
U-6128 preliminary engineering. Additional funds are requested for
REGIONAL planning and design.
K-4
Estimated
Cost
$250,000.00
Onslow Co. WBS 48353.1.1 $1,000,000.00
Div. 3 NC 24 (West Corbett Avenue) from Belgrade-Swansboro Road
R-5885 to Front Street. $10,000.00 has previously been approved for
REGIONAL preliminary engineering. Additional funds are requested for
planning and design.
Onslow Co. WBS 54019.1.1
Div. 3 US 17 Business (Marine Boulevard) at SR 1308
U-5728 (Bell Fork Road) in Jacksonville. $551,711.00 has previously
REGIONAL been approved for preliminary engineering. Additional funds are
requested.
Onslow Co. WBS 54025.1.1
Div. 3 US 17 (Wilmington Highway) at SR 1130
U-5735 (Old Maple Hurst Road). Construct interchange. $1,400,000.00
REGIONAL has previously been approved for preliminary engineering.
Additional funds are requested.
Onslow Co. WBS 54026.1.1
Div. 3 NC 53 (Western Boulevard) from US 17 (Marine Boulevard) to
U-5736 NC 24 (Lejuene Boulevard). $2,000,000.00 has previously been
REGIONAL approved for preliminary engineering. Additional funds are
requested.
$150,000.00
$500,000.00
$500,000.00
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Strategic Transportation Investments Funds
Town/
County
Division
PROJ.
CATEGORY
Project
Description
Onslow Co. WBS 54028.1.1
Div. 3 US 258 (Richlands Highway) from SR 1212 (Pony Farm Road)
U-5739 to SR 1213 (Blue Creek Road). $1,500,000.00 has previously
REGIONAL been approved for preliminary engineering. Additional funds are
requested.
Onslow Co. WBS 44359.1.1
Div. 3 SR 2715 (Trade Street) from NC 53 (Western Boulevard) to
U-5787 McDaniel Drive. $500,000.00 has previously been approved for
DIVISION preliminary engineering. Additional funds are requested.
Onslow Co. WBS 44694.1.1
Div. 3 Commerce Drive, from Commerce Drive to SR 1406
U-5878 (Piney Green Road). $750,000.00 has previously been
DIVISION approved for preliminary engineering. Additional funds are
requested.
Onslow Co. WBS 46896.1.1
Div. 3 NC 210 from US 17 to South of SR 1518 (Old Folkstone Road).
U-5949 $1,000,000.00 has previously been approved for preliminary
REGIONAL engineering. Additional funds are requested.
Onslow Co. WBS 45870.1.1
Div. 3 US 17 at US 17 Business (Marine Boulevard). $750,000.00 has
U-5951 previously been approved for preliminary engineering.
REGIONAL Additional funds are requested.
K-5
Estimated
Cost
$500,000.00
$300,000.00
$500,000.00
$150,000.00
$600,000.00
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Strategic Transportation Investments Funds
Town/
County
Division
PROJ.
CATEGORY
Project
Description
Onslow Co. WBS 48352.1.1
Div. 3 US 258 / NC 24 at SR 1329 (Rhodestown Fire Department
U-6148 Road). $10,000.00 has previously been approved for
REGIONAL preliminary engineering. Additional funds are requested for
planning and design.
New Hanover/ WBS 40237.1.1
Pender Cos. US 17 Hampstead Bypass from US 17 to US 17 north of
Div. 3 Hampstead. $4,033,500.00 has previously been approved for
R-3300 preliminary engineering. Additional funds are requested.
STATEWIDE This project has previously been identified as a Trust Fund
Intrastate System project.
Pender Co. WBS 48354.1.1
Div. 3 US 17 at NC 210 (Surf City). $10,000.00 has previously been
R-5877 approved for preliminary engineering. Additional funds are
REGIONAL requested for planning and design.
Pender Co. WBS 48355.1.1
Div. 3 NC 210 at SR 1560 (Watts Landing Road). $10,000.00 has
R-5899 previously been approved for preliminary engineering.
REGIONAL Additional funds are requested for planning and design.
Pender Co. WBS 48356.1.1
Div. 3 NC 50 / NC 210 at SR 1534 (Belt Road). $10,000.00 has
R-5900 previously been approved for preliminary engineering.
REGIONAL Additional funds are requested for planning and design.
K-6
Estimated
Cost
$250,000.00
$3,250,000.00
$250,000.00
$250,000.00
$250,000.00
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Strategic Transportation Investments Funds
Town/
County
Division
PROJ.
CATEGORY
Project
Description
K-7
Estimated
Cost
Pender Co. WBS 54023.1.1 $2,650,000.00
Div. 3 US 17 from SR 1582 (Washington Acres Road) to SR 1563
U-5732 (Sloop Point Loop Road). Convert to superstreet. $2,500,000.00
REGIONAL has previously been approved for preliminary engineering.
Additional funds are requested.
Sampson Co. WBS 48328.1.1
Div. 3 NC 24 (Southwest Boulevard/MLK JR. Boulevard) at
U-6126 Butler Road/Tram Road. $10,000.00 has previously been
REGIONAL approved for preliminary engineering. Additional funds are
requested for planning and design.
Edgecombe/ WBS 44908.3.2
Nash Cos. CSX A Line Intermodal Terminal. Initial funds are requested for
Div.4 construction.
P-5711 A
STATEWIDE
Edgecombe WBS 39062.1.2
Co. NC 111 (Wilson Street) from US 64 Alternate
Div.4 (Western Boulevard) to NC 122 (McNair Road). $315,000.00
U-4424 has previously been approved for preliminary engineering.
DIVISION Additional funds are requested.
Wayne Co. WBS 34461.2.7
Div. 4 US 70 (Goldsboro Bypass) from east of SR 1300
R-2554BA (Salem Church Road) to east of SR 1556
STATEWIDE (Wayne Memorial Drive). $12,187,000.00 has previously been
approved for right of way and utilities. Funds need to be
decreased ($1,372,748.43). WBS will be closed.
$250,000.00
$50,000,000.00
$720,000.00
-$1,372,748.43
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Strategic Transportation Investments Funds
Town/
County
Division
PROJ.
CATEGORY
Project
Description
Durham Co. WBS 46393.1.31
Div.5 Blackwell / Mangum grade separation. Initial funds are
P-5602EC requested for preliminary engineering.
STATEWIDE
Durham Co. WBS 50166.3.1
Div.5 NC 751 (Hope Valley Road) at SR 1183 (University Drive)
U-5745 intersection in Durham. $1,815,000.00 has previously been
REGIONAL approved for construction. $1,000,000.00 of Regional Strategic
Transportation Investments funds will be replaced with Build
NC Bonds funds.
Durham Co. WBS 50166.1.1
Div.5 NC 751 (Hope Valley Road) at SR 1183 (University Drive)
U-5745 intersection in Durham. $400,500.00 has previously been
REGIONAL approved for preliminary engineering. $356,000.00 of Regional
Strategic Transportation Investments funds will be replaced with
Build NC Bonds funds.
Franklin Co. WBS 46957.1.1
Div. 5 US 401 / NC 39 from NC 56 / NC 581 (Nash Street) to SR 1229
R-3608 (Main Street). $250,000.00 has previously been approved for
REGIONAL preliminary engineering. Additional funds are requested for
planning and design.
Franklin Co. WBS 47151.1.1
Div. 5 US 401 / NC 39 from Burke Boulevard to NS 56 / NC 581
U-6024 (Nash Street) in Louisburg. $250,000.00 has previously been
DIVISION approved for preliminary engineering. Additional funds are
requested for planning and design.
K-8
Estimated
Cost
$100,000.00
G,� ��
$0.00
$600,000.00
$500,000.00
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Strategic Transportation Investments Funds
Town/
County
Division
PROJ.
CATEGORY
Wake Co.
Div. 5
P-5602EA
STATEWIDE
Wake Co.
Div. 5
P-5602EB
STATEWIDE
Project
Description
WBS 46393.1.29
Wolfpack Lane grade separation. Initial funds are requested for
preliminary engineering.
W BS 46393.1.30
Jones Sausage Road grade separation. Initial funds are
requested for preliminary engineering.
Wake Co. WBS 48000.1.1
Div. 5 US 401 from south of SR 1006 (Old Stage Road) to south of
U-5302 SR 2538 (Mechanical Boulevard) in Garner. $795,000.00 has
REGIONAL previously been approved for preliminary engineering.
Additional funds are requested to complete final design.
K-9
Estimated
Cost
$150,000.00
$100,000.00
$350,000.00
Wake Co. WBS 44384.1.1 $1,500,000.00
Div. 5 SR 1002 (Aviation Parkway) from NC 54 to I-40 in Morrisville.
U-5811 $500,000.00 has previously been approved for preliminary
DIVISION engineering. Additional funds are requested for preliminary
engineering.
Wake Co. WBS 44398.2.1 $1,000,000.00
Div. 5 SR 2000 (Falls of Neuse Road) from I-540 to SR 2006
U-5826 (Durant Road). Initial funds are requested for full right of way
DIVISION and utilities.
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Strategic Transportation Investments Funds
Town/ Project
County Description
Division
PROJ.
CATEGORY
Wake Co. WBS 44706.1.1
Div.5 NC 50 (Creedmoor Road) from I-540 to north of NC 98.
U-5891 $300,000.00 has previously been approved for preliminary
REGIONAL engineering. Additional funds are requested for planning and
design.
Alamance Co. WBS 46393.1.26
Div. 7 Buckhorn road grade separation. Initial funds are requested for
P-5602GA preliminary engineering.
STATEWIDE
Greensboro/ WBS 34821.2.SU3
Guilford Co. Greensboro Eastern Loop from north of US 70 to US 29 north of
Div. 7 Greensboro. $3,000,000.00 has previously been approved for
U-2525B utilities. Funds need to be decreased ($1,836,259.49). This is a
STATEWIDE Strategic Transportation Investments Transition project.
WBS will be closed.
Guilford Co. WBS 44674.2.1
Div. 7 US 29 / US 70 / Business 85 at SR 1009 (South Main Street) in
U-5896 High Point. Funds are requested for advanced acquisition of
DIVISION Specific Parcel 605 (Property of John A. Herke and wife
Margaret) for $577,875.00.
Carrboro/ WBS 34860.2.1
Orange Co. SR 1919 (Smith Level Road) from Rock Haven Road to Bridge
Div.7 88 over Morgan Creek. $3,602,826.00 has previously been
U-2803 approved for right of way and utilities. Funds need to be
DIVISION decreased ($2,082,585.54). This project has previously been
identified as a Trust Fund Specific State Funds
Construction project. WBS will be closed.
K-10
Estimated
Cost
$2,000,000.00
$100,000.00
-$1,836,259.49
$577,875.00
-$2,082,585.54
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Strategic Transportation Investments Funds
Town/
County
Division
PROJ.
CATEGORY
Project
Description
Statewide WBS 46404.1.12
Div. 7 Greensboro Western Loop MapAct lawsuit. $200,000.00 has
M-0488L previously been approved for preliminary engineering / legal
REGIONAL services. Funds need to be decreased ($200,000.00). WBS will
be closed.
Guilford/
Randolph
Cos.
Div. 7/08
U-5864A
DIVISION
Lee Co.
Div. 8
AV-5856
DIVISION
W BS 46389.1.2
SR 1595 / SR 4053 (Surret Drive) from I-85 in Trinity to
SR 1300 (West Fairfield Road) in High Point. $400,000.00 has
previously been approved for preliminary engineering.
Additional funds are needed to cover expenditures that have
exceeded the previously authorized budget. WBS will be closed.
WBS 47209.1.1
Sanford-Lee County Regional Airport (TTA), corporate hangar
apron expansion. Initial funds are requested for preliminary
engineering.
Lee Co. WBS 38887.2.2
Div. 8 NC 42 / SR 1579 from US 421 in Sanford to SR 1538
R-3830 (East Harrington Avenue) in Broadway. Initial funds are
DIVISION requested for utilities.
Moore Co. WBS 47208.1.1
Div. 8 Moore County Airport (SOP), construct hangar taxiways and
AV-5855 internal airfield service road. Initial funds are requested for
DIVISION preliminary engineering.
K-11
Estimated
Cost
-$200,000.00
$111, 337.44
$350,000.00
$6,000,000.00
$300,000.00
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Strategic Transportation Investments Funds
Town/
County
Division
PROJ.
CATEGORY
Forsyth Co
Div. 9
AV-5832
DIVISION
Forsyth Co
Div. 9
AV-5832
DIVISION
Project
Description
WBS 47185.1.1
Smith Reynolds Airport (INT). Construct new taxilane. Initial
funds are requested for preliminary engineering.
WBS 47185.4.1
Smith Reynolds Airport (INT). Construct new taxilane. Initial
funds are requested for project mitigation for taxilane.
Cabarrus/ WBS 46378.1.1
Mecklenburg NC 73 (Davidson Highway) from SR 2693 (Davidson-Concord
Cos. Road) to US 29. $750,000.00 has previously been approved for
Div. 10 preliminary engineering. Additional funds are requested for
R-5706 design.
REGIONAL
Cabarrus Co. WBS 47896.3.1
Div. 10 Various, extend left turn lane at NC 73 and SR 1430. Construct
U-6098 right and left turn at access road on NC 73. Construct
DIVISION roundabout at SR 1620 and SR 1621 (Barr Road). Construct
200 feet southbound on-ramp right turn lane at I-85 and extend
storage to northbound off ramp. Initial funds are requested for
construction.
Mecklenburg WBS 53063.1.1
Co. I-85 from SR 2472 W. Mallard Creek Church Road) to 0.8 mile
Div. 10 north of SR 2467 (Mallard Creek Road). $560,000.00 has
I-5860 previously been approved for preliminary engineering. Funds
STATEWIDE need to be decreased ($560,000.00). Project will be
accomplished under project I-5826. WBS will be closed.
K-12
Estimated
Cost
$250,100.00
$4,300,937.00
$600,000.00
$1,700,000.00
-$560,000.00
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Strategic Transportation Investments Funds
Town/
County
Division
PROJ.
CATEGORY
Mecklenburg
Co.
Div. 10
P-5602JA
STATEWIDE
Mecklenburg
Co.
Div. 10
P-5602J B
STATEWIDE
Mecklenburg
Co.
Div. 10
R-2632AB
REGIONAL
Project
Description
WBS 46393.1.27
Old Dowd Road grade separation. Initial funds are requested for
preliminary engineering.
WBS 46393.1.28
Orr Road grade separation. Initial funds are requested for
preliminary engineering.
WBS 38824.1.2
NC 73 from NC 115 to SR 2693 (Davidson-Concord Road).
$343,768.00 has previously been approved for preliminary
engineering. Additional funds are requested for design.
K-13
Estimated
Cost
$30,000.00
$75,000.00
$400,000.00
Union Co. WBS 46398.3.1 $8,200,000.00
Div. 10 CSX SF Line, Milepost 311.8 to Milepost 316.9. 10,000 feet
P-5704 track siding extension at Stouts in Union County. Initial funds
REGIONAL are requested for construction. This is a Cash Flow project
with $3,500,000.00 in SFY 19 and $4,700,000.00 in SFY 20.
Union Co. WBS 50129.2.1 $800,000.00
Div. 10 US 74 (Roosevelt Boulevard) and SR 1514 (Rocky River Road)
U-5703 intersection. $400,000.00 has previously been approved for full
STATEWIDE right of way and utilities. Additional funds are requested.
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Strategic Transportation Investments Funds
Town/
County
Division
PROJ.
CATEGORY
Project
Description
Union Co. WBS 50129.1.3
Div. 10 US 74 (Roosevelt Boulevard), realign James Hamilton Road to
U-5703B intersect with SR 1514 (Rocky River Road) at Myers Road.
STATEWIDE Initial funds are requested for preliminary engineering.
Alleghany Co. WBS 34605.2.RU1
Div. 11 US 21 (Sparta Western Loop) from SR 1172 (Grandview Drive)
R-4060 to US 21. $130,000.00 has previously been approved for
REGIONAL utilities. Funds need to be decreased ($85,605.84). WBS will be
closed.
Surry Co. WBS 47998.1.1
Div. 11 I-74 & I-77 interchange/ramps. Initial funds are requested for
I-6050 preliminary engineering.
STATEWIDE
Yadkin Co
Div. 11
U-5809
DIVISION
WBS 44382.2.1
US 601 (State Street) from US 421 to SR 1146 (Lee Avenue).
Initial funds are requested for full right of way and utilities.
Mount Holly/ WBS 37649.2.RU2
Gaston Co. NC 273 (South Main Street) from Tuckaseege Road
Div. 12 (at Beatty Drive) to Highland Street. $60,567.00 has previously
U-3633 been approved for utilities. Funds need to be decreased
REGIONAL ($59,417.31). WBS will be closed.
K-14
Estimated
Cost
$10, 000.00
-$85,605.84
$10,000.00
$1,700,000.00
-$59,417.31
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Strategic Transportation Investments Funds
Town/
County
Division
PROJ.
CATEGORY
Project
Description
Iredell Co. WBS 41890.1.2
Div. 12 SR 1109 (Williamson Road) from I-77 to SR 1100
R-5100A (Brawley School Road). Initial funds are requested for
DIVISION preliminary engineering.
Rutherford WBS 50225.1.1
Co. SR 2241 (Oak Street) from SR 2159 (Pine Ridge Road) to
Div.13 US 74. $624,978.00 has previously been approved for
U-5833 preliminary engineering. $624,978.44 of Division Strategic
DIVISION Transportation Investments funds will be replaced with Build
NC Bonds funds. Additional funds of $49,022.00 of Build NC
Bonds funds are requested.
Rutherford WBS 50225.3.1
Co. SR 2241 (Oak Street) from SR 2159 (Pine Ridge Road) to
Div.13 US 74. $4,459,810.00 has previously been approved for
U-5833 construction. $4,000,000.00 of Division Strategic Transportation
DIVISION Investments funds will be replaced with Build NC Bonds funds.
K-15
Estimated
Cost
$500,000.00
$49,022.00
$0.00
Cherokee Co. WBS 50193.1.1 $2,500,000.00
Div. 14 US 19 / US 74 / US 64 / US 129 from the end of 4-lane divided
R-5735 section to SR 1556 (Martins Creek Road). $1,678,393.00 has
DIVISION previously been approved for preliminary engineering.
Additional funds are requested.
Cherokee/ WBS 47090.1.1 $450,000.00
Clay Cos. US 64 Business west of Hayesville to east of NC 141. Widen to
Div. 14 four lanes divided. $1,400,000.00 has previously been approved
R-5847 for preliminary engineering. Additional funds are requested.
DIVISION
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Strategic Transportation Investments Funds
Town/
County
Division
PROJ.
CATEGORY
Project
Description
Clay Co. WBS 46325.1.D1
Div. 14 NC 175 from Georgia State Line to US 64, upgrade roadway.
R-5742 $1,608,893.00 has previously been approved for preliminary
DIVISION engineering. Additional funds are requested.
Clay Co. WBS 46325.2.1
Div. 14 NC 175 from Georgia State Line to US 64, upgrade roadway.
R-5742 $2,200,000.00 has previously been approved for full right of way
DIVISION and utilities. Additional funds are requested.
Clay Co.
Div. 14
R-5863
DIVISION
WBS 47516.1.1
US 64 Business from Main Street to US 64. $700,000.00 has
previously been approved for preliminary engineering.
Additional funds are requested.
Graham Co. WBS 34508.1.2
Div.14 NC 143 from west Buffalo Creek to NC 143 Business.
R-2822B $605,000.00 has previously been approved for preliminary
REGIONAL engineering. Additional funds are requested.
Graham/
Swain Cos
Div. 14
R-5839
DIVISION
WBS 47109.1.1
NC 28 (Fontana Road) from NC 143 to US 129. Upgrade
roadway. $250,000.00 has previously been approved for
preliminary engineering. Additional funds are requested.
K-16
Estimated
Cost
$340,000.00
$550,000.00
$150,000.00
$400,000.00
�,.:� ��� ��
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Strategic Transportation Investments Funds
Town/
County
Division
PROJ.
CATEGORY
Project
Description
Haywood Co. WBS 50230.1.1
Div. 14 US 276 (Russ Avenue) from US 23/74 to US 23 Business
U-5839 (Main Street). $2,443,401.00 has previously been approved for
DIVISION preliminary engineering. Additional funds are requested.
Henderson WBS 50231.3.1
Co. SR 1547 (Old Airport Road) from US 25 to Mills Gap Road.
Div. 14 $4,100,000.00 has previously been approved for construction.
U-5840 $4,100,000.00 of Division Strategic Transportation Investments
DIVISION funds will be replaced with Build NC Bonds funds. Additional
funds of $2,900,000.00 of Build NC Bonds funds are requested
per the latest estimate.
Henderson WBS 50231.1.D1
Co. SR 1547 (Old Airport Road) from US 25 to Mills Gap Road.
Div. 14 $1,130,000.00 has previously been approved for preliminary
U-5840 engineering. $1,101,000.00 of Division Strategic Transportation
DIVISION Investments funds will be replaced with Build NC Bond funds.
Additional funds of $52,367.95 are requested.
Henderson WBS 44710.1.1
Co. SR 1170 (White Street) from SR 1171 (Willow Road) to US 176
Div.14 (Spartanburg Highway). $720,000.00 has previously been
U-5886 approved for preliminary engineering. Additional funds are
DIVISION requested.
Jackson Co. WBS 47084.1.2
Div. 14 NC 107 from NC 281 to Tuckaseegee Lake. $100,000.00 has
R-5841A previously been approved for preliminary engineering.
DIVISION Additional funds are requested.
K-17
Estimated
Cost
$300,000.00
$2,900,000.00
$52,367.95
$750,000.00
'.�:� ��� ��
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Strategic Transportation Investments Funds
Town/
County
Division
PROJ.
CATEGORY
Project
Description
Jackson Co. WBS 47084.1.3
Div. 14 NC 107 from 1000 feet North of the Lake Tuckaseegee Dam to
R-5841 B approximately 1 mile North of SR 1157 (Pine Creek Road).
DIVISION $500,000.00 has previously been approved for preliminary
engineering. Additional funds are requested.
Macon Co. WBS 50192.1.1
Div. 14 US 23/ US 441 from US 64 to SR 1652 (Wide Horizon Drive) /
R-5734A SR 1152 (Belden Circle). $1,781,319.00 has previously been
DIVISION approved for preliminary engineering. Additional funds are
requested.
Macon Co. WBS 50192.1.2
Div. 14 US 23 / US 441 from SR 1652 (Wide Horizon Drive) / SR 1152
R-5734B (Belden Circle) to SR 1649 (Prentiss Bridge Road). $545,000.00
REGIONAL has previously been approved for preliminary engineering.
Additional funds are requested.
Polk Co. WBS 34243.2.2
Div. 14 I-26 / US 74 / NC 108 interchange. $940,000.00 has previously
I-4729A been approved for full right of way and utilities. Additional funds
REGIONAL are requested.
Polk Co. WBS 34243.1.5
Div. 14 Construct improvements on NC 108 at exit 67. $780,000.00 has
I-4729B previously been approved for preliminary engineering.
REGIONAL Additional funds are requested.
K-18
Estimated
Cost
$810,000.00
$110,000.00
$430,000.00
'.:�� ��� ��
$300,000.00
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Strategic Transportation Investments Funds
Town/
County
Division
PROJ.
CATEGORY
Polk Co.
Div. 14
R-5840
DIVISION
Swain/
Jackson Cos.
Div. 14
R-4751
REGIONAL
Transylvania
Co.
Div. 14
R-5763
DIVISION
Transylvania
Co.
Div. 14
R-5799
REGIONAL
Project
Description
WBS 47083.1.1
NC 9 from US 74 to NC 108. Add paved shoulders. $625,000.00
has previously been approved for preliminary engineering.
Additional funds are requested.
WBS 40115.1.2
US 19 from SR 1152 (Hughes Branch Road) in Bryson City to
SR 1195 (US 19A). $1,170,000.00 has previously been
approved for preliminary engineering. Additional funds are
requested.
WBS 44638.1.1
SR 1540 (Wilson Road) from SR 1504 (Old US 64) to US 276.
$1,420,000.00 has previously been approved for preliminary
engineering. Additional funds are requested.
WBS 44984.1.1
Intersections of US 64, US 276
previously been approved
Additional funds are requested.
and NC 280. $705,000.00 has
for preliminary engineering.
Statewide WBS 34634.4.6
R-9999 Mitigation for Little Tenn 0204. Initial funds are requested to
STATEWIDE purchase private mitigation bank credits.
K-19
Estimated
Cost
$390,000.00
$130,000.00
$350,000.00
$820,000.00
$2,511,600.00
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Strategic Transportation Investments Funds
Town/
County
Division
PROJ.
CATEGORY
Project
Description
Statewide WBS 34634.4.7 $14,318,118.00
R-9999WM Mitigation for Pasquotank 0205. Initial funds are requested to
STATEWIDE/ purchase private mitigation bank credits using 40% Statewide
REGIONAL/ ($5,727,247.20) / 30% Regional ($4,295,435.40) / 30% Division
DIVISION ($4,295,435.40) Tier funding.
Statewide WBS 34634.4.8 $6,471,648.00
R-9999WM Mitigation for Watauga 0103. Initial funds are requested to
STATEWIDE/ purchase private mitigation bank credits using 40% Statewide
REGIONAL/ ($2,588,659.20) / 30% Regional ($1,941,494.40) / 30% Division
DIVISION ($1,941,494.40) Tier funding.
K-20
Estimated
Cost
Statewide WBS 34634.4.9 $10,167,998.00
R-9999WM Mitigation for Cape Fear 0005. Initial funds are requested to
STATEWIDE/ purchase private mitigation bank credits using 40% Statewide
REGIONAL/ ($4,067,199.20) / 30% Regional ($3,050,399.40) / 30% Division
DIVISION ($3,050,399.40) Tier funding.
STATEWIDE STRATEGIC TRANSPORTATION 23 PROJECTS $66,564,592.08
INVESTMENTS
REGIONAL STRATEGIC TRANSPORTATION
INVESTMENTS
35 PROJECTS
$24,834,976.85
DIVISION STRATEGIC TRANSPORTATION
INVESTMENTS
REGIONAL/STATEWIDE STRATEGIC
TRANSPORTATION INVESTMENTS
STATEWIDE/REGIONAL/DIVISION STRATEGIC
TRANSPORTATION INVESTMENTS
STRATEGIC TRANSPORTATION INVESTMENTS
36 PROJECTS
1 PROJECT
3PROJECTS
98 PROJECTS
$30,189,053.85
$200,000.00
$30,957,764.00
$152,746,386.78
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Spot Safety Improvement Projects
and for Specific Spot Mobility Projects
L-1
According to Executive Order No. 2 and G.S. 143B-350(g) the Board is requested to
concur with staff recommendations and delegate authority to the Secretary to approve
Funds for Specific Spot Safety and Spot Mobility Improvement Projects
Town/ Project Estimated
County Description Cost
Division
PROJ.
CATEGORY
Bertie Co. WBS 48284.3.1
Div. 1 NC 308 (Governors Road) between the Lewiston Town Limits
SS-4901 BJ and SR 1134 (Griffins Quarter Road). Initial Spot Safety
construction funds are needed for rumble strip installation and
pavement marking revisions.
File 01-18-53520C
Bertie Co. WBS 48285.3.1
Div. 1 US 13/17 between the Roanoke River Bridge and SR 1521
SS-4901 BK (Cedar Landing Road). Initial Spot Safety construction funds are
needed for widening, rumble strip installation, and pavement
marking revisions.
File 01-18-53585C
Jones Co. WBS 48287.3.1
Div. 2 NC 41 at SR 1002 (Wyse Fork Road/Ten Mile Fork Road).
SS-4902CY Initial Spot Safety construction funds are needed for actuated
flasher installation and Stop Sign upgrades.
File 02-18-53676C
Kinston/ WBS 48286.3.1
Lenoir Co. US 70 Bus./258 Bus. (Vernon Avenue) at SR 1570
Div.2 (College Street); US 70 Bus./258 Bus. (Vernon
SS-4902CX Carey Road; and US 70 Bus./258 Bus. (Vernon
Greenbrier Road. Initial Spot Safety construction
needed for traffic signal revisions.
File 02-18-52800C
Avenue) at
Avenue) at
funds are
Greenville/ WBS 48288.3.1
Pitt Co. US 264 (Greenville Boulevard) at SR 1523 (Whichard Road).
Div. 2 Initial Spot Safety construction funds are needed for offset right
SS-4902CZ turn lane construction.
File 02-18-51509C
$38,000.00
$400,000.00
$35,000.00
$150,000.00
$135,000.00
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Spot Safety Improvement Projects
and for Specific Spot Mobility Projects
L-2
According to Executive Order No. 2 and G.S. 143B-350(g) the Board is requested to
concur with staff recommendations and delegate authority to the Secretary to approve
Funds for Specific Spot Safety and Spot Mobility Improvement Projects
Town/ Project Estimated
County Description Cost
Division
PROJ.
CATEGORY
Pitt Co. WBS 48289.3.1
Div. 2 US 264 Alternate at SR 1139 (Moye-Turnage Road).
SS-4902DA Initial Spot Safety construction funds are needed for intersection
improvements.
File 02-18-51660C
Greenville/ WBS 48445.3.1
Pitt Co. SR 1707 (Charles Boulevard) 630' south of SR 1703
Div. 2 (14th Street). Initial Spot Safety construction funds are needed
SS-4902DB for Rectangular Rapid Flashing Beacons installation at existing
crosswalk.
File 02-18-54508C
Brunswick Co. WBS 48295.3.1
Div. 3 NC 904 (Seaside Road) and NC 179/SR 1163
SS-4903DX (Old Georgetown Road). Initial Spot Safety construction funds
are needed for traffic signal revisions.
File 03-18-48386C
Brunswick Co. WBS 48297.3.1
Div. 3 SR 1115 (Stone Chimney Road/Old Ferry Connection) and
SS-4903DZ SR 1119 (Stanley Road). Initial Spot Safety construction funds
are needed for Stop Sign upgrades.
File 03-18-53711 C
New Hanover WBS 48290.3.1
Co. US 17 Business (3rd Street) at Castle Street. Initial Spot Safety
Div. 3 construction funds are needed for traffic signal revisions and
SS-4903DU High Visibility Crosswalk installation.
File 03-18-48960C
$253,000.00
$30,000.00
$16,000.00
$5,000.00
$133,000.00
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Spot Safety Improvement Projects
and for Specific Spot Mobility Projects
L-3
According to Executive Order No. 2 and G.S. 143B-350(g) the Board is requested to
concur with staff recommendations and delegate authority to the Secretary to approve
Funds for Specific Spot Safety and Spot Mobility Improvement Projects
Town/ Project Estimated
County Description Cost
Division
PROJ.
CATEGORY
Wilmington/ WBS 48294.3.1
New Hanover US 17-76 (Dawson Street) and US 421 (3rd Street).
Co. Initial Spot Safety construction funds are needed for traffic
Div. 3 signal revisions.
SS-4903DW File 03-18-52326C
Sampson Co. WBS 48291.3.1
Div.3 US 13 at SR 1472 (Wrench Road). Initial Spot Safety
SS-4903DV construction funds are needed for actuated flashing beacon
installation.
File 03-18-53721 C
Sampson Co. WBS 48296.2.1
Div. 3 SR 1918 (Matthis Road) at SR 1919 (Old Warsaw Road).
SS-4903DY Initial Spot Safety right of way and utilities funds are needed for
actuated flasher installation with warning signs and sight
distance improvements.
File 03-17-47761 R
Sampson Co. WBS 48296.3.1
Div. 3 SR 1918 (Matthis Road) at SR 1919 (Old Warsaw Road).
SS-4903DY Initial Spot Safety construction funds are needed for actuated
flasher installation with warning signs and sight distance
improvements.
File 03-17-47761 C
Clayton/ WBS 48441.3.1
Johnston Co. US 70 Business at SR 1553 (Shotwell Road).
Div. 4 Initial Spot Mobility construction funds are needed for right turn
SM-5704B lane construction.
File 04-18-52127C
$12,000.00
$77,000.00
$36,000.00
$92,000.00
$229,000.00
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Spot Safety Improvement Projects
and for Specific Spot Mobility Projects
L-4
According to Executive Order No. 2 and G.S. 143B-350(g) the Board is requested to
concur with staff recommendations and delegate authority to the Secretary to approve
Funds for Specific Spot Safety and Spot Mobility Improvement Projects
Town/ Project Estimated
County Description Cost
Division
PROJ.
CATEGORY
Clayton/ WBS 48441.1.1
Johnston Co. US 70 Business at SR 1553 (Shotwell Road).
Div. 4 Initial Spot Mobility preliminary engineering funds are needed
SM-5704B for right turn lane construction.
File 04-18-52127P
Clayton/ WBS 48441.2.1
Johnston Co. US 70 Business at SR 1553 (Shotwell Road).
Div. 4 Initial Spot Mobility right of way and utilities funds are needed
SM-5704B for right turn lane construction.
File 04-18-52127R
Johnston Co. WBS 48298.3.1
Div. 4 SR 1934 (Old Beulah Road) at SR 2127/2149 (Shoeheel Road).
SS-4904ES Initial Spot Safety construction funds are needed for Stop Ahead
sign and pavement marking installation, and channelization
island installation.
File 04-18-53496C
Johnston Co. WBS 48299.3.1
Div. 4 SR 1700 (Covered Bridge Road) at SR 1720
SS-4904ET (Applewhite Road/Thanksgiving Fire Road). Initial Spot Safety
construction funds are needed for All-Way Stop installation.
File 04-18-53494C
Nash Co. WBS 48300.3.1
Div.4 NC 58 at NC 97. Initial Spot Safety construction funds are
SS-4904EU needed for left turn lane construction and traffic signal revisions.
File 04-18-52619C
$50,000.00
$471,000.00
$2,500.00
$35,000.00
$145,000.00
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Spot Safety Improvement Projects
and for Specific Spot Mobility Projects
L-5
According to Executive Order No. 2 and G.S. 143B-350(g) the Board is requested to
concur with staff recommendations and delegate authority to the Secretary to approve
Funds for Specific Spot Safety and Spot Mobility Improvement Projects
Town/ Project Estimated
County Description Cost
Division
PROJ.
CATEGORY
Nash Co. WBS 48300.2.1
Div.4 NC 58 at NC 97. Initial Spot Safety construction funds are
SS-4904EU needed for left turn lane right of way and utilities and traffic
signal revisions.
File 04-18-52619R
Durham/ WBS 48301.3.1
Durham Co. NC 55 (Apex Highway) at I-40 Eastbound Exit Ramp
Div.5 (Exit 278)/Park Forty Plaza. Initial Spot Safety construction
SS-4905FM funds are needed for traffic signal revisions.
File 05-18-53851 C
Vance Co. WBS 48302.3.1
Div. 5 SR 1501 (Allison Cooper Road) at Fishing Creek Bridge.
SS-4905FN Initial Spot Safety construction funds are needed for bridge
guardrail installation.
File 05-18-53853C
Wake Co. WBS 48442.1.1
Div.5 NC 50 at SR 2711 (Buffaloe Road). Initial Spot Mobility
SM-5705U preliminary engineering funds are needed for traffic signal
installation.
File 05-18-53889P
Wake Co. WBS 48442.3.1
Div.5 NC 50 at SR 2711 (Buffaloe Road). Initial Spot Mobility
SM-5705U construction funds are needed for traffic signal installation.
File 05-18-53889C
$40, 000.00
$25,000.00
$25,000.00
$5,000.00
$75,000.00
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Spot Safety Improvement Projects
and for Specific Spot Mobility Projects
L-6
According to Executive Order No. 2 and G.S. 143B-350(g) the Board is requested to
concur with staff recommendations and delegate authority to the Secretary to approve
Funds for Specific Spot Safety and Spot Mobility Improvement Projects
Town/ Project Estimated
County Description Cost
Division
PROJ.
CATEGORY
Angier/ WBS 48303.2.1
Harnett Co. NC 55 (Raleigh Street) at SR 1441 (W. Williams Street).
Div. 6 Initial Spot Safety right of way and utilities funds are needed for
SS-4906DX concrete island installation.
File 06-18-52382R
Angier/ WBS 48303.3.1
Harnett Co. NC 55 (Raleigh Street) at SR 1441 (W. Williams Street).
Div. 6 Initial Spot Safety construction funds are needed for concrete
SS-4906DX island installation.
File 06-18-52382C
Alamance Co. WBS 48306.3.1
Div. 7 NC 62 at SR 2029/SR 2030. Initial Spot Safety construction
SS-4907CK funds are needed for All-Way Stop installation and overhead
flasher revisions.
File 07-18-863C
Greensboro/ WBS 48304.3.1
Guilford Co. US 29 at Lakeview Memorial Park Cemetery Entrance.
Div. 7 Initial Spot Safety construction funds are needed for directional
SS-4907C1 crossover construction.
File 07-18-835C
Guilford Co. WBS 48305.3.1
Div. 7 SR 2819 (McLeansville Road) and bridge 4000156 over
SS-4907CJ Reedy Fork Creek. Initial Spot Safety construction funds are
needed for bridge guardrail installation.
File 07-18-839C
$10, 000.00
$64,500.00
$110, 000.00
$300,000.00
$41,000.00
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Spot Safety Improvement Projects
and for Specific Spot Mobility Projects
L-7
According to Executive Order No. 2 and G.S. 143B-350(g) the Board is requested to
concur with staff recommendations and delegate authority to the Secretary to approve
Funds for Specific Spot Safety and Spot Mobility Improvement Projects
Town/ Project Estimated
County Description Cost
Division
PROJ.
CATEGORY
Moore Co. WBS 48307.3.1 $10,000.00
Div. 8 SR 1803 (Vass Carthage Road) at SR 1802 (Niagara Carthage
SS-4908BZ Road). Initial Spot Safety construction funds are needed for All-
Way Stop installation.
File 08-18-51364C
Davidson Co. WBS 48309.3.1
Div. 9 SR 1232 (Odell Owen Road) approximately 441 feet north of
SS-4909CG SR 1230. Initial Spot Safety construction funds are needed for
guardrail installation.
File 09-18-861 C
Davidson Co. WBS 48311.2.1
Div. 9 SR 2097 (Mount Zion Church Road) at SR 2183 (Denton Road).
SS-4909C1 Initial Spot Safety right of way and utilities funds are needed for
post mounted Vehicle Entering when Flashing sign and flasher
installation.
File 09-18-921 R
Davidson Co. WBS 48311.3.1
Div. 9 SR 2097 (Mount Zion Church Road) at SR 2183 (Denton Road).
SS-4909C1 Initial Spot Safety construction funds are needed for post
mounted Vehicle Entering when Flashing sign and flasher
installation.
File 09-18-921 C
Winston- WBS 48443.3.1
Salem/ SR 3210 (Transou Road) at SR 1525 (Yadkinville Road).
Forsyth Co. Initial Spot Mobility construction funds are needed for right turn
Div. 9 lane construction and traffic signal revisions.
SM-5709E File 09-18-534C
$26,000.00
$26,000.00
$60,000.00
$245,000.00
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Spot Safety Improvement Projects
and for Specific Spot Mobility Projects
L-8
According to Executive Order No. 2 and G.S. 143B-350(g) the Board is requested to
concur with staff recommendations and delegate authority to the Secretary to approve
Funds for Specific Spot Safety and Spot Mobility Improvement Projects
Town/ Project Estimated
County Description Cost
Division
PROJ.
CATEGORY
Winston- WBS 48443.1.1
Salem/ SR 3210 (Transou Road) at SR 1525 (Yadkinville Road).
Forsyth Co. Initial Spot Mobility preliminary engineering funds are needed
Div. 9 for right turn lane construction and traffic signal revisions.
SM-5709E File 09-18-534P
Winston- WBS 48443.2.1
Salem/ SR 3210 (Transou Road) at SR 1525 (Yadkinville Road).
Forsyth Co. Initial Spot Mobility right of way and utilities funds are needed
Div. 9 for right turn lane construction and traffic signal revisions.
SM-5709E File 09-18-534R
Kernersville/ WBS 48310.3.1
Forsyth Co. SR 2643 (Union Cross Road) at SR 2640
Div. 9 (Shields RoadNVhicker Road). Initial Spot Safety construction
SS-4909CH funds are needed for traffic signal revisions.
File 09-18-3897C
Kernersville/ WBS 48310.2.1
Forsyth Co. SR 2643 (Union Cross Road) at SR 2640
Div. 9 (Shields Road/Whicker Road). Initial Spot Safety right of way
SS-4909CH and utilities funds are needed for traffic signal revisions
File 09-18-3897R
Rowan Co. WBS 48308.3.1
Div. 9 SR 1503 (Grace Church Road) at SR 1506 (Shue Road).
SS-4909CF Initial Spot Safety construction funds are needed for post
mounted Vehicle Entering when Flashing sign and flasher
installation.
File 09-18-870C
$30,000.00
$75,000.00
$45,000.00
$65,000.00
$60,000.00
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Spot Safety Improvement Projects
and for Specific Spot Mobility Projects
L-9
According to Executive Order No. 2 and G.S. 143B-350(g) the Board is requested to
concur with staff recommendations and delegate authority to the Secretary to approve
Funds for Specific Spot Safety and Spot Mobility Improvement Projects
Town/ Project Estimated
County Description Cost
Division
PROJ.
CATEGORY
Rowan Co. WBS 48308.2.1
Div. 9 SR 1503 (Grace Church Road) at SR 1506 (Shue Road).
SS-4909CF Initial Spot Safety right of way and utilities funds are needed for
post mounted Vehicle Entering when Flashing sign and flasher
installation.
File 09-18-870R
Pineville/ WBS 47843.3.1
Matthews/ US 74 signal system between US 601 (South) and Fowlers
Monroe/ Secrest Road/Williams Road; NC 51, Polk Street, Carolina
Mecklenburg/ Place Parkway and Park Road (Pineville signal system); and
Union Cos. John Street, NC 51 and US 74 corridors (Matthews signal
Div. 10 system). $580,000.00 in Spot Mobility construction funds has
SM-5710D previously been approved for traffic signal system
improvements. Additional funds are needed due to scope
change. Scope needs to be revised to include additional traffic
signal system improvements on numerous routes in Division 10.
File 10-17-242-2
Pineville/ WBS 47843.1.1
Matthews/ US 74 signal system between US 601 (South) and Fowlers
Monroe/ Secrest Road/Williams Road; NC 51, Polk Street, Carolina
Mecklenburg/ Place Parkway and Park Road (Pineville signal system); and
Union Cos. John Street, NC 51 and US 74 corridors (Matthews signal
Div. 10 system). $120,000 in Spot Mobility preliminary engineering
SM-5710D funds has previously been approved for traffic signal system
improvements. $120,000.00 in Spot Mobility preliminary
engineering funds has previously been approved for traffic
signal system improvements. All funds will not be needed,
therefore, reduce funds.
File 10-17-242-1
Gastonia/ WBS 48314.3.1
Gaston Co. SR 2329 (Redbud Drive)/ SR 2446 (Hoffman Road) at SR 1255
Div. 12 (E. Hudson Boulevard). Initial Spot Safety construction funds
SS-4912CV are needed for Be Prepared to Stop warning signs and flashers
installation, radius revisions, and pavement marking upgrades.
File 12-18-223C
$26,000.00
$50,000.00
-$50,000.00
$197,000.00
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Spot Safety Improvement Projects
and for Specific Spot Mobility Projects
L-10
According to Executive Order No. 2 and G.S. 143B-350(g) the Board is requested to
concur with staff recommendations and delegate authority to the Secretary to approve
Funds for Specific Spot Safety and Spot Mobility Improvement Projects
Town/ Project Estimated
County Description Cost
Division
PROJ.
CATEGORY
Gastonia/ WBS 48314.2.1
Gaston Co. SR 2329 (Redbud Drive)/ SR 2446 (Hoffman Road) at SR 1255
Div. 12 (E. Hudson Boulevard). Initial Spot Safety right of way and
SS-4912CV utilities funds are needed for Be Prepared to Stop warning signs
and flashers installation, radius revisions, and pavement
marking upgrades.
File 12-18-223R
Mooresville/ WBS 48313.3.1
Iredell Co. NC 150 at SR 1164/SR 2397
Div. 12 Drive/Overhead Bridge Road).
SS-4912CU funds are needed for advance
signs and beacons installation.
File 12-18-224C
(Oakridge Farm Hwy at Selma
Initial Spot Safety construction
Vehicle When Entering flashing
Mooresville/ WBS 48313.2.1
Iredell Co. NC 150 at SR 1164/SR 2397 (Oakridge Farm Hwy at Selma
Div. 12 Drive/Overhead Bridge Road). Initial Spot Safety right of way
SS-4912CU and utilities funds are needed for advance Vehicle When
Entering flashing signs and beacons installation.
File 12-18-224R
Lincoln Co
Div. 12
SM-5712E
WBS 48444.3.1
NC 73 and NC 16
funds are needed
signal revisions.
File 12-18-219C
Business. Initial Spot Mobility construction
for intersection improvements and traffic
Lincoln Co. WBS 48444.1.1
Div. 12 NC 73 and NC 16 Business. Initial Spot Mobility preliminary
SM-5712E engineering funds are needed for intersection improvements
and traffic signal revisions.
File 12-18-219P
$3,000.00
$21,000.00
$1,000.00
$150,000.00
$60,000.00
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Spot Safety Improvement Projects
and for Specific Spot Mobility Projects
n Clay County to
right of way and
rumblestrips, and
According to Executive Order No. 2 and G.S. 143B-350(g) the Board is requested to
concur with staff recommendations and delegate authority to the Secretary to approve
Funds for Specific Spot Safety and Spot Mobility Improvement Projects
Town/ Project Estimated
County Description Cost
Division
PROJ.
CATEGORY
Burke Co. WBS 48315.3.1
Div. 13 NC 126 from SR 1308 to SR 1281, near Nebo.
SS-4913CW Initial Spot Safety construction funds are needed for guardrail
installation.
File 13-18-215C
Burke Co. WBS 48315.2.1
Div. 13 NC 126 from SR 1308 to SR 1281, near Nebo.
SS-4913CW Initial Spot Safety right of way and utilities funds are needed for
guardrail installation.
File 13-18-215R
Clay/ WBS 48316.3.1
Macon Cos. US 64 from SR 1349 (western intersection) in Clay County to
Div. 14 0.1 mile west of SR 1448. Initial Spot Safety construction funds
SS-4914D0 are needed for rumblestripes, rumblestrips, and long life
pavement marking installation.
File 14-18-210C
Clay/ WBS 48316.2.1
Macon Cos. US 64 from SR 1349 (western intersection) i
Div. 14 0.1 mile west of SR 1448. Initial Spot Safety
SS-4914D0 utilities funds are needed for rumblestripes,
long life pavement marking installation.
File 14-18-210R
ITEM L SUMMARY
53 PROJECTS
L-11
$35,000.00
$1,000.00
$280,000.00
$2,000.00
$4,458,000.00
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Federal - Aid Projects
Division 1
Enhancement
Town/
County/PROJ
CATEGORY
Northampton
Co.
E R-5600AA
STATEWIDE
Project
Description
46305.3.58, STP-0095(055)
I-95 Northampton Welcome Center. Funds are needed for
landscape renovations.
Urban
Pasquotank
Co.
U-5942
REGIONAL
45861.2.1, STBG-0111(025)
Elizabeth City Signal System Upgrades. Funds are needed
for utilities.
Bridge
Martin Co. 55003.3.3, BRSTP-0125(006)
B-5503 Replace Bridge #53 over Collie Creek on SR 1142 (Prison
DIVISION Camp Road). Funds are needed for construction to replace
bridge.
Rural
Martin Co. 38932.2.2, STP-1142(011)
R-4705 SR 1142 (Prison Camp Road) from NC 903 to SR 1182
DIVISION (East College Road). Funds are needed for full right of way
and utilities.
December 6, 2018
M-1
Estimated
Cost
$470,000.00 Cost
$376,000.00 Fed.
$94,000.00 State
$80,000.00 Cost
$64,000.00 Fed.
$16,000.00 State
$2,050,000.00 Cost
$1,640,000.00 Fed.
$410,000.00 State
$5,500,000.00 Cost
$4,400,000.00 Fed.
$1,100,000.00 State
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Federal - Aid Projects
Division 2
Bridge
Town/
County/PROJ
CATEGORY
Pitt Co.
B-4605
DIVISION
Project
Description
38430.2.1, BRZ-1777(007)
Replace Bridge #5 over Chicod Creek on SR 1777. Funds
are needed for full right of way and utilities.
December 6, 2018
M-2
Estimated
Cost
$10,000.00 Cost
$8,000.00 Fed.
$2,000.00 State
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Federal - Aid Projects
Division 3
Urban
Town/ Project
County/PROJ Description
CATEGORY
New Hanover 34932.1.4, STP-1175(011)
Co. SR 1175 (Kerr Avenue) at the US 74 (Martin Luther King, Jr.
U-3338C Parkway) interchange in Wilmington. $1,000,000.00 has
REGIONAL previously been approved for preliminary engineering.
Additional funds are needed as requested.
New Hanover 50113.1.2, NHP-0132(011)
Co. NC 132 (College Road) from SR 1272 (New Centre Drive) to
U-5702A US 117 (Shipyard Boulevard) in Wilmington. $1,000,000.00
STATEWIDE has previously been approved for preliminary engineering.
Additional funds are needed as requested.
New Hanover 50114.1.FS1, NHPP-0076(012)
Co. NC 132 (College Road) at US 76 (Oleander Drive) in
U-5704 Wilmington. $800,000.00 has previously been approved for
STATEWIDE preliminary engineering. Additional funds are needed as
requested.
New Hanover 50115.1.FS1, NHPP-0074(159)
Co. US 74 (Eastwood Road) at SR 1409 (Military Cuttoff Road).
U-5710 $1,700,000.00 has previously been approved for preliminary
STATEWIDE engineering. Additional funds are needed as requested.
Bridge
Brunswick Co. 45584.1.1, BRZ-1515(011)
B-5629 Replace Bridge #40 over Mills Creek on SR 1515.
DIVISION $100,000.00 has previously been approved for preliminary
engineering. Additional funds are needed as requested.
Duplin Co. 45587.1.2, BRZ-1828(001)
B-5632 Replace Bridge #187 over Back Swamp on SR 1828. Funds
DIVISION are needed for preliminary engineering.
M-3
Estimated
Cost
$750,000.00 Cost
$600,000.00 Fed.
$150,000.00 State
$200,000.00 Cost
$160,000.00 Fed.
$40,000.00 State
$300,000.00 Cost
$240,000.00 Fed.
$60,000.00 State
$1,000,000.00 Cost
$800,000.00 Fed.
$200,000.00 State
$100,000.00 Cost
$80,000.00 Fed.
$20,000.00 State
$100,000.00 Cost
$80,000.00 Fed.
$20,000.00 State
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Federal - Aid Projects
Division 3 (Continued)
Bridge
Town/
County/PROJ
CATEGORY
Duplin Co
B-5647
DIVISION
Project
Description
45602.1.2, BRZ-1135(011)
Replace Bridge #52 over Rock Fish Creek on SR 1135.
Funds are needed for preliminary engineering.
Sampson Co. 46024.1.2, BRZ-1817(001)
B-5310 Replace Bridge #188 over Ward Swamp on SR 1817. Funds
DIVISION are needed for preliminary engineering.
Safety
Onslow Co. 50139.3.1, HSIP-0172(013)
W-5602 NC 172 from the Camp Lejeune gate to NC 210. Funds are
REGIONAL needed for construction based on the estimate from the 12-
Month Tentative Letting List published October 12, 2018.
Rural
Brunswick Co. 41582.1.1, STP-0211(021)
R-5021 NC 211 from SR 1500 (Midway Road) to NC 87.
DIVISION $8,000,000.00 has previously been approved for preliminary
engineering. Additional funds are needed as requested.
M-4
Estimated
Cost
$100,000.00 Cost
$80,000.00 Fed.
$20,000.00 State
$100,000.00 Cost
$80,000.00 Fed.
$20,000.00 State
$10,631,958.00 Cost
$8,785,566.00 Fed.
$1,846,392.00 State
$2,500,000.00 Cost
$2,000,000.00 Fed.
$500,000.00 State
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Federal - Aid Projects
Division 4
Bridge
Town/ Project
County/PROJ Description
CATEGORY
Wilson Co. 48193.2.1, BRZ-1339(006)
B-5998 Replace Bridge #92 over Town Swamp on SR 1339. Funds
DIVISION are needed for full right of way and utilities.
Safety
Halifax Co. 44850.3.13, HSIP-0043(030)
W-5704M NC 43 / NC 561 at SR 1329 (Evans Road) and SR 1333
REGIONAL (Lynch Road). Funds are needed for construction to install
all-way stop.
M-5
Estimated
Cost
$53,000.00 Cost
$42,400.00 Fed.
$10,600.00 State
$15,000.00 Cost
$13,500.00 Fed.
$1,500.00 State
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Federal - Aid Projects
Division 5
Interstate
Town/ Project
County/PROJ Description
CATEGORY
Wake Co. 46307.1.1, NHP-0440(023)
I-5870 I-440 / US 1 Improvement project from west of Ridge Road
STATEWIDE to east of US 70 (Glenwood Avenue) in Raleigh.
$2,000,000.00 has previously been approved for preliminary
engineering. Additional funds are needed as requested.
Wake Co. 53074.3.1, NHP-0040(084)
I-5873 I-40 at the NC 54 interchange in Raleigh. Funds are needed
REGIONAL for construction to improve interchange.
Congestion Mitigation
Wake Co. 43714.1.16, CMAQ-0503(035)
C-56041D Higgins Greenway Phase 3, approximately 0.8 miles of
EXEMPT greenway toward downtown Cary. Funds are needed for
preliminary engineering.
Wake Co. 43714.3.4, CMAQ-0520(056)
C-56040B Raleigh Bike Share System. $1,381,682.00 has previously
EXEMPT been approved for construction. Additional funds are needed
for the installation of bike racks and equipment.
M-6
Estimated
Cost
$1,000,000.00 Cost
$800,000.00 Fed.
$200,000.00 State
$4,100,000.00 Cost
$3,280,000.00 Fed.
$820,000.00 State
$15,000.00 Cost
$10,500.00 Fed.
$4,500.00 Local
$97,388.00 Cost
$77,910.00 Fed.
$19,478.00 Local
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Federal - Aid Projects
Division 5 (Continued)
Urban
Town/ Project
County/PROJ Description
CATEGORY
Wake Co. 44796.3.2, STPDA-2768(003)
U-5927A North Judd Parkway - SR 2768 / SR 5056 (North Judd
DIVISION Parkway North East) from SR 3736 (Old Honeycutt Road) to
SR 5056 and SR 1402 (East Broad Street). $1,686,300.00
has previously been approved for construction. Additional
funds are needed per the supplemental local agreement to
widen roadway to multi-lanes.
Wake Co. 47899.1.1, STPDA-0520(121)
U-6094 SR 1152 (Holly Springs Road) from east of NC 55 to Flint
DIVISION Point Lane in Holly Springs. Funds are needed for
preliminary engineering.
Safety
Divisionwide 44851.1.26, HSIP-OOSS(023)
W-5705Z Upgrade guardrail end units along various Interstate and
STATEWIDE National Highway System routes in Highway Division 5.
Funds are needed for preliminary engineering.
Wake Co. 44851.1.25, HSIP-1313(007)
W-5705Y SR 1313 (Walnut Street) at SR 1349 (Dillard Drive) in Cary
DIVISION Funds are needed for preliminary engineering.
Municipal Bridge
Wake Co. 50148.3.1, BRSTP-0520(053)
B-5556 Replace Bridge #490 over Walnut Creek on Lake Dam Road
DIVISION in Raleigh. $1,307,240.00 has previously been approved for
construction. Additional funds are needed as requested to
replace bridge.
M-7
Estimated
Cost
$2,276,000.00 Cost
$1,138,000.00 Fed.
$138,000.00 State
$1,000,000.00 Local
$25,000.00 Cost
$20,000.00 Fed.
$5,000.00 Local
$5,000.00 Cost
$4,500.00 Fed.
$500.00 State
$25,000.00 Cost
$22,500.00 Fed.
$2,500.00 State
$360,000.00 Cost
$288,000.00 Fed.
$72,000.00 Local
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Federal - Aid Projects
Division 5 (Continued)
Rural
Town/ Project
County/PROJ Description
CATEGORY
Wake Co. 37673.1.TA2, STP-0540(019)
R-2721 Future NC 540 - Southern Wake Freeway / Triangle
STATEWIDE Expressway Southeast Extension (Raleigh Outer Loop) from
NC 55 South to US 401 South. $3,566,964.00 has
previously been approved for preliminary engineering.
Additional funds are needed to cover expenditures that have
or will exceed the previously authorized budget.
Wake Co. 35516.1.TA1, STP-0540(027)
R-2828 Future NC 540 - Southern Wake Freeway / Triangle
STATEWIDE Expressway Southeast Extension (Raleigh Outer Loop) from
US 401 to I-40. $2,643,283.00 has previously been
approved for preliminary engineering. Additional funds are
needed as requested.
Wake Co. 35516.1.TA2, STP-0540(020)
R-2828 Future NC 540 - Southern Wake Freeway / Triangle
STATEWIDE Expressway Southeast Extension (Raleigh Outer Loop) from
US 401 to I-40. $7,735,734.00 has previously been
approved for preliminary engineering. Additional funds are
needed to cover expenditures that have or will exceed the
previously authorized budget.
Wake Co. 35517.1.TA1, STP-0540(021)
R-2829 Future NC 540 - Eastern Wake Freeway / Triangle
STATEWIDE Expressway Southeast Extension (Raleigh Outer Loop) from
I-40 to the US 64 / US 264 Bypass south of Garner.
$7,346,062.00 has previously been approved for preliminary
engineering. Additional funds are needed as requested.
M-8
Estimated
Cost
$7,200,560.00 Cost
$5,760,448.00 Fed.
$1,440,112.00 State
$2,000,000.00 Cost
$1,600,000.00 Fed.
$400,000.00 State
$2,983,568.00 Cost
$2,386,854.00 Fed.
$596,714.00 State
$2,000,000.00 Cost
$1,600,000.00 Fed.
$400,000.00 State
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Federal - Aid Projects
Division 5 (Continued)
Bicycle and Pedestrian
Town/ Project
County/PROJ Description
CATEGORY
Wake Co. 47291.1.1, TAP-0505(094)
EB-5894 Black Creek Greenway Phases I, II and V from West
DIVISION Dynasty Drive to Old Reedy Creek Road in Cary. $4,000.00
has previously been approved for preliminary engineering.
Additional funds are needed as requested.
Wake Co. 44111.3.15, STPDA-0505(085)
U-55300A Sidewalk Overpass Project along SR 1348 (Trailwood Drive)
DIVISION to fill sidewalk gaps between Thistledown Drive / SR 1572
(Main Campus Drive) and Canine Tech Way / SR 1355
(Lineberry Drive) and across I-40. $595,200.00 has
previously been approved for construction. Additional funds
are needed as requested to install sidewalks.
M-9
Estimated
Cost
$5,000.00 Cost
$4,000.00 Fed.
$1,000.00 Local
$528,000.00 Cost
$264,000.00 Fed.
$264,000.00 Local
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Federal - Aid Projects
Division 6
Safety
Town/ Project
County/PROJ Description
CATEGORY
Cumberland 50138.3.171, HSIP-1108(019)
Co. SR 1108 (Lakewood Drive) at SR 3670 (Middleton Court)
W-5601 FN and SR 3671 (Lullwater Drive). Funds are needed for
DIVISION construction to widen turn lanes.
Rail Program
Robeson Co. 44803.1.26, RR-1006(050)
Z-5700FD Railway-Highway Grade Crossing Safety Project at SR 1006
DIVISION (Morgan J Road / Great Marsh Church Road) and CSX
Crossing 629 584M in Rennert. $20,000.00 has previously
been approved for preliminary engineering. Additional funds
are needed as requested.
M-10
Estimated
Cost
$552,500.00 Cost
$497,250.00 Fed.
$55,250.00 State
$10,000.00 Cost
$9,000.00 Fed.
$1,000.00 State
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Federal - Aid Projects
Division 7
Congestion Mitigation
Town/ Project
County/PROJ Description
CATEGORY
Orange Co. 46289.1.1, CMS-0702(021)
C-5181 Jones Creek Greenway Project to fill gaps between the
EXEMPT Carrboro Upper Bolin Trail and Twin Creeks Greenway, and
to implement a program to support on-vehicle trips to Morris
Grove Elementary School. $80,000.00 has previously been
approved for preliminary engineering. Additional funds are
needed as requested.
Bridge
Caswell Co. 45681.1.2, BRZ-1710(008)
B-5725 Replace Bridge #7 over Hyco Creek on SR 1710. Funds are
DIVISION needed for preliminary engineering.
Guilford Co. 45679.1.2, BRZ-1158(013)
B-5723 Replace Bridge #54 over Richland Creek on SR 1158.
DIVISION Funds are needed for preliminary engineering.
Rail Program
Guilford Co. 44803.1.41, RR-0710(038)
Z-5700GC Railway-Highway Grade Crossing Safety Project at Ogden
DIVISION Street and Norfolk Southern Crossing 713 784A in High
Point. Funds are needed for preliminary engineering.
M-11
Estimated
Cost
$84,000.00 Cost
$67,200.00 Fed.
$16,800.00 Local
$100,000.00 Cost
$80,000.00 Fed.
$20,000.00 State
$100,000.00 Cost
$80,000.00 Fed.
$20,000.00 State
$40,000.00 Cost
$36,000.00 Fed.
$4,000.00 State
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Federal - Aid Projects
Division 7 (Continued)
Bicycle and Pedestrian
Town/ Project
County/PROJ Description
CATEGORY
Alamance Co. 47280.1.1, TAP-0087(042)
EB-5884 NC 87 (South Main Street) from SR 2183 (Ivey Road) to
DIVISION SR 2100 (East Gilbreath Street). Funds are needed for
preliminary engineering.
Orange Co. 50417.1.1, TAP-0708(107)
EB-5721 Orange County Bicycle Route 1- from Cleland Drive to
DIVISION Willow Drive in Chapel Hill. $71,200.00 has previously been
approved for preliminary engineering. Additional funds are
needed as requested.
M-12
Estimated
Cost
$55,200.00 Cost
$44,160.00 Fed.
$11,040.00 Local
$31,000.00 Cost
$24,800.00 Fed.
$6,200.00 Local
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Federal - Aid Projects
Division 9
Congestion Mitigation
Town/ Project
County/PROJ Description
CATEGORY
Rowan Co. 44008.3.10, CMS-0914(022)
C-4908G Salisbury Mall Area Sidewalks - along US 70 (Statesville
EXEMPT Boulevard) and US 601 (Jake Alexander Boulevard). Funds
are needed for construction to install sidewalks.
Safety
Forsyth Co
W-5709H
DIVISION
44855.1.8, HSIP-4000(001)
SR 4000 (University Parkway) at Cherry Street in Winston-
Salem. Funds are needed for preliminary engineering.
Rowan Co. 44855.1.5, HSIP-0153(007)
W-5709E NC 153 (Rice Street) at SR 1197 (Cannon Farm Road) in
REGIONAL China Grove. $100,000.00 has previously been approved for
preliminary engineering. Additional funds are needed as
requested.
M-13
Estimated
Cost
$388,000.00 Cost
$310,400.00 Fed.
$77,600.00 Local
$100,000.00 Cost
$90,000.00 Fed.
$10,000.00 State
$150,000.00 Cost
$135,000.00 Fed.
$15,000.00 State
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Federal - Aid Projects
Division 10
Interstate
Town/ Project
County/PROJ Description
CATEGORY
Mecklenburg 50128.1.FS1, NHPP-077-1(220)29
Co. I-77 at the NC 73 interchange. $500,000.00 has previously
I-5715 been approved for preliminary engineering. Additional funds
STATEWIDE are needed as requested.
Mecklenburg 52024.1.1, NHPP-0277(018)
Co. I-277 / US 74 from I-77 to Brevard Street. $200,000.00 has
I-5746 previously been approved for preliminary engineering.
STATEWIDE Additional funds are needed as requested.
Mecklenburg 50470.3.1, NHPIM-0485(050)
Co. I-485 from Idlewild Road to US 74. $3,300,000.00 has
I-5827 previously been approved for construction. Additional funds
STATEWIDE are needed as requested for pavement rehabilitation.
Congestion Mitigation
Mecklenburg 43735.2.12, CMAQ-1001(082)
Co. Lakeview Road Improvements - SR 2112 (Lakeview Road)
C-5613H at SR 2110 (Reames Road) and along Lakeview Road from
EXEMPT Beatties Ford Road to Reames Road in Charlotte. Funds
are needed for full right of way and utilities.
M-14
Estimated
Cost
$4,000,000.00 Cost
$3,200,000.00 Fed.
$800,000.00 State
$1,900,000.00 Cost
$1,520,000.00 Fed.
$380,000.00 State
$450,000.00 Cost
$360,000.00 Fed.
$90,000.00 State
$2,777,778.00 Cost
$1,000,000.00 Fed.
$1,777,778.00 Local
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Federal - Aid Projects
Division 10 (Continued)
Bridge
Town/ Project
County/PROJ Description
CATEGORY
Union Co. 46091.1.FD1, BRZ-1681(003)
B-5376 Replace Bridge #21 over Stewarts Creek on SR 1681.
DIVISION $100,000.00 has previously been approved for preliminary
engineering. Additional funds are needed as requested.
Union Co. 46092.3.3, BRZ-2170(006)
B-5377 Replace Bridge #157 over Pole Cat Creek on SR 2170
DIVISION Funds are needed for construction to replace bridge.
Safety
Stanly Co. 44856.3.20, HSIP-1494(003)
W-5710T SR 1494 (West Main Street) from US 52 to Railroad Street
DIVISION in Albemarle. Funds are needed for construction to install
pedestrian crossings.
Union Co. 44856.2.11, HSIP-0200(007)
W-5710K NC 200 (Lancaster Highway) and SR 1128 (McWhorter
REGIONAL Road / Tom Starnes Road). Funds are needed for full right
of way and utilities.
Union Co. 44856.2.12, HSIP-0016(062)
W-5710L NC 16 (Providence Road) and Gray Byrum Road near
REGIONAL Waxhaw. Funds are needed for full right of way and utilities.
M-15
Estimated
Cost
$100,000.00 Cost
$80,000.00 Fed.
$20,000.00 State
$675,000.00 Cost
$540,000.00 Fed.
$135,000.00 State
$30,000.00 Cost
$27,000.00 Fed.
$3,000.00 State
$75,000.00 Cost
$67,500.00 Fed.
$7,500.00 State
$100,000.00 Cost
$90,000.00 Fed.
$10,000.00 State
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Federal - Aid Projects
Division 11
Urban
Town/
County/PROJ
CATEGORY
Caldwell Co
U-4700CA
REGIONAL
Project
Description
35993.2.5, NHP-0321(037)
US 321 at SR 1160 (Mount Herman Road). Funds are
needed for full right of way and utilities.
Caldwell Co. 35993.2.9, NHP-0321(046)
U-4700CB US 321 at SR 1809 / 1952 (Pine Mountain Road). Funds are
STATEWIDE needed for full right of way and utilities.
Caldwell Co. 35993.2.10, NHP-0321(045)
U-4700CC US 321 at SR 1108 (Mission Road). Funds are needed for
STATEWIDE full right of way and utilities.
M-16
Estimated
Cost
$420,000.00 Cost
$336,000.00 Fed.
$84,000.00 State
$500,000.00 Cost
$400,000.00 Fed.
$100,000.00 State
$550,000.00 Cost
$440,000.00 Fed.
$110,000.00 State
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Federal - Aid Projects
Division 12
Congestion Mitigation
Town/ Project
County/PROJ Description
CATEGORY
Gaston Co. 43728.1.2, CMAQ-2093(001)
C-5606A Belmont Mount Holly Sidewalk Project - SR 2093 (Belmont
EXEMPT Mount Holly Road) between the existing sidewalks at the
Circle K Gas Station and Margaret Avenue. $22,307.00 has
previously been approved for preliminary engineering.
Additional funds are needed as requested.
Enhancement
Gaston Co.
ER-5600LB
DIVISION
46305.3.55, STBG-0085(049)
I-85 at the US 274 interchange. Funds are needed for
construction for landscaping.
Bridge
Lincoln Co.
B-6042
REGIONAL
48327.1.1, NHPB-0150(047)
Replace Bridge #26 over the Seaboard Air Line Railway on
NC 150. Funds are needed for preliminary engineering.
Safety
Catawba Co. 44858.3.23, HSIP-0040(081)
W-5712W US 321 from the Lincoln-Gaston County Line to I-40 and
STATEWIDE including the I-40 interchange in Catawba County. Funds
are needed for construction to upgrade guardrail end units.
Cleveland Co. 44858.3.16, HSIP-0085(048)
W-5712P I-85 from the South Carolina Line to Exit 17 and also US 74
STATEWIDE from I-85 to Harmon Road. Funds are needed for
construction to upgrade guardrail end units.
M-17
Estimated
Cost
$31,142.00 Cost
$24,602.00 Fed.
$6,540.00 Local
$89,600.00 Cost
$71,680.00 Fed.
$17,920.00 State
$100,000.00 Cost
$80,000.00 Fed.
$20,000.00 State
$250,000.00 Cost
$225,000.00 Fed.
$25,000.00 State
$250,000.00 Cost
$225,000.00 Fed.
$25,000.00 State
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Federal - Aid Projects
Division 13
Interstate
Town/ Project
County/PROJ Description
CATEGORY
Buncombe 36030.1.2, IMNHF-026-1(086)9
Co. I-26 from NC 280 (Exit 40) to I-40 in Asheville.
I-4700 $1,060,000.00 has previously been approved for preliminary
STATEWIDE engineering. Additional funds are needed as requested for
planning and environmental studies.
Buncombe 36030.1.FS4, NHPP-026-1(198)3
Co. I-26 from NC 280 (Exit 40) to NC 146 / Long Shoals Road
I-4700A (Exit 37). $750,000.00 has previously been approved for
STATEWIDE preliminary engineering. Additional funds are needed as
requested.
Buncombe 36030.1.FS3, NHPP-026-1(199)6
Co. I-26 from NC 146 / Long Shoals Road (Exit 37) to I-40.
I-4700B $750,000.00 has previously been approved for preliminary
STATEWIDE engineering. Additional funds are needed as requested.
Burke Co. 41497.2.1, IMF-0401(184)111
I-5008 I-40 at SR 1734 / SR 1826 (Exit 111). Funds are needed for
REGIONAL full right of way and utilities.
Burke Co. 53075.2.1, NHP-0040(045)
I-5874 I-40 at SR 1142 / Jamestown Road (Exit 100). Funds are
REGIONAL needed for full right of way and utilities.
National Highway
Burke Co.
I-5875
REGIONAL
53076.2.1, NHP-0040(046)
I-40 at SR 1712 (Drexel Road). Funds are needed for full
right of way and utilities.
M-18
Estimated
Cost
$4,200,000.00 Cost
$3,360,000.00 Fed.
$840,000.00 State
$1,200,000.00 Cost
$960,000.00 Fed.
$240,000.00 State
$3,500,000.00 Cost
$2,800,000.00 Fed.
$700,000.00 State
$4,595,000.00 Cost
$3,676,000.00 Fed.
$919,000.00 State
$1,740,000.00 Cost
$1,392,000.00 Fed.
$348,000.00 State
$3,620,000.00 Cost
$2,896,000.00 Fed.
$724,000.00 State
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Federal - Aid Projects
Division 13 (Continued)
Safety
Town/ Project
County/PROJ Description
CATEGORY
Rutherford 44861.3.18, HSIP-0221(049)
Co. US 221 Alternate from the South Carolina Line to SR 2018
W-5713R (Old Main Street) near Cliffside. Funds are needed for
REGIONAL construction to install guardrails.
Bicycle and Pedestrian
Burke Co. 45972.1.1, STBGDA-OOOS(916)
EB-5827 Fonta Flora Trail Extension - from Laurel Ridge Court and
DIVISION North Powerhouse Road to the proposed Trailhead at Harris
Whisnant Road and Cobb Road in Burke County. Funds are
needed for preliminary engineering.
M-19
Estimated
Cost
$785,000.00 Cost
$706,500.00 Fed.
$78,500.00 State
$300,000.00 Cost
$240,000.00 Fed.
$60,000.00 Local
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Federal - Aid Projects
Division 14
Interstate
Town/ Project
County/PROJ Description
CATEGORY
Henderson 34232.1.1, NHF-26-1(62)23
Co. I-26 from NC 225 (US 25 Connector) to NC 280.
I-4400 $8,583,193.54 has previously been approved for preliminary
STATEWIDE engineering. Additional funds are needed as requested for
planning and environmental studies.
Henderson 34232.1.5, NHP-0026(016)
Co. I-26 at the US 64 (Exit 49) interchange. $1,000,000.00 has
I-4400BA previously been approved for preliminary engineering.
STATEWIDE Additional funds are needed as requested.
Henderson 34232.1.FS4, NHPP-026-1(200)13
Co. I-26 from US 25 Business (Exit 44) to NC 280 (Exit 40).
I-4400C $750,000.00 has previously been approved for preliminary
REGIONAL engineering. Additional funds are needed as requested.
Enhancement
Cherokee Co. 46305.3.57, STBG-0074(219)
ER-5600NB US 74 Site Development in Murphy. Funds are needed for
REGIONAL construction for landscaping.
Urban
Haywood Co. 47166.3.1, STBGDA-0110(013)
U-6055 NC 110 (Pisgah Drive) at Locust Street. Funds are needed
EXEMPT for construction to improve intersection.
Haywood Co. 47166.2.1, STBGDA-0110(013)
U-6055 NC 110 (Pisgah Drive) at Locust Street.
EXEMPT previously been approved for right of
Additional funds are needed as requested.
$221,000.00 has
way and utilities.
M-20
Estimated
Cost
$4,000,000.00 Cost
$3,200,000.00 Fed.
$800,000.00 State
$1,800,000.00 Cost
$1,440,000.00 Fed.
$360,000.00 State
$2,200,000.00 Cost
$1,760,000.00 Fed.
$440,000.00 State
$320,000.00 Cost
$256,000.00 Fed.
$64,000.00 State
$800,000.00 Cost
$640,000.00 Fed.
$160,000.00 State
$550,000.00 Cost
$440,000.00 Fed.
$110,000.00 State
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Federal - Aid Projects
Division 14 (Continued)
Rural
Town/ Project
County/PROJ Description
CATEGORY
Cherokee Co. 44999.1.1, NHP-0074(196)
R-5803 US 74 at the end of the divided highway in Cherokee County
REGIONAL to the beginning of the divided highway in Almond.
$545,000.00 has previously been approved for preliminary
engineering. Additional funds are needed as requested.
Divisionwide 44910.3.5, TAP-1420(009)
R-5794C ADA ramps (Americans with Disabilities Act) for areas with a
DIVISION population < 5,000. $735,000.00 has previously been
approved for construction. Additional funds are needed as
requested to construct concrete curb ramps and retrofitting
existing ramps.
Henderson 34473.1.3, STP-0191(014)
Co. NC 191 from SR 1381 (Mountain Road) to NC 280 just
R-2588B south of Mills River. $1,560,000.00 has previously been
DIVISION approved for preliminary engineering. Additional funds are
needed as requested.
Jackson Co. 45818.1.FR1, STP-0107(013)
R-5600 NC 107 from NC 116 to US 23 Business and US 23
REGIONAL Business from SR 1432 (Skyland Drive) to Municipal Drive
in Sylva. $2,550,000.00 has previously been approved for
preliminary engineering. Additional funds are needed as
requested.
Swain Co. 32572.1.FS10, APD-0074(178)
A-0009 Future US 74 Corridor "K" from US 19 / US 74 / US 129 in
EXEMPT Andrews to NC 28 east of Almond. $500,000.00 has
previously been approved for preliminary engineering.
Additional funds are needed as requested.
Bicycle and Pedestrian
Haywood Co. 47631.1.1, STBGDA-0019(060)
EB-5926 US 19 (Soco Road) from US 276 to Fie Top Road in Maggie
DIVISION Valley. Funds are needed for preliminary engineering.
M-21
Estimated
Cost
$900,000.00 Cost
$720,000.00 Fed.
$180,000.00 State
$170,000.00 Cost
$136,000.00 Fed.
$34,000.00 State
$2,000,000.00 Cost
$1,600,000.00 Fed.
$400,000.00 State
$150,000.00 Cost
$120,000.00 Fed.
$30,000.00 State
$450,000.00 Cost
$450,000.00 Fed.
$175,000.00 Cost
$140,000.00 Fed.
$35,000.00 Local
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Funds for Specific Federal - Aid Projects
Statewide
Rail Program
M-22
Town/ Project Estimated
County/PROJ Description Cost
CATEGORY
Statewide 44806.1.1, RR-OOSS(024) $500,000.00 Cost
Z-5800 Railway-Highway Grade Crossing Safety Projects at various $450,000.00 Fed.
DIVISION locations across North Carolina. Funds are needed for $50,000.00 State
REGIONAL preliminary engineering.
STATEWIDE
ITEM M SUMMARY - 81 PROJECT(S) -(TOTAL FEDERAL AND STATE) $92,087,758.00
December 6, 2018
ITEM N
HIGHWAY PROGRAM
STIP ADDITIONS
DIVISION 9
* EB-5952 FAIRLAWN DRIVE, NC 67 (REYNOLDA ROAD) TO SR ENGINEERING
FORSYTH 1528 (SILAS CREEK PKWY) IN WINSTON-SALEM.
PROJ.CATEGORY CONSTRUCT SIDEWALK. RIGHT-OF-WAY
DIVISION PROJECT ADDED AT REQUEST OF MPO.
CONSTRUCTION
* EB-5953 SR 4000 (UNIVERSITY PARKWAY), SR-1686
FORSYTH (SHATTALON DRIVE) TO ROBIN WOOD LANE IN
PROJ.CATEGORY WINSTON-SALEM. CONSTRUCT SIDEWALK.
DIVISION PROJECT ADDED AT REQUEST OF MPO.
* EB-5954 GRIFFITH ROAD, KIMWELL DRIVE TO BURKE MILL
FORSYTH ROAD IN WINSTON-SALEM. CONSTRUCT SIDEWALK.
PROJ.CATEGORY PROJECT ADDED AT REQUEST OF MPO.
DIVISION
* EB-5955 SR 1348 (ROBINHOOD ROAD), SPEAKS FARM ROAD TO
FORSYTH MUDDY CREEK GREENWAY IN WINSTON-SALEM.
PROJ.CATEGORY CONSTRUCT SIDEWALK.
DIVISION PROJECT ADDED AT REQUEST OF MPO.
* EB-5956 SR 1992 (SULLIVANTOWN ROAD), US 311 AT HARLEY
FORSYTH DRIVE TO WALKERTOWN HIGH/MIDDLE SCHOOL IN
PROJ.CATEGORY WALKERTOWN. INSTALL BICYCLE AND PEDESTRIAN
DIVISION FACILITIES AND CONSTRUCT SIDEWALK.
PROJECT ADDED AT REQUEST OF MPO.
* INDICATES FEDERAL AMENDMENT
ENGINEERING
CONSTRUCTION
ENGINEERING
RIGHT-OF-WAY
CONSTRUCTION
ENGINEERING
RIGHT-OF-WAY
CONSTRUCTION
ENGINEERING
RIGHT-OF-WAY
CONSTRUCTION
FY 2019 -
FY 2019 -
FY 2019 -
FY 2019 -
FY 2020 -
FY 2020 -
FY 2019 -
FY 2019 -
FY 2019 -
FY 2019 -
$79,000
$20,000
$198,000
$50,000
$593,000
$148,000
$1,088,000
$76,000
$19,000
$508,000
$127,000
$730,000
(STBG)
(L)
(STBG)
(L)
(STBGDA)
(L)
(STBG)
(L)
(STBG)
(L)
FY 2019 - $181,000 (STBG)
FY 2019 - $45,000 (L)
FY 2019 - $34,000 (STBG)
FY 2019 - $8,000 (L)
FY 2019 - $1,296,000 (STBG)
FY 2019 - $324,000 (L)
$1,888,000
FY 2019 -
FY 2019 -
FY 2019 -
FY 2019 -
FY 2019 -
FY 2019 -
$56,000
$14,000
$53,000
$13,000
$376,000
$94,000
$606,000
(STBG)
(L)
(STBG)
(L)
(STBG)
(L)
FY 2019 -
FY 2019 -
FY 2019 -
FY 2019 -
FY 2019 -
FY 2019 -
$56,000
$14,000
$8,000
$2,000
$440,000
$110,000
$630,000
(STBG)
(L)
(STBG)
(L)
(STBGDA)
(L)
Thursday, December 06, 2018 1
ITEM N
HIGHWAY PROGRAM
STIP ADDITIONS
DIVISION 9
* EB-5957 SR 2648 (OLD WINSTON ROAD), EXISTING SIDEWALK ENGINEERING FY 2019 -
FORSYTH ACROSS FROM SEVENTH DAY ADVENTIST CHURCH FY 2019 -
PROJ.CATEGORY PARKING LOT TO HOPKINS ROAD IN KERNERSVILLE. RIGHT-OF-WAY FY 2020 -
DIVISION CONSTRUCT SIDEWALK ON SOUTH SIDE. FY 2020 -
PROJECT ADDED AT REQUEST OF MPO. CONSTRUCTION FY 2021 -
FY 2021 -
* EB-5958 BERMUDA RUN, TWINS WAY (NEAR INTERSECTION
FORSYTH WITH US-158) WEST TO PEDESTRIAN TUNNEL UNDER I-
PROJ.CATEGORY 40 IN BERMUDA RUN. CONSTRUCT PORTION OF BLUE
DIVISION HERON TRAIL.
PROJECT ADDED AT REQUEST OF MPO.
ENGINEERING
CONSTRUCTION
FY 2019 -
FY 2019 -
FY 2019 -
FY 2019 -
FY 2019 -
FY 2019 -
* EB-5959 SR 3000 (IDOLS ROAD), SR 1103 (MIDDLEBROOK
FORSYTH DRIVE) TO TANGLEWOOD PARK ROAD IN CLEMMONS.
PROJ.CATEGORY CONSTRUCT SIDEWALK.
DIVISION PROJECT ADDED AT REQUEST OF MPO.
* U-6154 SR 1308 (LEWISVILLE-VIENNA ROAD), AT SR 1348
FORSYTH (ROBINHOOD ROAD) IN LEWISVILLE. CONVERT
PROJ.CATEGORY EXISTING SIGNALIZED INTERSECTION TO A SINGLE
DIVISION LANE ROUNDABOUT.
PROJECT ADDED AT REQUEST OF MPO.
* U-6155 SR 1725 (UNIVERSITY PKWY), AT INTERSECTION WITH
FORSYTH COLISEUM DRIVE IN WINSTON-SALEM. CONSTRUCT
PROJ.CATEGORY INTERSECTION IMPROVEMENTS FOR PEDESTRIAN
DIVISION SAFETY.
PROJECT ADDED AT REQUEST OF MPO.
* INDICATES FEDERAL AMENDMENT
ENGINEERING
CONSTRUCTION
ENGINEERING
RIGHT-OF-WAY
CONSTRUCTION
ENGINEERING
CONSTRUCTION
FY 2019 -
FY 2019 -
FY 2020 -
FY 2020 -
FY 2020 -
FY 2019 -
FY 2019 -
FY 2020 -
FY 2020 -
FY 2021 -
FY 2021 -
FY 2019 -
FY 2019 -
FY 2019 -
FY 2019 -
FY 2019 -
$29,000
$7,000
$29,000
$7,000
$186,000
$46,000
$304,000
$189,000
$47,000
$1,263,000
$217,000
$2,000
$371,000
$2,089,000
$88,000
$22,000
$202,000
$516,000
$179,000
$1,007,000
$96,000
$24,000
$200,000
$50,000
$720,000
$180,000
$1,270,000
$60,000
$15,000
$65,000
$50,000
$60,000
$250,000
(STBG)
(L)
(STBG)
(L)
(STBGDA)
(L)
(STBG)
(L)
(STBG)
(STBGDA)
(TAPDA)
(L)
(STBGDA)
(L)
(STBG)
(STBGDA)
(L)
(STBG)
(L)
(STBG)
(L)
(STBGDA)
(L)
(STBG)
(L)
(STBG)
(HSIP)
(L)
Thursday, December 06, 2018 2
ITEM N
HIGHWAY PROGRAM
STIP ADDITIONS
DIVISION 10
* U-57036
UNION
PROJ.CATEGORY
STATEWIDE
US 74 (ROOSEVELT BLVD), REALIGN JAMES HAMILTON RIGHT-OF-WAY FY 2019 - $500,000 (T)
ROAD TO INTERSECT WITH SR 1514 (ROCKY RIVER CONSTRUCTION FY 2020 - $650,000 (T)
ROAD) AT MYERS ROAD. $1,150,000
ADD RIGHT-OF-WAY IN FY 19 NOT PREVIOUSLY
PROGRAMMED.
DIVISION 11
* I-6050 I-74 & I-77, I-74 & I-77 INTERCHANGES/RAMPS
SURRY PROJECT ADDED AT REQUEST OF DIVISION.
PROJ.CATEGORY
STATEWIDE
DIVISION 13
* EB-5547B
BUNCOMBE
PROJ.CATEGORY
DIVISION
CONSTRUCTION FY 2019 - $1,000,000 (NHPIM)
$1,000,000
BLACK MOUNTAIN RIVERWALK GREENWAY, ENGINEERING FY 2019 -
CONSTRUCT MULTI-USE PATH FROM BLACK FY 2019 -
MOUNTAIN AVENUE TO THE INTO THE OAKS TRAIL. CONSTRUCTION FY 2020 -
ADD CONSTRUCTION IN FY 20 NOT PREVIOUSLY FY 2020 -
PROGRAMMED AT REQUEST OF MPO
STIP MODIFICATIONS
DIVISION 1
R-5740 SR 1329 (WOODVILLE ROAD), SR 1331 (RED BANK
PERQUIMANS ROAD) TO SR 1300 (NEW HOPE ROAD). UPGRADE
PROJ.CATEGORY ROADWAY.
DIVISION PROJECT TO UTILIZE BUILD NC BONDS
* INDICATES FEDERAL AMENDMENT
BUILD NC CONST
CONSTRUCTION
FY 2019 -
FY 2020 -
FY 2021 -
FY 2022 -
FY 2023 -
FY 2024 -
FY 2025 -
FY 2026 -
FY 2027 -
FY 2028 -
FY 2029 -
POST YR-
FY 2019 -
$110,000
$28,000
$600,000
$150,000
$888,000
$429,000
$429,000
$429,000
$429,000
$429,000
$429,000
$429,000
$429,000
$429,000
$429,000
$429,000
$1,716,000
$800,000
$7,235,000
(STBGDA)
(L)
(STBGDA)
(L)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
Thursday, December 06, 2018 3
ITEM N
HIGHWAY PROGRAM
DIVISION 2
R-3403B
CRAVEN
PROJ.CATEGORY
REGIONAL
STIP MODIFICATIONS
US 17, SR 1433 (ANTIOCH ROAD) TO NC 43 RIGHT-OF-WAY
COST INCREASE EXCEEDING $2 MILLION AND 25%
THRESHOLDS. UTILITIES
BUILD NC CONST
CONSTRUCTION
R-4463A
CRAVEN
PROJ.CATEGORY
REGIONAL
NC 43 CONNECTOR, US 17 TO SOUTH OF US 70. RIGHT-OF-WAY
PROJECT TO UTILIZE BUILD NC BONDS UTILITIES
BUILD NC CONST
CONSTRUCTION
R-5777C
CRAVEN
PROJ.CATEGORY
STATEWIDE
US 70, THURMAN ROAD TO HAVELOCK BYPASS. RIGHT-OF-WAY
UPGRADE ROADWAY TO FREEWAY AND CONSTRUCT UTILITIES
SERVICE ROADS. CONSTRUCTION
ACCELERATE RIGHT-OF-WAY FROM PY TO FY 20 AND
CONSTRUCTION FROM PY TO FY 20 TO EXPEDITE
DELIVERY OF NEW STI PROJECT DUE TO RECENT
AWARD OF FEDERAL INFRA GRANT.
* INDICATES FEDERAL AMENDMENT
FY 2020 -
FY 2021 -
FY 2020 -
FY 2021 -
FY 2022 -
FY 2023 -
FY 2024 -
FY 2025 -
FY 2026 -
FY 2027 -
FY 2028 -
FY 2029 -
POST YR-
FY 2022 -
FY 2023 -
FY 2024 -
FY 2025 -
FY 2026 -
FY 2019 -
FY 2019 -
FY 2019 -
FY 2020 -
FY 2021 -
FY 2022 -
FY 2023 -
FY 2024 -
FY 2025 -
FY 2026 -
FY 2027 -
FY 2028 -
FY 2029 -
POST YR-
FY 2019 -
$3,400,000
$3,400,000
$450,000
$450,000
$1,373,000
$1,373,000
$1,373,000
$1,373,000
$1,373,000
$1,373,000
$1,373,000
$1,373,000
$9,611,000
$6,340,000
$6,340,000
$6,340,000
$6,340,000
$6,340,000
$59,995,000
$1,225,000
$500,000
$472,000
$472,000
$472,000
$472,000
$472,000
$472,000
$472,000
$472,000
$472,000
$472,000
$472,000
$1,888,000
$500,000
$9,305,000
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
FY 2020 - $28,500,000 (T)
FY 2020 - $1,100,000 (T)
FY 2020 - $6,175,000 (T)
FY 2021 - $39,108,000 (T)
FY 2022 - $39,108,000 (T)
FY 2023 - $39,109,000 (T)
$153,100,000
Thursday, December 06, 2018 4
ITEM N
HIGHWAY PROGRAM
STIP MODIFICATIONS
DIVISION 2
R-5813 US 70, SR 1227 (JIM SUTTON ROAD)/SR 1252 (WILLIE
LENOIR MEASLEY ROAD). CONSTRUCT AT GRADE
PROJ.CATEGORY INTERSECTION TO INTERCHANGE
REGIONAL COST INCREASE EXCEEDING $2 MILLION AND 25%
THRESHOLDS.
* U-2817 SR 1700 (EVANS STREETI OLD TAR ROAD), SR 1711
PITT (WORTHINGTON ROAD) IN WINTERVILLE TO US 264
PROJ.CATEGORY ALTERNATE (GREENVILLE BOULEVARD) IN
DIVISION GREENVILLE. WIDEN TO MULTI-LANES.
U-5860
BEAUFORT
PROJ.CATEGORY
DIVISION
DIVISION 3
AV-5739
BRUNSWICK
PROJ.CATEGORY
DIVISION
* B-5981
DUPLIN
PROJ.CATEGORY
STATEWIDE
COST INCREASE EXCEEDING $2 MILLION AND 25%
THRESHOLDS.
RIGHT-OF-WAY FY 2022 - $14,930,000
UTILITIES FY 2022 - $2,191,000
CONSTRUCTION FY 2024 - $8,208,000
FY 2025 - $8,208,000
FY 2026 - $8,208,000
FY 2027 - $8,208,000
$49,953,000
RIGHT-OF-WAY
UTILITIES
CONSTRUCTION
FY 2019 -
FY 2020 -
FY 2019 -
FY 2020 -
FY 2021 -
FY 2022 -
FY 2023 -
FY 2024 -
$22,500,000
$22,500,000
$1,150,000
$1,150,000
$8,575,000
$8,575,000
$8,575,000
$8,575,000
$81,600,000
SR 1306 (15TH STREET), US 17 BUSINESS (CAROLINA RIGHT-OF-WAY FY 2024 -
AVENUE) TO BROWN STREET. WIDEN TO MULTI- CONSTRUCTION FY 2026 -
LANES. FY 2027 -
TO ALLOW ADDITIONAL TIME FOR PLANNING AND FY 2028 -
DESIGN, DELAY RIGHT-OF-WAY FROM FY 18 TO FY 24
AND CONSTRUCTION FROM FY 19 TO FY 26.
CAPE FEAR REGIONAL (SUT), APPROACH CLEARING CONSTRUCTION FY 2019 -
AT RUNWAY 5 AND RUNWAY 23.
TO ALLOW ADDITIONAL TIME FOR PLANNING AND
DESIGN, DELAY CONSTRUCTION FROM FY 16 TO FY 19.
$5,885,000
$3,203,000
$3,203,000
$3,203,000
$15,494,000
(T)
(T)
(T)
(T)
(T)
(T)
(STBG)
(STBG)
(STBG)
(STBG)
(STBG)
(STBG)
(STBG)
(STBG)
(T)
(T)
(T)
(T)
$170,000 (T)
$170,000
US 117 NBL, REPLACE BRIDGE 300016 OVER CSX RIGHT-OF-WAY FY 2021 - $443,000 (STBG)
RAILROAD. BRIDGE PRESERVATION OF BRIDGE 300017 CONSTRUCTION FY 2022 - $5,052,000 (STBG)
OVER CSX. $5,495,000
MODIFY PROJECT SCOPE, FUNDING AMOUNTS, AND
SCHEDULE.
* INDICATES FEDERAL AMENDMENT
Thursday, December 06, 2018 5
ITEM N
HIGHWAY PROGRAM
STIP MODIFICATIONS
DIVISION 3
* U-3338C SR 1175 (KERR AVENUE), SR 1175 (KERR AVENUE) RIGHT-OF-WAY FY 2019 - $3,912,000 (STBG)
NEW HANOVER INTERCHANGE AT US 74 (MLK, JR. PARKWAY). CONSTRUCTION FY 2020 -$20,500,000 (STBG)
PROJ.CATEGORY COST INCREASE EXCEEDING $2 MILLION AND 25% $24,412,000
REGIONAL THRESHOLDS.
U-5932 US 17, NC 211. CONVERT INTERSECTION TO
BRUNSWICK INTERCHANGE.
PROJ.CATEGORY COST INCREASE EXCEEDING $2 MILLION AND 25%
STATEWIDE THRESHOLDS.
RIGHT-OF-WAY
UTILITIES
CONSTRUCTION
FY 2022 -
FY 2023 -
FY 2022 -
FY 2023 -
FY 2024 -
FY 2025 -
FY 2026 -
$10,000,000
$10,000,000
$5,200,000
$5,200,000
$6,667,000
$6,667,000
$6,666,000
$50,400,000
(T)
(T)
(T)
(T)
(T)
(T)
(T)
DIVISION 4
B-5947 NC 581, REPLACE BRIDGE 630091 OVER TAR RIVER.
NASH ACCELERATE RIGHT-OF-WAY FROM FY 25 TO FY 20
PROJ.CATEGORY AND CONSTRUCTION FROM FY 26 TO FY 21.
REGIONAL
RIGHT-OF-WAY FY 2020 -
CONSTRUCTION FY 2021 -
FY 2022 -
FY 2023 -
$400,000
$2,667,000
$2,667,000
$2,667,000
$8,401,000
(T)
(T)
(T)
(T)
P-5711A CSX A LINE, CCX INTERMODAL TERMINAL AND TRACK CONSTRUCTION FY 2019 -$50,000,000 (T)
EDGECOMBE IMPROVEMENTS. FY 2020 - $43,100,000 (T)
PROJ.CATEGORY MODIFYPROJECTSCOPEANDFUNDINGAMOUNTS. $93,100,000
STATEWIDE
R-38256 NC 42, EAST OF SR 1902 (GLEN LAUREL ROAD) TO SR CONSTRUCTION FY 2019 -$22,200,000 (T)
JOHNSTON 1003 (BUFFALOE ROAD). FY 2020 -$22,200,000 (T)
PROJ.CATEGORY COST INCREASE EXCEEDING $2 MILLION AND 25% FY 2021 -$22,200,000 (T)
DIVISION THRESHOLDS. $66,600,000
* INDICATES FEDERAL AMENDMENT
Thursday, December 06, 2018 6
ITEM N
HIGHWAY PROGRAM
STIP MODIFICATIONS
DIVISION 4
U-3609B US 13 (BERKELEY BOULEVARD), SR 1003 (NEW HOPE BUILD NC ROW
WAYNE ROAD) TO SR1572 (SAULSTON ROAD).
PROJ.CATEGORY TO ALLOW ADDITIONAL TIME FOR PLANNING AND
REGIONAL DESIGN DELAY RIGHT-OF-WAY FROM FY 19 TO FY 20.
DIVISION 5
G5183B
DURHAM
PROJ.CATEGORY
EXEMPT
RIGHT-OF-WAY
UTILITIES
CONSTRUCTION
SR 1945 (S. ALSTON AVE.), SR 1171 (RIDDLE RD.) TO CONSTRUCTION
CAPPS ST.
TO ALLOW ADDITIONAL TIME FOR RIGHT OF WAY,
UTILITIES AND FINAL DESIGN DELAY CONSTRUCTION
FROM FY 18 TO FY 19, AT REQUEST OF MPO.
* EB-5895 NC 55 (EAST WILLIAMS STREET), SR 1301 (SUNSET
WAKE LAKE ROAD) TO NC 55 IN HOLLY SPRINGS.
PROJ.CATEGORY CONSTRUCT SIDEWALK.
DIVISION TO REFLECT CURRENT PROJECT DELIVERY SCOPE
AND SCHEDULE, ADD RIGHT OF WAY IN FY 19 AND
DELAY CONSTRUCTION FROM FY 19 TO FY 20 AT THE
REQUEST OF TOWN AND MPO.
* INDICATES FEDERAL AMENDMENT
RIGHT-OF-WAY
CONSTRUCTION
FY 2020 -
FY 2021 -
FY 2022 -
FY 2023 -
FY 2024 -
FY 2025 -
FY 2026 -
FY 2027 -
FY 2028 -
FY 2029 -
POST YR-
FY 2020 -
FY 2020 -
FY 2021 -
FY 2021 -
FY 2022 -
FY 2023 -
FY 2024 -
FY 2019 -
FY 2019 -
FY 2019 -
FY 2019 -
FY 2020 -
FY 2020 -
$515,000
$515,000
$515,000
$515,000
$515,000
$515,000
$515,000
$515,000
$515,000
$515,000
$2,575,000
$1,750,000
$1,750,000
$1,750,000
$5,875,000
$5,875,000
$5,875,000
$5,875,000
$36,475,000
$644,360
$161,090
$805,450
$80,000
$20,000
$400,000
$100,000
$600,000
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(CMAQ)
(L)
(TAP)
(L)
(TAP)
(L)
Thursday, December 06, 2018 7
ITEM N
HIGHWAY PROGRAM
STIP MODIFICATIONS
DIVISION 5
* I-5870 I-440 / US 1, WEST OF RIDGE ROAD TO EAST OF US 70 RIGHT-OF-WAY
WAKE (GLENWOOD AVENUE) IN RALEIGH. CONSTRUCT NEW UTILITIES
PROJ.CATEGORY INTERCHANGE AT RIDGE ROAD TO CONNECT WITH CONSTRUCTION
STATEWIDE CRABTREE VALLEY AVENUE, REALIGN I-440 / US 1
INTERCHANGE WITH US 70 (GLENWOOD AVENUE),
REALIGN AND WIDEN CRABTREE VALLEY AVENUE
BETWEEN SR 3009 (EDWARDS MILL ROAD) AND RIDGE
ROAD, AND REPLACE BRIDGE 910494 OVER
CRABTREE CREEK ON SR 1670 (BLUE RIDGE ROAD).
COST INCREASE EXCEEDING $2 MILLION AND 25%
THRESHOLDS.
* P-5717
DURHAM
PROJ.CATEGORY
REGIONAL
FY 2022 - $115,000,000 (T)
FY 2022 - $1,200,000 (T)
FY 2022 - $5,325,000 (T)
FY 2023 - $25,294,000 (T)
FY 2024 - $25,294,000 (T)
FY 2025 - $50,587,000 (T)
$222,700,000
NORFOLK SOUTHERN H LINE, CROSSING 734742W AT RIGHT-OF-WAY FY 2019 -
SR 1121 (CORNWALLIS ROAD) IN DURHAM. CONSTRUCTION FY 2020 -
CONSTRUCT GRADE SEPARATION. FY 2020 -
COST INCREASE EXCEEDING $2 MILLION AND 25%
THRESHOLDS.
R-5705B NC 55, NC 210 TO SR 4809 (JICARILLA LANE). PART ON
HARNETT NEW LOCATION.
WAKE MODIFY PROJECT SCOPE AND FUNDING AMOUNTS.
PROJ.CATEGORY COST INCREASE EXCEEDING $2 MILLION AND 25%
REGIONAL THRESHOLDS.
$2,500,000 (T)
$15,600,000 (T)
$500,000 (0)
$18,600,000
RIGHT-OF-WAY FY 2020 - $2,685,000 (T)
UTILITIES FY 2020 - $355,000 (T)
CONSTRUCTION FY 2022 - $12,466,000 (T)
FY 2023 - $12,466,000 (T)
FY 2024 - $12,466,000 (T)
$40,438,000
R-5705C NC 55, SR 4809 (JICARILLA LANE) TO NC 42 IN FUQUAY- RIGHT-OF-WAY POST YR- $6,800,000 (T)
WAKE VARINA. UTILITIES POST YR- $900,000 (T)
MODIFYPROJECT SCOPE AND FUNDING AMOUNTS. CONSTRUCTION POST YR- $17,900,000 (T)
$25,600,000
* U-2901 B NC 55 (WILLIAMS STREET), US 1 TO NORTH OF SR 1160 RIGHT-OF-WAY FY 2019 - $770,000 (T)
WAKE (OLIVE CHAPEL ROAD). CONVERT EXISTING UTILITIES FY 2019 - $93,000 (T)
PROJ.CATEGORY MULTILANES TO MEDIAN DIVIDED SECTION AND CONSTRUCTION FY 2021 -$23,100,000 (T)
REGIONAL WIDEN REMAINING 2-LANE SECTIONS TO MULTILANES. $23,963,000
COST INCREASE EXCEEDING $2 MILLION AND 25%
THRESHOLDS.
* INDICATES FEDERAL AMENDMENT
Thursday, December 06, 2018 8
ITEM N
HIGHWAY PROGRAM
STIP MODIFICATIONS
DIVISION 5
U-4916 SR 1165 (BECKFORD DRIVE), HARRISON STREET TO
VANCE NORTH PARK DRIVE IN HENDERSON. WIDEN TO
PROJ.CATEGORY THREE LANES WITH CURB AND GUTTER, STORM
TRANSITION DRAINAGE, AND SIDEWALKS.
TO ALLOW CITYADDITIONAL TIME TO COMPLETE
FINAL DESIGN, DELA Y CONSTRUCTION FROM FY 18
TO FY 19.
CONSTRUCTION FY 2019 - $679,000 (HP)
FY 2019 - $170,000 (L)
$849,000
U-5302 US 401, SOUTH OF SR 1006 (OLD STAGE ROAD) TO RIGHT-OF-WAY
WAKE SOUTH OF SR 2538 (MECHANICAL BOULEVARD) I BUILD NC CONST
PROJ.CATEGORY GARNER STATION BOULEVARD IN GARNER. CONVERT
REGIONAL TO SUPERSTREET.
REVISE TERMINI AT REQUEST OF DIVISION TO
REFLECT CURRENT DOCUMENT SCOPE.
* U-5745 NC 751 (HOPE VALLEY ROAD), SR 1183 (UNIVERSITY
DURHAM DRIVE) INTERSECTION IN DURHAM. CONSTRUCT
PROJ.CATEGORY ROUNDABOUT.
REGIONAL PROJECT TO UTILIZE BUILD NC BONDS
U-5747A
WAKE
PROJ.CATEGORY
DIVISION
CONSTRUCTION
FY 2019 - $850,000
FY 2020 - $515,000
FY 2021 - $515,000
FY 2022 - $515,000
FY 2023 - $515,000
FY 2024 - $515,000
FY 2025 - $515,000
FY 2026 - $515,000
FY 2027 - $515,000
FY 2028 - $515,000
FY 2029 - $515,000
POST YR- $2,575,000
FY 2020 - $7,200,000
$15,775,000
BUILD NC CONST FY 2019 - $86,000
FY 2020 - $86,000
FY 2021 - $86,000
FY 2022 - $86,000
FY 2023 - $86,000
FY 2024 - $86,000
FY 2025 - $86,000
FY 2026 - $86,000
FY 2027 - $86,000
FY 2028 - $86,000
FY 2029 - $86,000
POST YR- $344,000
$1,290,000
SR 1635 (MCCRIMMON PARKWAY), SR 1613 (DAVIS RIGHT-OF-WAY
DRIVE) TO NORTH OF SR 1637 (CHURCH STREET) IN UTILITIES
MORRISVILLE. WIDEN TO 4-LANE DIVIDED FACILITY. CONSTRUCTION
TO ALLOW ADDITIONAL TIME FOR PLANNING AND
DESIGN DELAY RIGHT-OF-WAY FROM FY 19 TO FY 20.
* INDICATES FEDERAL AMENDMENT
FY 2020 - $2,000,000
FY 2020 - $500,000
FY 2021 - $3,500,000
FY 2022 - $3,500,000
FY 2023 - $3,500,000
$13,000,000
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
Thursday, December 06, 2018 9
ITEM N
HIGHWAY PROGRAM
STIP MODIFICATIONS
DIVISION 5
U-5747B NC 54, SR 1635 (MCCRIMMON PARKWAY) IN BUILD NC ROW
WAKE MORRISVILLE. CONVERT AT-GRADE INTERSECTION
PROJ.CATEGORY TO GRADE SEPARATION, INCLUDING GRADE
REGIONAL SEPARATION OF NORTH CAROLINA RAILROAD.
TO ALLOW ADDITIONAL TIME FOR PLANNING AND
DESIGN DELAY RIGHT-OF-WAY FROM FY 19 TO FY 20.
DIVISION 6
* EB-5800
CUMBERLAND
PROJ.CATEGORY
DIVISION
* I-5850B
ROBESON
PROJ.CATEGORY
STATEWIDE
I-59386
ROBESON
PROJ.CATEGORY
STATEWIDE
RIGHT-OF-WAY
UTILITIES
CONSTRUCTION
FY 2020 -
FY 2021 -
FY 2022 -
FY 2023 -
FY 2024 -
FY 2025 -
FY 2026 -
FY 2027 -
FY 2028 -
FY 2029 -
POST YR-
FY 2020 -
FY 2020 -
FY 2021 -
FY 2022 -
FY 2023 -
SR 2251 (OWEN DRIVE), US 301 TO SR 1007 (ALL CONSTRUCTION FY 2019 -
AMERICAN EXPRESSWAY). CONSTRUCT SIDEWALK FY 2019 -
ON EAST SIDE.
TO ALLOW ADDITIONAL TIME FOR PLANNING AND
DESIGN, DELAY CONSTRUCTION FROM FY 18 TO FY 19.
I-95, PAVEMENT REHABILITATION
COST INCREASE EXCEEDING $2 MILLION AND 25%
THRESHOLDS.
$515,000
$515,000
$515,000
$515,000
$515,000
$515,000
$515,000
$515,000
$515,000
$515,000
$2,575,000
$1,800,000
$500,000
$4,134,000
$4,134,000
$4,134,000
$22,427,000
$441,000
$110,000
$551,000
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(TAP)
(L)
CONSTRUCTION FY 2019 - $14,000,000 (NHPIM)
$14,000,000
I-74, PAVEMENT REHABILITATION
COST INCREASE EXCEEDING $2 MILLION AND 25%
THRESHOLDS.
* INDICATES FEDERAL AMENDMENT
CONSTRUCTION FY 2019 - $16,700,000 (NHPIM)
$16,700,000
Thursday, December 06, 2018 10
ITEM N
HIGHWAY PROGRAM
STIP MODIFICATIONS
DIVISION 6
R-5705A NC 55, JUST SOUTH OF SR 1532 (OAK GROVE CHURCH RIGHT-OF-WAY FY 2020 - $3,253,000 (T)
HARNETT ROAD) TO NC 210. PART ON NEW LOCATION. UTILITIES FY 2020 - $1,159,000 (T)
PROJ.CATEGORY MODIFY PROJECT SCOPE AND FUNDING AMOUNTS. CONSTRUCTION FY 2022 -$11,900,000 (T)
DIVISION COST INCREASE EXCEEDING $2 MILLION AND 25% FY 2023 -$11,900,000 (T)
THRESHOLDS. FY 2024 - $11,900,000 (T)
$40,112,000
R-5819 US 741US 76, SR 1740 (OLD LAKE ROAD). CONVERT AT- UTILITIES
COLUMBUS GRADE INTERSECTION TO OVERPASS. CONSTRUCTION
PROJ.CATEGORY COST INCREASE EXCEEDING $2 MILLION AND 25%
REGIONAL THRESHOLDS.
R-5820 US 741US 76, SR 1735 (CHAUNCEY TOWN ROAD)
COLUMBUS CONVERT AT-GRADE INTERSECTION TO
PROJ.CATEGORY INTERCHANGE.
REGIONAL COST INCREASE EXCEEDING $2 MILLION AND e'
THRESHOLDS.
UTILITIES
CONSTRUCTION
FY 2020 - $35,000
FY 2022 - $5,350,000
FY 2023 - $5,350,000
$10,735,000
FY 2020 - $47,000
FY 2022 - $6,533,000
FY 2023 - $6,533,000
FY 2024 - $6,534,000
$19,647,000
DIVISION 7
C-5650 SR 1919 (SMITH LEVEL ROAD I S. GREENSBORO ST),
ORANGE PUBLIC WORKS DRIVE TO N. END OF OLD PITTSBORO
PROJ.CATEGORY ROAD IN CARRBORO. CONSTRUCT 3,100 LF SIDEWALK
DIVISION ON ONE SIDE.
ENGINEERING
FY 2019 -
FY 2019 -
FY 2020 -
FY 2020 -
FY 2021 -
FY 2021 -
FY 2021 -
RIGHT-OF-WAY
TO REFLECT CURRENT TOWN DELIVERYSCHEDULE, CONSTRUCTION
DELAY ENGINEERING FROM FY 18 TO FY 19, RIGHT-OF-
WAY FROM FY 18 TO FY 20 AND CONSTRUCTION
FROM FY 18 TO FY 21.
C-5700 OAKDALE ROAD, EXISTING SIDEWALK EAST OF EAST CONSTRUCTION FY 2019 -
GUILFORD MAIN STREET TO CHIMNEY COURT IN JAMESTOWN. FY 2019 -
PROJ.CATEGORY EXTEND SIDEWALK.
EXEMPT TOWN NEEDS ADDITIONAL TIME FOR PLANNING AND
DESIGN. DELAY CONSTRUCTION FROM FY 18 TO FY
19.
* INDICATES FEDERAL AMENDMENT
$84,000
$21,000
$100,000
$25,000
$440,000
$530,000
$748,000
$1,948,000
$136,000
$34,000
$170,000
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(STBGDA)
(L)
(STBGDA)
(L)
(CMAQ)
(STBGDA)
(L)
(CMAQ)
(L)
Thursday, December 06, 2018 11
ITEM N
HIGHWAY PROGRAM
STIP MODIFICATIONS
DIVISION 7
EB-5721 ORANGE COUNTY BICYCLE ROUTE 1, CLELAND DRIVE CONSTRUCTION FY 2019 - $375,000 (TAP)
ORANGE TO WILLOW DRIVE IN CHAPEL HILL. UPGRADE FY 2019 - $94,000 (L)
PROJ.CATEGORY EXISTING OFF-ROAD PATH AND CONSTRUCT NEW $469,000
DIVISION SECTION OF PATH.
TO REFLECT CURRENT TOWN DELIVERY SCHEDULE,
DELAY CONSTRUCTION FROM FY 18 TO FY 19 AT
REQUEST OF MPO.
EB-5879
ALAMANCE
PROJ.CATEGORY
DIVISION
* EB-5880
ORANGE
PROJ.CATEGORY
DIVISION
* EB-5886A
ORANGE
PROJ.CATEGORY
DIVISION
US 70 (NORTH CHURCH STREET), SR 1716 (GRAHAM-
HOPEDALE ROAD) TO SR 1719 (SELLARS MILL ROAD)
IN BURLINGTON. CONSTRUCT SIDEWALK.
ENGINEERING
RIGHT-OF-WAY
TO REFLECT CURRENT CITY DELIVERY SCHEDULE,
DELAYENGINEERING, RIGHT-OF-WAYAND CONSTRUCTION
CONSTRUCTION FROM FY 18 TO FY 19.
SR 1005 (JONES FERRY ROAD), DAVIE ROAD TO SR
1010 (WEST MAIN STREET) IN CARRBORO.
CONSTRUCT SIDEWALK ON NORTH SIDE.
ENGINEERING
RIGHT-OF-WAY
TO REFLECT CURRENT TOWN DELIVERY SCHEDULE,
DELAY ENGINEERING FROM FY 18 TO FY 22, RIGHT OF CONSTRUCTION
WAY FROM FY 20 TO FY 23 AND CONSTRUCTION
FROM FY 21 TO FY 24.
SR 1780 (ESTES DRIVE), SR 1772 (NORTH
GREENSBORO STREET) TO SOUTH OF NORFOLK-
SOUTHERN RR TRACKS IN CARRBORO
ENGINEERING
RIGHT-OF-WAY
TO REFLECT CURRENT TOWN DELIVERY SCHEDULE,
DELAY ENGINEERING FROM FY 18 TO FY 20, RIGHT OF CONSTRUCTION
WAY FROM FY 20 TO FY 21 AND CONSTRUCTION
FROM FY 21 TO FY 22.
* EB-5890 BARNES STREET, KING STREET TO SR 1005 (JONES
ORANGE FERRY ROAD) IN CARRBORO. CONSTRUCT SIDEWALK.
PROJ.CATEGORY TO REFLECT CURRENT TOWN DELIVERY SCHEDULE,
DIVISION DELAY ENGINEERING FROM FY 19 TO FY 22, RIGHT OF
WAY FROM FY 21 TO FY 23 AND CONSTRUCTION
FROM FY 22 TO FY 24.
* INDICATES FEDERAL AMENDMENT
ENGINEERING
RIGHT-OF-WAY
CONSTRUCTION
FY 2019 -
FY 2019 -
FY 2019 -
FY 2019 -
FY 2019 -
FY 2019 -
FY 2022 -
FY 2022 -
FY 2023 -
FY 2023 -
FY 2024 -
FY 2024 -
FY 2020 -
FY 2020 -
FY 2021 -
FY 2021 -
FY 2022 -
FY 2022 -
FY 2022 -
FY 2022 -
FY 2023 -
FY 2023 -
FY 2024 -
FY 2024 -
$13,000
$3,000
$22,000
$6,000
$53,000
$13,000
$110,000
$71,000
$18,000
$25,000
$6,000
$353,000
$88,000
$561,000
$136,000
$34,000
$37,000
$9,000
$678,000
$170,000
$1,064,000
$37,000
$9,000
$13,000
$3,000
$184,000
$46,000
$292,000
(TAP)
(L)
(TAP)
(L)
(TAP)
(L)
(TAP)
(L)
(TAP)
(L)
(TAP)
(L)
(TAP)
(L)
(TAP)
(L)
(TAP)
(L)
(TAP)
(L)
(TAP)
(L)
(TAP)
(L)
Thursday, December 06, 2018 12
ITEM N
HIGHWAY PROGRAM
STIP MODIFICATIONS
DIVISION 7
I-5898 FUTURE I-73 I US 220, US 311 I NC 135 INTERCHANGE. RIGHT-OF-WAY
ROCKINGHAM WIDEN BRIDGE 780074 AND UPGRADE INTERCHANGE. UTILITIES
PROJ.CATEGORY TO REFLECT CURRENT PROJECT DELIVERY CONSTRUCTION
REGIONAL SCHEDULE, DELAY RIGHT-OF-WAY FROM FY 18 TO FY
19.
* U-2581BA US 70, SR3045 (MOUNT HOPE CHURCH ROAD) TO SR RIGHT-OF-WAY
GUILFORD 3175 (BIRCH CREEK ROAD) UTILITIES
PROJ.CATEGORY COSTINCREASE EXCEEDING $2 MILLION AND 25% BUILD NC CONST
DIVISION THRESHOLDS.
CONSTRUCTION
FY 2019 -
FY 2019 -
FY 2020 -
FY 2019 -
FY 2019 -
FY 2020 -
FY 2021 -
FY 2022 -
FY 2023 -
FY 2024 -
FY 2025 -
FY 2026 -
FY 2027 -
FY 2028 -
FY 2029 -
POST YR-
FY 2020 -
U-5543 VARIOUS, VARIABLE MESSAGE SIGNS FOR TRAFFIC CONSTRUCTION FY 2019 -
DURHAM MANAGEMENT ON MAJOR CORRIDORS IN CHAPEL FY 2019 -
ORANGE HILL.
PROJ.CATEGORY TOWN NEEDS ADDITIONAL TIME FOR PLANNING AND
EXEMPT DESIGN. DELAY CONSTRUCTION FROM FY 18 TO FY
19.
U-5841 FRIENDLY AVENUE, WEST OF GREEN VALLEY ROAD RIGHT-OF-WAY FY 2020 -
GUILFORD TO LINDELL ROAD IN GREENSBORO. WIDENING AND UTILITIES FY 2020 -
PROJ.CATEGORY INTERSECTION IMPROVEMENTS. CONSTRUCTION FY 2021 -
DIVISION TO CONFORM TO CURRENTLY PROGRAMMED
FUNDING SOURCE, DELAY RIGHT-OF-WAY FROM FY
19 TO FY 20 AND CONSTRUCTION FROM FY 20 TO FY
21(NOTE: NO CHANGE TO PROJECT DELIVERY
SCHEDULE).
* INDICATES FEDERAL AMENDMENT
$300,000
$30,000
$1,875,000
$2,205,000
$1,597,000
$473,000
$429,000
$429,000
$429,000
$429,000
$429,000
$429,000
$429,000
$429,000
$429,000
$429,000
$2,145,000
$5,900,000
$14,405,000
$786,000
$197,000
$983,000
$250,000
$100,000
$1,250,000
$1,600,000
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(STBGDA)
(L)
(T)
(T)
(T)
Thursday, December 06, 2018 13
ITEM N
HIGHWAY PROGRAM
DIVISION 8
* EB-5872A
SCOTLAND
PROJ.CATEGORY
DIVISION
STIP MODIFICATIONS
SR 1108 (WEST BOULEVARD), SR 1105 (TURNPIKE RIGHT-OF-WAY
ROAD) TO GLASGOW DRIVE AND EAST OF US 15 / US
401 / US 501 TO SUNSET DRIVE IN LAURINBURG. CONSTRUCTION
ADD RIGHT OF WAY IN FY 20 AT THE REQUEST OF
RPO.
* R-2527 NC 24 / NC 27, NC 73 TO TROY BYPASS. WIDEN TO
MONTGOMERY MULTILANES.
PROJ.CATEGORY PROJECT TO UTILIZE BUILD NC BONDS
REGIONAL
* U-5727 US 1/ US 151 US 501, SOUTH OF SR 1198 (BRYAN
LEE DRIVE) TO SR 1237 (CARTHAGE STREET) IN SANFORD
PROJ.CATEGORY UPGRADE TO SUPERSTREET AND RELOCATE NC 78
REGIONAL (TRAMWAY ROAD).
REVISE TERMINI AND SCOPE AT REQUEST OF
DIVISION TO CONFORM TO CURRENT PROJECT
CONFIGURATION.
BUILD NC ROW
RIGHT-OF-WAY
UTILITIES
CONSTRUCTION
FY 2020 -
FY 2020 -
FY 2020 -
FY 2020 -
FY 2019 -
FY 2020 -
FY 2021 -
FY 2022 -
FY 2023 -
FY 2024 -
FY 2025 -
FY 2026 -
FY 2027 -
FY 2028 -
FY 2029 -
POST YR-
FY 2019 -
FY 2019 -
FY 2021 -
FY 2022 -
FY 2023 -
FY 2024 -
$133,000
$33,000
$348,000
$88,000
$602,000
$686,000
$686,000
$686,000
$686,000
$686,000
$686,000
$686,000
$686,000
$686,000
$686,000
$686,000
$2,744,000
$426,000
$1,011,000
$11,550,000
$11,550,000
$11,550,000
$11,550,000
$57,927,000
RIGHT-OF-WAY FY 2019 - $3,600,000
CONSTRUCTION FY 2020 - $8,816,000
FY 2021 - $8,816,000
FY 2022 - $8,816,000
$30,048,000
(TAP)
(L)
(TAP)
(L)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(NHP)
(NHP)
(NHP)
(NHP)
U-5975 US 1/ US 151 US 501, US 151 US 501 (WHITE HILL RIGHT-OF-WAY FY 2020 -$22,957,000 (T)
LEE ROAD) I SR 1179 (ROCKY FORK CHURCH ROADO TO UTILITIES FY 2020 - $2,755,000 (T)
PROJ.CATEGORY SOUTH OF SR 1198 (BRYAN DRIVE). UPGRADE TO CONSTRUCTION FY 2021 -$12,746,000 (T)
REGIONAL SUPERSTREET. $38,458,000
REVISE N.TERMINUS AT DIV. REQUEST. TO ALLOW
ADDITIONAL TIME TO COORDINATE DESIGN, DELAY
RIGHT OF WAY FROM FY 19 TO FY 20. TO CONFORM
TO CURRENTLY PROGRAMMED FUNDING SOURCE,
DELAY CONSTRUCTION FROM FY 20 TO FY 21(NOTE:
NO CHANGE IN LETTING SCHEDULE).
* INDICATES FEDERAL AMENDMENT
Thursday, December 06, 2018 14
ITEM N
HIGHWAY PROGRAM
STIP MODIFICATIONS
DIVISION 9
B-4626 NC 8 I NC 49, REPLACE BRIDGE 790003 AND APPLY RIGHT-OF-WAY FY 2019 - $300,000 (STBG)
ROWAN DECK PRESERVATION TREATEMENT TO BRIDGE UTILITIES FY 2019 - $300,000 (STBG)
PROJ.CATEGORY 790008 OVER YADKIN RIVER AND WINSTON-SALEM CONSTRUCTION FY 2020 - $6,165,000 (STBG)
STATEWIDE SOUTHBOUND RAILROAD. $6,765,000
TO ALLOW ADDITIONAL TIME TO COMPLETE THE
RIGH-OF-WAY PLANS, DELAY RIGHT-OF-WAY FROM
FY 18 TO FY 19, AT REQUEST OF STRUCTURE
MANAGEMENT UNIT.
EB-4020C
FORSYTH
PROJ.CATEGORY
TRANSITION
BRUSITY FORK GREENWAY, LOWERY STREET TO
REYNOLDS PARK ROAD
TO REFLECT CURRENT CITY DELIVERY SCHEDULE,
DELAY CONSTRUCTION FROM FY 19 TO FY 20 AT
REQUEST OF MPO .
CONSTRUCTION FY 2020 - $300,000 (STBG)
FY 2020 - $700,000 (STBGDA)
FY 2020 - $175,000 (L)
$1,175,000
EB-5619
ROWAN
PROJ.CATEGORY
DIVISION
GRANTS CREEK GREENWAY, KELSEY SCOTT PARK TO
CATAWBA COLLEGE. CONSTRUCT MULTIUSE PATH.
PROJECT SPLIT INTO SEGMENTS AT REQUEST OF
MPO AND CITY TO FACILITATE DELIVERY - SEE
FOLLOWING ENTRIES FOR FUNDING AND SCHEDULES.
EB-5619A GRANTS CREEK GREENWAY, VICINITY OF CONSTRUCTION FY 2019 - $134,800 (TAPDA)
ROWAN FORESTDALE DRIVE TO CATAWBA COLLEGE IN FY 2019 - $33,700 (L)
PROJ.CATEGORY SALISBURY. CONSTRUCT LOW-WATER BRIDGE $168,500
DIVISION GREENWAY CONNECTION.
PROJECT BREAK CREATED AT REQUEST OF MPO
AND CITY. ACCELERATE CONSTRUCTION FY 20 TO FY
19 TO FACILITATE DELIVERY.
EB-5619B GRANTS CREEK GREENWAY, KELSEY SCOTT PARK TO
ROWAN VICINITY OF FORESTDALE DRIVE IN SALISBURY.
PROJ.CATEGORY CONSTRUCT MULTIUSE PATH.
DIVISION PROJECT BREAK CREATED AT REQUEST OF MPO
AND CITY TO FACILITATE DELIVERY.
* INDICATES FEDERAL AMENDMENT
RIGHT-OF-WAY
CONSTRUCTION
FY 2019 -
FY 2019 -
FY 2020 -
FY 2020 -
$40,000 (TAPDA)
$10,000 (L)
$660,000 (TAPDA)
$165,000 (L)
$875,000
Thursday, December 06, 2018 15
ITEM N
HIGHWAY PROGRAM
STIP MODIFICATIONS
DIVISION 9
EB-5722 NC 67 (SILAS CREEK PARKWAY), BOLTON STREET TO ENGINEERING
FORSYTH LOCKLAND AVENUE IN WINSTON-SALEM. CONSTRUCT
PROJ.CATEGORY SIDEWALK ON NORTH SIDE TO CONNECT EXISTING
DIVISION SECTIONS. RIGHT-OF-WAY
* EB-5810
FORSYTH
PROJ.CATEGORY
DIVISION
* I-5952
FORSYTH
PROJ.CATEGORY
STATEWIDE
ADD RIGHT OF WAY IN FY 19 NOT PREVIOUSLY
PROGRAMMED, AT REQUEST OF MPO. TO REFLECT CONSTRUCTION
CURRENT TOWN DELIVERY SCHEDULE, DELAY
ENGINEERING FROM FY18 TO FY 19.
VARIOUS, BARBARA JANE AVENUE, BYERLY ROAD, ENGINEERING
AND BARRY STREET IN WINSTON-SALEM. CONSTRUCT
SIDEWALKS. CONSTRUCTION
ADD ENGINEERING IN FY 19 NOT PREVIOUSLY
PROGRAMMED AND DELAY CONSTRUCTION FROM FY
18 TO FY 20, BOTH AT REQUEST OF MPO TO REFLECT
CURRENT TOWN DELIVERY SCHEDULE.
I-40, SR 1101 (HARPER ROAD) IN CLEMMONS TO EAST
OF US 421 / BUSINESS 40 IN WINSTON-SALEM.
PAVEMENT REHABILITATION.
PROJECT BREAK CREATED AT REQUEST OF DIVISION
OFFICE. SEE 1-5952A ENTRY FOR DETAILS. COST
INCREASE EXCEEDING $2 MILLION AND 25%
THRESHOLDS.
FY 2019 -
FY 2019 -
FY 2019 -
FY 2019 -
FY 2019 -
FY 2020 -
FY 2020 -
FY 2019 -
FY 2019 -
FY 2020 -
FY 2020 -
$296,000
$36,000
$83,000
$728,000
$182,000
$360,000
$90,000
$1,775,000
$48,000
$12,000
$176,000
$44,000
$280,000
(STBG)
(TAP)
(L)
(STBG)
(L)
(TAP)
(L)
(STBG)
(L)
(TAP)
(L)
I-5952A i-40, BRIDGE REHABILITATION. CONSTRUCTION FY 2020 - $2,516,000 (NHPIM)
FORSYTH NEW PROJECT BREAK CREATED WITH $2,516,000
PROJ.CATEGORY CONSTRUCTION IN FY 20 AT REQUEST OF DIVISION
STATEWIDE OFFICE FOR SEPARATE LETTING OF BRIDGE
COMPONENT
* INDICATES FEDERAL AMENDMENT
Thursday, December 06, 2018 16
ITEM N
HIGHWAY PROGRAM
STIP MODIFICATIONS
DIVISION 9
* R-2577A US 158, MULTI-LANES NORTH OF US 421 / I-40 RIGHT-OF-WAY
FORSYTH BUSINESS TO SR 1965 (BELEWS CREEK ROAD) UTILITIES
PROJ.CATEGORY COST INCREASE EXCEEDING $2 MILLION AND 25% BUILD NC CONST
REGIONAL THRESHOLDS.
CONSTRUCTION
DIVISION 10
C-5225B CHARLOTTE, TOBY CREEK GREENWAY, ROCKLAND
MECKLENBURG DRIVE TO BLUE ROCK DRIVE.
PROJ.CATEGORY TO ALLOW ADDITIONAL TIME FOR DESIGN DELAY
EXEMPT CONSTRUCTION FROM FY 18 TO FY 19
C-5538
MECKLENBURG
PROJ.CATEGORY
DIVISION
C-5557
CABARRUS
PROJ.CATEGORY
EXEMPT
FY 2020 -
FY 2020 -
FY 2022 -
FY 2023 -
FY 2024 -
FY 2025 -
FY 2026 -
FY 2027 -
FY 2028 -
FY 2029 -
POST YR-
FY 2022 -
FY 2023 -
$7,800,000
$469,000
$2,574,000
$2,574,000
$2,574,000
$2,574,000
$2,574,000
$2,574,000
$2,574,000
$2,574,000
$18,018,000
$7,700,000
$7,700,000
$62,279,000
CONSTRUCTION FY 2019 -
FY 2019 -
CHARLOTTE, INTERSECTION OF TUCKASEEGEE- CONSTRUCTION FY 2019 -
BERRYHILL-THRIFT ROADS IN CHARLOTTE. FY 2019 -
CONSTRUCT A TRAFFIC CIRCLE. FY 2019 -
TO ALLOW ADDITIONAL TIME FOR PLANNING AND
DESIGN DELAY CONSTRUCTION FROM FY 18 TO FY 19
CONCORD, CITY OF CONCORD'S NE SUBSET CONSTRUCTION FY 2019 -
SIDEWALKS. INSTALL SIDEWALKS AT VARIOUS FY 2019 -
LOCATIONS.
TO ALLOW ADDITIONAL TIME FOR PLANNING AND
DESIGN DELAY CONSTRUCTION FROM FY 18 TO FY 19
EB-5775 CORNELIUS, SOUTH PRONG ROCKY RIVER CONSTRUCTION
MECKLENBURG GREENWAY (SOUTH STREET - MAIN STREET).
PROJ.CATEGORY CONSTRUCT GREENWAY.
DIVISION TO ALLOW ADDITIONAL TIME FOR PLANNING AND
DESIGN DELAY CONSTRUCTION FROM FY 18 TO FY 19
AND UPDATE FUNDING
* INDICATES FEDERAL AMENDMENT
$1,240,000
$360,000
$1,600,000
$1,797,000
$1,053,000
$826,000
$3,676,000
$420,000
$105,000
$525,000
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(CMAQ)
(L)
(CMAQ)
(STBGDA)
(L)
(CMAQ)
(L)
FY 2019 - $840,000 (STBGDA)
FY 2019 - $628,000 (TAPDA)
FY 2019 - $367,000 (L)
$1,835,000
Thursday, December 06, 2018 17
ITEM N
HIGHWAY PROGRAM
STIP MODIFICATIONS
DIVISION 10
* EB-5844 KANNAPOLIS, LITTLE TEXAS ROAD, LANE STREET TO ENGINEERING
CABARRUS DALE EARNHARDT BOULEVARD. CONSTRUCT
PROJ.CATEGORY SIDEWALK AND CURB AND GUTTER. RIGHT-OF-WAY
DIVISION TO ALLOW ADDITIONAL TIME FOR PLANNING DELAY
PRELIMINARY ENGINEERING FROM FY 18 TO FY 19 AT CONSTRUCTION
REQUEST OF MPO
FY 2019 -
FY 2019 -
FY 2019 -
FY 2019 -
FY 2020 -
FY 2020 -
FY 2020 -
FY 2020 -
$320,000
$80,000
$320,000
$80,000
$131,000
$1,280,000
$320,000
$33,000
$2,564,000
(TAP)
(L)
(TAP)
(L)
(CMAQ)
(TAP)
(L)
(L)
EB-5931 INDIAN TRAIL, NORTH INDIAN TRAIL ROAD. SOUTH CONSTRUCTION FY 2019 -$2,510,000 (STBGDA)
UNION FORK ROAD TO LIBERTY LANE. CONSTRUCT FY 2019 - $1,351,000 (L)
PROJ.CATEGORY COMPLETE STREET. $3,861,000
DIVISION TO ALLOW ADDITIONAL TIME FOR PLANNING AND
DESIGN DELAY CONSTRUCTION FROM FY 18 TO FY 19
I-5797 I-85, CONCRETE PAVEMENT JOINT SOUTH OF NC 16 CONSTRUCTION FY 2019 - $100,000 (NHPIM)
MECKLENBURG TO CONCRETE PAVEMENT JOINT AT US 29/NC40 $100,000
PROJ.CATEGORY CONNECTOR. RESTRIPE PAVEMENT.
STATEWIDE TO ALLOW ADDITIONAL TIME FOR PLANNING AND
DESIGN DELAY CONSTRUCTION FROM FY 18 TO FY 19
I-5837 I-85, GASTON COUNTY LINE TO 0.7 MILES NORTH OF CONSTRUCTION FY 2020 - $1,800,000 (NHPIM)
MECKLENBURG GASTON COUNTY LINE. INCLUDES RAMPS FROM $1,800,000
PROJ.CATEGORY GASTON COUNTY LINE TO GLENWOOD AVENUE.
STATEWIDE PAVEMENT REHABILITATION.
TO ALLOW ADDITIONAL TIME FOR PLANNING AND
DESIGN DELAY CONSTRUCTION FROM FY 19 TO FY 20
* I-5902 I-485, SR 1786 TO NC 27. BRIDGE REHABILITATION. CONSTRUCTION FY 2020 - $900,000 (NHPIM)
MECKLENBURG ACCELERATE CONSTRUCTION FROM FY 22 TO FY 20 $900,000
PROJ.CATEGORY AT DIVISION REQUEST
STATEWIDE
* I-5905 I-85, 0.2 MILE WEST OF NC 16 (BROOKSHIRE CONSTRUCTION FY 2020 -$14,000,000 (NHPIM)
MECKLENBURG BOULEVARD) TO CONCRETE PAVEMENT JOINT AT US $14,000,000
PROJ.CATEGORY 291NC 49 CONNECTOR. PAVEMENT REHABILITATION.
STATEWIDE ACCELERATE CONSTRUCTION FROM FY 23 TO FY 20
AT REQUEST OF DIVISION
* INDICATES FEDERAL AMENDMENT
Thursday, December 06, 2018 18
ITEM N
HIGHWAY PROGRAM
STIP MODIFICATIONS
DIVISION 10
U-5108
MECKLENBURG
PROJ.CATEGORY
TRANSITION
* U-6032
CABARRUS
MECKLENBURG
PROJ.CATEGORY
DIVISION
DIVISION 12
* R-3603A
ALEXANDER
CATAWBA
PROJ.CATEGORY
DIVISION
NORTHCROSS DRIVE EXTENSION, NC 73 IN RIGHT-OF-WAY
HUNTERSVILLE TO WESTMORELAND ROAD IN
CORNELIUS. CONSTRUCT ROAD ON NEW LOCATION.
TO ALLOW ADDITIONAL TIME FOR PLANNING DELAY
RIGHT-OF-WAY FROM FY 18 TO FY 19
SR 2464 (ODELL SCHOOL ROAD), I-485 TO CONCORD
MILLS BOULEVARD. WIDEN TO MULTI-LANES DIVIDED.
COST INCREASE EXCEEDING $2 MILLION AND 25%
THRESHOLDS.
CONSTRUCTION
BUILD NC ROW
RIGHT-OF-WAY
UTILITIES
CONSTRUCTION
NC 127, SR 1400 (CLONINGER MILL ROAD) TO SR 1156 RIGHT-OF-WAY
(RICHEY ROAD). UTILITIES
COST INCREASE EXCEEDING $2 MILLION AND 25% CONSTRUCTION
THRESHOLDS.
* INDICATES FEDERAL AMENDMENT
FY 2019 -
FY 2019 -
FY 2019 -
FY 2020 -
FY 2020 -
FY 2020 -
FY 2020 -
FY 2021 -
FY 2022 -
FY 2023 -
FY 2024 -
FY 2025 -
FY 2026 -
FY 2027 -
FY 2028 -
FY 2029 -
POST YR-
FY 2020 -
FY 2020 -
FY 2021 -
FY 2022 -
FY 2023 -
$955,000
$500,000
$489,000
$4,765,000
$1,000,000
$2,023,000
$9,732,000
$86,000
$86,000
$86,000
$86,000
$86,000
$86,000
$86,000
$86,000
$86,000
$86,000
$430,000
$1,400,000
$500,000
$8,333,000
$8,333,000
$8,334,000
$28,190,000
(STBGDA)
(BA)
(L)
(STBG)
(BA)
(L)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
FY 2021 - $3,400,000 (T)
FY 2021 - $100,000 (T)
FY 2023 - $12,967,000 (T)
FY 2024 - $12,966,000 (T)
FY 2025 - $12,967,000 (T)
$42,400,000
Thursday, December 06, 2018 19
ITEM N
HIGHWAY PROGRAM
STIP MODIFICATIONS
DIVISION 12
R-5100A
IREDELL
PROJ.CATEGORY
DIVISION
* U-2221 C
CLEVELAND
* W-5212DIV
CATAWBA
IREDELL
PROJ.CATEGORY
DIVISION
DIVISION 13
B-5876
RUTHERFORD
PROJ.CATEGORY
STATEWIDE
SR 1109 (WILLIAMSON ROAD), I-77 TO SR 1100 BUILD NC ROW
(BRAWLEY SCHOOL ROAD). WIDEN TO MULTI-LANES.
PROJECT TO UTILIZE BUILD NC BONDS
NC 180, SR 2052 TO NC 150.
COST INCREASE EXCEEDING $2 MILLION AND 25%
THRESHOLDS.
VARIOUS, DIVISION 12 RUMBLE STRIPS, GUARDRAIL,
SAFETY AND LIGHTING IMPROVEMENTS AT SELECTED
LOCATIONS IN THE DIVISION CATEGORY.
ADD RIGHT-OF-WAY IN FY 19 AND FY 20 AND
CONSTRUCTION IN FY 19 AND FY 20 NOT PREVIOUSLY
PROGRAMMED.
RIGHT-OF-WAY
UTILITIES
CONSTRUCTION
FY 2019 -
FY 2020 -
FY 2021 -
FY 2022 -
FY 2023 -
FY 2024 -
FY 2025 -
FY 2026 -
FY 2027 -
FY 2028 -
FY 2029 -
POST YR-
FY 2019 -
FY 2019 -
FY 2020 -
FY 2021 -
FY 2022 -
FY 2023 -
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
$600,000
$600,000
$600,000
$600,000
$600,000
$600,000
$600,000
$600,000
$600,000
$600,000
$600,000
$2,400,000
$1,000,000
$500,000
$500,000
$10,100,000
$10,100,000
$10,200,000
$41,400,000
RIGHT-OF-WAY FY 2023 - $7,600,000
UTILITIES FY 2023 - $900,000
CONSTRUCTION FY 2025 - $14,800,000
$23,300,000
RIGHT-OF-WAY
CONSTRUCTION
US 74, REPLACE BRIDGE 800083 AND BRIDGE 800084 RIGHT-OF-WAY
OVER SECOND BROAD RIVER. CONSTRUCTION
ACCELERATE RIGHT-OF-WAY FROM FY 20 TO FY 19
AND CONSTRUCTION FROM FY 21 TO FY 20 AFTER
PRESCREENING AND SCOPING WITH FIRM. PROJECT
IS NO LONGER COMBINED WITH 8-5871
* INDICATES FEDERAL AMENDMENT
(T)
(T)
(T)
FY 2019 - $50,000 (HSIP)
FY 2020 - $50,000 (HSIP)
FY 2019 - $2,500,000 (HSIP)
FY 2020 - $2,500,000 (HSIP)
$5,100,000
FY 2019 - $440,000 (STBG)
FY 2020 - $4,400,000 (STBG)
FY 2021 - $4,400,000 (STBG)
$9,240,000
Thursday, December 06, 2018 20
ITEM N
HIGHWAY PROGRAM
STIP MODIFICATIONS
DIVISION 13
EB-5547A BLACK MOUNTAIN RIVERWALK GREENWAY, ENGINEERING
BUNCOMBE CONSTRUCT MULTI-USE PATH FROM EXISTING FLAT
PROJ.CATEGORY CREEK GREENWAY TRAILHEAD NORTH OF US 70 TO RIGHT-OF-WAY
DIVISION BLACK MOUNTAIN AVENUE.
* EB-5925
BUNCOMBE
PROJ.CATEGORY
DIVISION
* U-5019A
BUNCOMBE
PROJ.CATEGORY
DIVISION
* U-50196
BUNCOMBE
PROJ.CATEGORY
DIVISION
TO ALLOW ADDITIONAL TIME FOR PLANNING AND CONSTRUCTION
DESIGN DELAY RIGHT-OF-WAY FROM FY 18 TO FY 19
AND CONSTRUCTION FROM FY 19 TO FY 20
BEAVERDAM CREEK GREENWAY, NC 251 TO US 25. ENGINEERING
CONSTRUCT MULTI-USE PATH.
ADD PRELIMINARYENGINEERING IN FY 19 NOT CONSTRUCTION
PREVIOUSLY PROGRAMMED AND TO ALLOW TIME
FOR PLANNING AND DESIGN DELAY CONSTRUCTION
FROM FY 2018 TO FY 2020 AT REQUEST OF MPO
RIVERWAY MULTI-MODAL NETWORK, TOWN BRANCH CONSTRUCTION
GREENWAY
DELAY CONSTRUCTION FROM FY 20 TO FY 21 AT
REQUEST OF MPO.
FY 2018 -
FY 2018 -
FY 2019 -
FY 2019 -
FY 2020 -
FY 2020 -
FY 2020 -
$487,000
$122,000
$80,000
$20,000
$2,300,000
$334,000
$659,000
$4,002,000
(STBGDA)
(L)
(STBGDA)
(L)
(STBG)
(STBGDA)
(L)
FY 2019 - $600,000 (STBGDA)
FY 2019 - $150,000 (L)
FY 2020 - $1,600,000 (STBGDA)
FY 2020 - $400,000 (L)
$2,750,000
FY 2021 - $3,420,000 (STBGDA)
FY 2021 - $855,000 (L)
$4,275,000
RIVERWAY MULTI-MODAL NETWORK, FRENCH BROAD CONSTRUCTION FY 2019 - $4,000,000 (STBGDA)
RIVER WEST GREENWAY, FRENCH BROAD RIVER FY 2019 - $1,000,000 (L)
PARK TO HAYWOOD ROAD. $5,000,000
ACCELERATE CONSTRUCTION FROM FY 21 TO FY 19
AT REQUEST OF MPO.
U-5833 SR 2241 (OAK STREET), SR 2159 (PINE RIDGE ROAD)
RUTHERFORD TO US 74. WIDEN EXISTINGoij ROADWAY.
PROJ.CATEGORY PROJECT TO UTILIZE BUILD NC BONDS
DIVISION
* INDICATES FEDERAL AMENDMENT
BUILD NC CONST FY 2019 -
FY 2020 -
FY 2021 -
FY 2022 -
FY 2023 -
FY 2024 -
FY 2025 -
FY 2026 -
FY 2027 -
FY 2028 -
FY 2029 -
POST YR-
CONSTRUCTION FY 2019 -
$429,000
$429,000
$429,000
$429,000
$429,000
$429,000
$429,000
$429,000
$429,000
$429,000
$429,000
$1,716,000
$300,000
$6,735,000
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
Thursday, December 06, 2018 21
ITEM N
HIGHWAY PROGRAM
STIP MODIFICATIONS
DIVISION 13
U-5834
BUNCOMBE
PROJ.CATEGORY
DIVISION
* W-5213DIV
BUNCOMBE
PROJ.CATEGORY
DIVISION
DIVISION 14
SR 3116 (MILLS GAP ROAD), US 25 (HENDERSONVILLE RIGHT-OF-WAY
ROAD) TO SR 3157 (WESTON ROAD). UPGRADE
EXISTING ROADWAY.
TO ALLOW ADDITIONAL TIME FOR PLANNING DELAY
RIGHT-OF-WAY FROM FY 18 TO FY 19
VARIOUS, DIVISION 13 RUMBLE STRIPS, GUARDRAIL,
SAFETY AND LIGHTING IMPROVEMENTS AT SELECTED
LOCATIONS IN THE DIVISION CATEGORY.
ADD RIGHT-OF-WAY IN FY 19 AND FY 20 AND
CONSTRUCTION IN FY 19 AND FY 20 NOT PREVIOUSLY
PROGRAMMED.
CONSTRUCTION
RIGHT-OF-WAY
CONSTRUCTION
FY 2019 - $6,167,000 (T)
FY 2020 - $6,167,000 (T)
FY 2021 - $6,166,000 (T)
FY 2021 - $3,000,000 (T)
$21,500,000
FY 2019 - $50,000 (HSIP)
FY 2020 - $50,000 (HSIP)
FY 2019 - $700,000 (HSIP)
FY 2020 - $700,000 (HSIP)
$1,500,000
* A-0011C NC 69, GEORGIA STATE LINE TO US 64 (HAYESVILLE RIGHT-OF-WAY FY 2018 - $8,300,000 (APD)
CLAY BYPASS). WIDEN TO FOUR-LANES CONSTRUCTION FY 2020 -$18,750,000 (APD)
PROJ.CATEGORY COST INCREASE EXCEEDING $2 MILLION AND 25% FY 2021 -$18,750,000 (APD)
EXEMPT THRESHOLDS. $45,800,000
B-6031
JACKSON
PROJ.CATEGORY
DIVISION
B-6032
JACKSON
PROJ.CATEGORY
DIVISION
SR 1300 (PUMPKINTOWN ROAD), REPLACE BRIDGE RIGHT-OF-WAY FY 2019 -
490069 OVER SAVANNAH CREEK. CONSTRUCTION FY 2021 -
TO ALLOW ADDITIONAL TIME FOR PLANNING AND
DESIGN DELAY CONSTRUCTION FROM FY 20 TO FY 21
AT REQUEST OF DIVISION
SR 1397 (THOMAS VALLEY ROAD), REPLACE BRIDGE RIGHT-OF-WAY FY 2019 -
490144 OVER NATIONS CREEK. CONSTRUCTION FY 2021 -
TO ALLOW ADDITIONAL TIME FOR PLANNING AND
DESIGN DELAY CONSTRUCTION FROM FY 20 TO FY 21
AT REQUEST OF DIVISION
B-6033 SR 1445 (LEE BUMGARNER ROAD), REPLACE BRIDGE RIGHT-OF-WAY FY 2019 -
JACKSON 490129 OVER SCOTT CREEK. CONSTRUCTION FY 2021 -
PROJ.CATEGORY TO ALLOW ADDITIONAL TIME FOR PLANNING AND
DIVISION DESIGN DELAY CONSTRUCTION FROM FY 20 TO FY 21
AT REQUEST OF DIVISION
* INDICATES FEDERAL AMENDMENT
$80,000
$800,000
$880,000
$50,000
$500,000
$550,000
$120,000
$1,200,000
$1,320,000
(STBGOFF)
(STBGOFF)
(STBGOFF)
(STBGOFF)
(STBGOFF)
(STBGOFF)
Thursday, December 06, 2018 22
ITEM N
HIGHWAY PROGRAM
STIP MODIFICATIONS
DIVISION 14
B-6034 SR 1300 (PUMPKINTOWN ROAD), REPLACE BRIDGE RIGHT-OF-WAY FY 2019 - $80,000 (STBGOFF)
JACKSON 490065 OVER SAVANNAH CREEK. CONSTRUCTION FY 2021 - $800,000 (STBGOFF)
PROJ.CATEGORY TO ALLOW ADDITIONAL TIME FOR PLANNING AND $880,000
DIVISION DESIGN DELAY CONSTRUCTION FROM FY 20 TO FY 21
AT REQUEST OF DIVISION
B-6035 SR 1738 (HOOPER CEMETERY ROAD), REPLACE RIGHT-OF-WAY FY 2019 - $70,000 (STBGOFF)
JACKSON BRIDGE 490203 OVER CANEY FORK. CONSTRUCTION FY 2021 - $700,000 (STBGOFF)
PROJ.CATEGORY TO ALLOW ADDITIONAL TIME FOR PLANNING AND $770,000
DIVISION DESIGN DELAY CONSTRUCTION FROM FY 20 TO FY 21
AT REQUEST OF DIVISION
B-6036 SR 1737 (CANEY FORK ROAD), REPLACE BRIDGE RIGHT-OF-WAY FY 2019 - $70,000 (STBGOFF)
JACKSON 490081 OVER JOHNS CREEK. CONSTRUCTION FY 2021 - $700,000 (STBGOFF)
PROJ.CATEGORY TO ALLOW ADDITIONAL TIME FOR PLANNING AND $770,000
DIVISION DESIGN DELAY CONSTRUCTION FROM FY 20 TO FY 21
AT REQUEST OF DIVISION
* I-5922 I-40, TENNESSEE STATE LINE TO MILEMARKER 7. CONSTRUCTION FY 2019 - $2,673,000 (STBGIM)
HAYWOOD PAVEMENT REHABILITATION. FY 2020 - $2,673,000 (STBGIM)
PROJ.CATEGORY ACCELERATE CONSTRUCTION FROM FY 22 TO FY 19 $5,346,000
STATEWIDE AT REQUEST OF DIVISION
* I-5923 I-40, MILEMARKER 7 TO MILEMARKER 15. PAVEMENT CONSTRUCTION FY 2019 -$2,344,000 (STBGIM)
HAYWOOD REHABILITATION. FY 2020 - $2,344,000 (STBGIM)
PROJ.CATEGORY qCCELERATE CONSTRUCTION FROM FY 22 TO FY 19 $4,688,000
STATEWIDE AT REQUEST OF DIVISION
* R-25886 NC 191, SR 1381 (MOUNTAIN ROAD) TO NC 280 SOUTH
HENDERSON OF MILLS RIVER.
PROJ.CATEGORY ACCELERATE CONSTRUCTION FROM FY 22 TO FY 21
DIVISION PER DIVISION
RIGHT-OF-WAY
UTILITIES
CONSTRUCTION
FY 2020 - $2,250,000 (STBG)
FY 2021 - $2,250,000 (STBG)
FY 2020 - $500,000 (STBG)
FY 2022 - $14,500,000 (STBG)
FY 2023 - $14,500,000 (STBG)
FY 2024 - $14,500,000 (STBG)
$48,500,000
* INDICATES FEDERAL AMENDMENT
Thursday, December 06, 2018 23
ITEM N
HIGHWAY PROGRAM
STIP MODIFICATIONS
DIVISION 14
R-4751 US 19, SR 1152 (HUGHES BRANCH ROAD) IN BRYSON RIGHT-OF-WAY FY 2020 - $400,000 (T)
SWAIN CITY TO SR 1195 (US 19A). MODERNIZE ROADWAY. UTILITIES FY 2020 - $100,000 (T)
PROJ.CATEGORY TO ALLOW ADDITIONAL TIME FOR PLANNING DELAY CONSTRUCTION FY 2021 - $8,500,000 (T)
REGIONAL RIGHT-OF-WAY FROM FY 19 TO FY 20 $9,000,000
* R-5799 US 64, US 276, NC 280, US 64, US 276, NC 280 AND US RIGHT-OF-WAY FY 2020 - $7,100,000 (T)
TRANSYLVANIA 64. CONSTRUCT INTERSECTION IMPROVEMENTS. UTILITIES FY 2020 - $100,000 (T)
PROJ.CATEGORY COST INCREASE EXCEEDING $2 MILLION AND 25% CONSTRUCTION FY 2021 -$6,400,000 (T)
REGIONAL THRESHOLDS. $13,600,000
U-5840 SR 1547 (OLD AIRPORT ROAD), US 25 TO MILLS GAP
HENDERSON ROAD. WIDEN ROADWAY.
PROJ.CATEGORY PROJECT TO UTILIZE BUILD NC BONDS
DIVISION
BUILD NC CONST
CONSTRUCTION
FY 2019 -
FY 2020 -
FY 2021 -
FY 2022 -
FY 2023 -
FY 2024 -
FY 2025 -
FY 2026 -
FY 2027 -
FY 2028 -
FY 2029 -
POST YR-
FY 2019 -
$600,000
$600,000
$600,000
$600,000
$600,000
$600,000
$600,000
$600,000
$600,000
$600,000
$600,000
$2,400,000
$200,000
$9,200,000
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
(T)
STATEWIDE
* SR-5001 VARIOUS, SAFE ROUTES TO SCHOOL PROGRAM. CONSTRUCTION 2019 $500,000 (SRTS)
STATEWIDE PROJECTS TO IMPROVE SAFETY, REDUCE TRAFFIC, $500,000
PROJ.CATEGORY FUEL CONSUMPTION AND AIR POLLUTION IN VICINITY
DIVISION OF SCHOOLS.
ADD CONSTRUCTION IN FY 19 NOT PREVIOUSLY
PROGRAMMED.
* INDICATES FEDERAL AMENDMENT
Thursday, December 06, 2018 24
ITEM N
HIGHWAY PROGRAM
STIP DELETIONS
DIVISION 1
* F-5702D
HYDE
PROJ.CATEGORY
DIVISION
DIVISION 2
* B-6045
PAMLICO
PROJ.CATEGORY
DIVISION
DIVISION 4
P-5711 B
EDGECOMBE
NASH
PROJ.CATEGORY
STATEWIDE
DIVISION 7
* EL-4828B
ORANGE
ORANGE
PROJ.CATEGORY
TRANSITION
NC 12, CONSTRUCT TRANSIT SHELTERSIBENCHES CONSTRUCTION FY 2018 - $110,000 (0)
AND TRANSIT VEHICLES $110,000
DELETE, WORK TO BE ACCOMPLISHED UNDER
OTHER STATE FUNDS.
SR 1302 (JANERIO ROAD), REPLACE BRIDGE 680057 RIGHT-OF-WAY FY 2022 - $600,000 (STBGOFF)
OVER DAWSON CREEK. CONSTRUCTION FY 2023 - $6,000,000 (STBGOFF)
DELETE, WORK TO BE ACCOMPLISHED UNDER $6,600,000
PROJECT 8-5995.
CSX A LINE, DOUBLE TRACK IMPROVEMENTS FROM CONSTRUCTION FY 2018 -$19,695,000 (T)
MILEPOST A105 TO A117 FY 2019 -$19,695,000 (T)
DELETE, WORK TO BE ACCOMPLISHED UNDER $39,390,000
PROJECT P-5711A.
MORGAN CREEK GREENWAY, PHASE 2 CONSTRUCTION FY 2018 - $730,000 (TAPDA)
DELETE PROJECT BREAK AT THE REQUEST OF TOWN FY 2018 - $182,000 (L)
AND DIVISION OFFICE. $912,000
DIVISION 9
* C-5216 SR 3346 (SOUTH MAIN STREET), EXTEND SIDEWALKS
DAVIDSON ON SOUTH MAIN STREET AND PROVIDE WIDE PAVED
PROJ.CATEGORY SHOULDERS ON ANNA LEWIS DRIVE AND EMERGENCY
EXEMPT DRIVE TO PROVIDE BICYCLE ACCESS TO LEXINGTON
MEMORIAL HOSPITAL IN LEXINGTON.
DELETE AT REQUEST OF MPO; PROJECT DECLINED
BY CITY.
* INDICATES FEDERAL AMENDMENT
ENGINEERING
CONSTRUCTION
FY 2018 -
FY 2018 -
FY 2019 -
FY 2019 -
$107,000 (CMAQ)
$27,000 (L)
$481,000 (CMAQ)
$120,000 (L)
$735,000
Thursday, December 06, 2018 25
ITEM N
DIVISION 9
* G5217
DAVIDSON
PROJ.CATEGORY
EXEMPT
DIVISION 10
* G5502
CABARRUS
PROJ.CATEGORY
EXEMPT
HIGHWAY PROGRAM
STIP DELETIONS
VARIOUS, BIKE AND PEDESTRIAN IMPROVEMENTS IN
VICINITY OF SCHOOL. BISECKER AND MIZE ROADS,
PROVIDE WIDE PAVED SHOULDERS AND CONSTRUCT
SIDE-WALKS ON CORNELIA STREET AND HILLSIDE
DRIVE IN LEXINGTON.
DELETE AT REQUEST OF MPO; PROJECT DECLINED
BY CITY.
LITTLE TEXAS ROAD, LITTLE TEXAS ROAD IN
KANNAPOLIS, FOREST PARK DRIVE TO EXISTING
SIDEWALK SOUTH OF MISSION TRIPP STREET.
CONSTRUCT 800 FEET OF SIDEWALK.
DELETE, WORK TO BE ACCOMPLISHED UNDER
PROJECT EB-5844
CONSTRUCTION FY 2019 -
FY 2019 -
$152,000 (CMAQ)
$38,000 (L)
$190,000
DIVISION 14
* C-5151 EASTERN BAND OF CHEROKEE INDIANS (EBCI), GREAT CONSTRUCTION FY 2018 - $177,000 (CMAQ)
HAYWOOD SMOKIES NATIONAL PARK. CONSTRUCT A MIXED-USE FY 2018 - $65,000 (L)
SWAIN PATHWAY. $242,000
PROJ.CATEGORY DELETE AT THE REQUEST OF DIVISION.
EXEMPT
ITEM N SUMMARY
ADDITION S
MODIFICATION S
DELETION S
* INDICATES FEDERAL AMENDMENT
13 PROJECTS
96 PROJECTS
8 PROJECTS
117 PROJECTS
$12,900,000
$48,179,000
($35,279,000)
Thursday, December 06, 2018 26
Item O
Page 1 of 11
NCDOT December 6, 2018 Board of Transportation Agenda
SUMMARY: There are a total of 28 agreements for approval by the Board of Transportation.
Division 1
Dare County This Project consists of improvements on SR 1217
R-5014 (Colington Road) from the dead end road to US 158
41162.3.1 (Croatan Highway) in Kill Devil Hills. This Utility
Construction Agreement (UCA) is for the adjustment and/or
relocation of water lines. The County is responsible for
actual costs of the relocation work. The estimated
reimbursement is $463,064.47.
Division 2
Contentnea Metropolitan Sewer
District
Pitt County
R-2250
34411.3.7
This Design-Build Project consists of improvements on
US 264 (Greenville Southwest Bypass) from south of
SR 1149 (Old NC 11) to existing US 264. This Utility
Construction Agreement (UCA) is for Betterments. The
District has requested an upgrade of the existing 14"
sanitary sewer force main to a proposed 20". The District
shall reimburse the Department a lump sum payment of
$82,965.63 for the utility work.
NC Wildlife Resources This Project consists of the construction of pedestrian
Commission facilities, boardwalk and sidewalk along NC 58 to provide
Jones County access to Brock's Mill Pond in Jones County. The
48240 Commission shall perform the work. The Department shall
participate in the construction costs of the project up to a
maximum amount of $69,525. Costs which exceed this
amount shall be borne by the Commission.
Division 3
City of Wilmington This Project consists of construction of a bus pull-out and
New Hanover County loading area along Shipyard Boulevard including sidewalk
U-5534N at Rutledge Drive to Vance Street in Wilmington. This
44096.1.15 Supplemental Agreement is to increase funding for the
44096.2.15 Project. The Department's original participation was
44096.3.15 $240,000 in STP-DA funds. The Department shall
reimburse the Municipality an additional $80,000 (80%) of
approved eligible costs from STBGP-DA funds. The
Municipality will provide $20,000 (20%) as a local match.
The Municipality is responsible for all phases of the Project
and all costs that exceed the total available funding.
December 6, 2018
Item O
Page 2 of 11
NCDOT December 6, 2018 Board of Transportation Agenda
Division 5
Town of Morrisville This Project consists of the design and construction of a
Wake County greenway trail connecting residential neighborhoods to
C-5168 retail and employment areas in Morrisville. This
46233.1.1 Supplemental Agreement is to increase the funding for the
46233.2.1 Project. The Department's original participation was
46233.3.1 $4,203,816 in CMAQ and TAP funds. The Department
agrees to reimburse the Municipality an additional
$129,786 (50%) in TAP funds. The Municipality's original
participation was $1,655,680. The Municipality will provide
$129,786 (50%) as their additional local match. The total
estimated cost of the Project is $6,119,068. Any costs that
exceed the total available funding will be the responsibility
of the Municipality.
Town of Wake Forest This Project consists of improvements to SR 1930 (Stadium
Wake County Drive), from US 1 to SR 1954 (North Wingate Street) in
U-5515 Wake Forest, including widening, sidewalk, bicycle lanes
55056.1.1 and pedestrian/transit amenities in Wake Forest. This
55056.2.F1 Supplemental Agreement is to add new funding to the
55056.3.1 Project. The Department's original participation was
$3,562,400 in STP-DA funds and $100,000 in High
Impact/Low Cost State funds. The Department agrees to
reimburse the Municipality an additional $3,038,750 (50%)
of STBG-DA funds. The Municipality's original participation
was $890,600. The Municipality will provide $3,038,750
(50%) as their additional local match. The total estimated
cost of the Project is $10,630,500. Any costs that exceed
the total available funding will be the responsibility of the
Municipality.
Town of Holly Springs This Project consists of the construction of a superstreet on
Wake County NC 55 Bypass at Sportsmanship Way in Holly Springs.
U-5118JB This Supplemental Agreement is to increase the funding for
42379.3.35 the Project. The Department's original participation was
$1,200,000 in STP-DA funds. The Department agrees to
reimburse the Municipality an additional $577,967 (50%) of
STBG-DA funds. The Municipality's original match was
$300,000. The Municipality will provide $577,967 (50%) as
their additional local match. The total estimated cost of the
Project is $2,655,934. Any costs that exceed the total
available funding will be the responsibility of the
Municipality.
December 6, 2018
Item O
Page 3 of 11
NCDOT December 6, 2018 Board of Transportation Agenda
Division 5, con't.
City of Durham and Durham- This Project consists of the development of a web-based
Chapel Hill-Carrboro interactive mapping application tool for the MPO congestion
Metropolitan Planning management process to update the Comprehensive
Organization (MPO) Transportation Plan and monitor the Metropolitan
Durham County Transportation Plan performance measures. The
M-0528CC Department shall reimburse 100% of eligible expenses
48232.3.3 incurred by the MPO up to a maximum amount of
$150,000. The Municipality shall provide all costs that
exceed the total available funding.
City of Durham and Durham- This Project consists of the development and update of the
Chapel Hill-Carrboro MPO-automated and electronic TIP Funding spatial
Metropolitan Planning database and application portal that will link the
Organization (MPO) Comprehensive Transportation Plan and monitor the
Durham County Metropolitan Transportation Plan performance measures.
M-0528CD The Department shall reimburse 100% of eligible expenses
48232.3.4 incurred by the MPO up to a maximum amount of
$150,000. The Municipality shall provide all costs that
exceed the total available funding.
City of Durham This Project consists of the construction of bicycle lanes
Durham County and/or sidewalks along University Dr (SR 2220, NC 751,
EB-5514 SR 1183) from SR 2220 (Old Chapel Hill Rd) to SR 1158
50030.3.1 (W Cornwallis Rd). This Supplemental Agreement is to
increase the funding for the Project. The Department's
original participation was $1,025,000 using $820,000 in
STP-EB federal funds and $205,000 as state match. The
Department agrees to reimburse the Municipality an
additional $905,611 with $724,489 (80%) of STBG federal
funds and $181,122 (20%) as a state match. The total
estimated cost of the Project is $1,930,611. Any costs that
exceed the total available funding will be the responsibility
of the Municipality.
US Department of This Cooperative Agreement with US Department of
Transportation (USDOT) Transportation (USDOT) using FY 17 TIGER funds will
Wake County partially finance a contract for the Department to construct
U-4437 a railroad grade separation and improvements at the
35868.3.4 intersection of Blue Ridge Road and Hillsborough Street in
Raleigh. The USDOT shall participate in the amount of
$19,900,000 using TIGER funds and the Department will
utilize $37,198,674 in other federal funds, for a total federal
share of $57,098,674 (80°/a). The Department will provide
$14,274,669 (20%) in State funds as a match, for a total
project amount of $71,373,343.
December 6, 2018
Item O
Page 4 of 11
NCDOT December 6, 2018 Board of Transportation Agenda
Division 6
Fayetteville Public Works This Project consists of construction, design, signal
Commission revisions, and right of way and easement acquisition for a
Cumberland County right turn lane into a proposed business located on NC
W-5206AA Highway 59 in Fayetteville. The Municipality will relocate
sewer and water lines and the Department will participate in
the actual construction costs of the utility work. The
estimated cost is $24,000.
Fayetteville Public Works This Project consists of construction of the Fayetteville
Commission Outer Loop from South of US 401 to South of SR 1400
Cumberland County (Cliffdale Road). This Utility Agreement is to design the
U-2519CA preliminary construction plans for a Betterment of the water
34817.3.13 line from 16" to 24" as part of the utility work for the Project.
The lump sum cost to the Municipality is $29,522.12.
Division 7
City of High Point This Project consists of the installation of sidewalk in six (6)
Guilford County locations within the city limits of High Point. The six (6)
C-5609L locations include 1)James Road between E Hartley Drive
43731.2.10 (SR 4143) and Oakview Road, 2) Eastchester Drive (SR68)
43731.3.10 between Hickswood Road (SR 1523) and Ramsay Street,
3) N Main Street (SR 1009) between south of Dayton
Avenue and Old Winston Road, 4) Fairfield Road (SR 610
and SR 1300) between Plaza Lane and Brentwood Street,
5) Eastchester Drive (SR 68) between N Main Street (SR
1009) and Johnson Street and 6) Eastchester Drive (SR
68) between E Hartley Drive (SR 4143)/University Parkway
and Centennial Street. The Department shall reimburse
80% of eligible expenses incurred by the Municipality up to
a maximum amount of $1,564,080. The Municipality shall
provide the 20% match ($391,020) and all costs that
exceed the total available funding.
Division 8
Town of Mount Gilead This Project consists of the construction of a 5' sidewalk on
Montgomery County one side of NC 731 to connect with Stanback Park in Mount
EB-5899 Gilead. The Department shall reimburse the Municipality
47257.1.1 80% ($108,000) of approved eligible costs from TAP funds.
47257.3.3 The Municipality will provide 20% ($27,000) as a local
match. The Municipality is responsible for all phases of the
Project and all costs that exceed the total available funding.
December 6, 2018
Item O
Page 5 of 11
NCDOT December 6, 2018 Board of Transportation Agenda
Division 9
City of Winston-Salem This Municipal Operations Agreement (Schedule C)
Forsyth County provides for the municipal operation of State-owned traffic
9.1034SM signals at certain intersections on the State Highway
9.2034SM System within or near the City of Winston-Salem. The
Department shall pay the Municipality an annual approved
amount for the traffic signals operation, maintenance, and
administrative costs as per the Agreement.
City of Winston-Salem This Municipal Operations Agreement (Schedule D)
Forsyth County provides for the municipal operation of the computerized
9.1034SM traffic control system, including timing plans, electric traffic
9.2034SM signals and other traffic control devices on the State
Highway System Streets located within or near the City of
Winston-Salem. The Department shall pay the Municipality
an annual approved cost for the traffic control system
operation, maintenance, and administrative costs as per
the Agreement.
City of Salisbury The Project will relocate a portion of Klumac Road (SR
Rowan County 2541), under the mainline track of NSR/NCRR, to tie into
U-3459 existing Klumac Road (SR 2541) south of Kentucky Street
53500.3.STR01T4 and eliminate the need for the at-grade crossing on Klumac
Road (SR 2541). At the request of the Municipality,
NCDOT has agreed to construct sidewalks on the newly
constructed Klumac Road. The Municipality has agreed to
accept ownership and maintenance responsibilities for
sidewalks on the newly relocated portion of Klumac Road
from US 29 (Main Street) to south of Kentucky Street where
it ties into the existing Klumac Road (SR 2541) and the
remaining portion of old Klumac Road (SR 2541) from US
29 to south of Kentucky Street where it ties into the
relocated Klumac Road, at no expense or liability
whatsoever to NCDOT. The Municipality shall reimburse
NCDOT thirty percent (30%), estimated to be $35,000.00,
of the actual cost of constructing the sidewalks. Upon
completion of the Project, the remaining portion of old
Klumac Road (SR 2541) from US 29 (Main Street) to south
of Kentucky Street, where it ties into the new Klumac Road,
shall be owned and maintained by the Municipality, at no
expense to the Department. The relocated portion of
Klumac Road shall be owned and maintained by the
Department, at no expense to the
Municipality. This agenda item supersedes the item that
was approved by the BOT on June 7, 2012.
December 6, 2018
Item O
Page 6 of 11
NCDOT December 6, 2018 Board of Transportation Agenda
Division 10
City of Charlotte This Project consists of the UNC Charlotte Adjacent
Mecklenburg County Arterials Multimodal Solutions Study. The Municipality is
M-0528BN responsible for the Project. The Department shall
48232.2.14 reimburse eligible costs up to $40,000 (80%) in
SPR funding and $10,000 (20%) in state funding. The
Municipality shall be responsible for all costs that exceed
the total available funding of $50,000.
City of Albemarle This Project consists of improvements on NC 24-27 from
Stanly County Bird Avenue in Albemarle to west of the Pee Dee River.
R-2530B This Utility Construction Agreement (UCA) is for the
34446.3.4 adjustment and/or relocation of water and sewer lines. The
Municipality shall be responsible for actual costs of the
relocation work. The estimated cost is $1,181,029.25.
City of Charlotte This Project consists of a feasibility study for improvements
Mecklenburg County to Providence Road (NC 16) from Alexander Road/Rea
M-0522 Road in Mecklenburg County to the Rea Road Extension in
47433.1.13 Union County. The Department shall perform the study.
The Municipality shall participate in 20% of the costs of the
project in the amount of $64,204.
Montgomery County This Project consists of improvements on NC 24-27 from
Stanly County NC 740 in Albemarle to east of the Pee Dee River. This
R-2530B Utility Construction Agreement (UCA) is for the adjustment
34446.3.4 and/or relocation of water lines. The County is responsible
for actual costs of the relocation work. The estimated
reimbursement is $59,025.
NorFolk Southern Railway This Amendment #1 to the Charlotte Maintenance Facility
Company (NS) Access Project Construction and Maintenance Agreement
Mecklenburg County executed on March 7, 2016 is being executed to clarify the
section on "Ownership" to match the original intent that NS
is the owner of all railroad signal equipment installed by
NS, regardless of location. There will be no additional cost
to the Department.
NorFolk Southern Railway This Rail Agreement provides for the review of engineering
Company (NS) plans developed by the Department for the construction of
Mecklenburg County improvements at the intersection of Crossing # 721 712S,
U-5873 MP O 20.81 (NC 115 - N. Main Street) and (SR 6037 -
46425 Potts Street) in the Town of Davidson. Improvements may
include, but not limited to, paving, grading, and drainage.
The Department will reimburse NS 100% of the cost of
work performed by NS under this Agreement. The
estimated cost to the Department is $30,000.
December 6, 2018
Item O
Page 7 of 11
NCDOT December 6, 2018 Board of Transportation Agenda
Division 10, con't.
CSX Transportation, Inc. (CSXT)
Union County
P-5704
46398
Division 11
On October 2, 2009, the Department and CSXT entered
into a Railroad Master Construction Agreement which
detailed the terms and conditions by which CSXT would
construct various rail safety improvements within the State
of North Carolina. This Addendum #10 to the Master
Construction Agreement provides for the construction of a
two-mile passing siding track in Indian Trail from east of
Wesley Chapel Stouts Road near MP SF-312.5 to east of
Indian Trail Road near MP SF- 315.31. The proposed
passing siding improves the capacity and efficiency of the
direct rail link between the Port of Wilmington and the
Charlotte market. The Department has performed the
design work and obtained the permits, under the terms of
the Preliminary Engineering Agreement. CSXT shall
perform all of the construction work for the project within
the existing right-of-way. The Department shall reimburse
CSXT 100% of the actual eligible costs. The estimated cost
to the Department is $8,200,000. This Addendum #10 was
previously approved by the Board on April 6, 2017 with a
total estimated cost to the Department of $5,500,000.
CSXT, at no cost to the Department, shall maintain the
siding track once constructed.
Town of Blowing Rock This Project consists of the construction of section 2 of the
Watauga County recreational Greenway Trail heading into Blowing Rock at
EB-5924 the parking area adjacent to Tanger Outlet and running up
47629.3 to the North end of the Chestnut Ridge property. The
44607 Municipality is responsible for all phases of the Project.
The Department shall reimburse approved eligible costs
from the Federal Lands Access Program (FLAP) funds
allocation, not to exceed $1,791,988. The non-federal
match for the FLAP funds is $145,000 from Contingency
Funds and the Municipality will be responsible for providing
$285,495 and all costs that exceed the total available
funding of $2,222,483.
Town of Yadkinville This Project consists of improvements on US 601 (State
Yadkin County Street) from US 421 to SR 1146 (Lee Road). This Utility
U-5809 Construction Agreement (UCA) is for the adjustment and/or
44382.3.1 relocation of water and sewer lines. The Municipality is
responsible for actual costs of the relocation work. The
estimated reimbursement is $489,324.
December 6, 2018
Item O
Page 8 of 11
NCDOT December 6, 2018 Board of Transportation Agenda
Division 14
Clay County This Project consists of improvements on NC 69 from the
A-0011 C Georgia State Line to US 64. The Department shall prepare
32574.3.8 the environmental and/or planning document, project plans
and specifications, acquire any needed right of way and
construct the project. The County shall relocate and adjust
any municipally-owned utilities. At the request of the
County, the Department shall include in its contract the
construction of pedestrian facilities within the project limits.
The County shall reimburse the Department 30% of the
actual cost of the work. The estimated reimbursement from
the County is $46,170.
December 6, 2018
Item O
Page 9 of 11
NCDOT December 6, 2018 Board of Transportation Agenda
SUMMARY: There are a total of 12 agreements for informational purposes only.
Division 3
Town of Ocean Isle Beach This Project consists of landscaping for a roundabout at the
Brunswick County intersection of Highway 179, Highway 904 (Causeway
3603.3.30 Drive) and SR 1184 (Ocean Isle Beach Road SW) in
Ocean Isle Beach. The Department shall install the
landscape plantings. The Municipality shall maintain the
plantings after a one-year establishment period.
Division 5
Win Duke LLC This Project consists of the modification of the existing
Durham County traffic signal at the intersection of US 501 (North Duke
36249.3959 Street) at Frasier Street. The Department will review the
traffic signal plans and inspect the traffic signal installation.
The Developer shall reimburse the Department 100% of the
actual cost of all work performed by the Department. The
estimated cost is $5,000.
Shelbourne Healthcare This Project consists of the upgrade of the existing traffic
Development Group signal on Regency Parkway at Elderlee Drive in Cary. The
Wake County Department will review the traffic signal plans and inspect
36249.3960 the traffic signal installation. The Developer shall
reimburse the Department 100% of the actual cost of all
work performed by the Department. The estimated cost is
$5,000.
G3 Properties, LLC This Project consists of the upgrade of the traffic signal on
Wake County US 64 at Liles Dean Lane. The Department will review the
36249.3961 traffic signal plans and inspect the traffic signal installation.
The Developer shall reimburse the Department 100% of the
actual cost of all work performed by the Department. The
estimated cost is $5,000.
Trinity Group Investments This Project consists of the upgrade of the traffic signal on
Franklin County US 1 at Bert Winston Road and installation of a new traffic
36249.3965 signal on US 1 at Northbound (U-Turn Movement). The
Department will review the traffic signal plans and inspect
the traffic signal installation. The Developer shall
reimburse the Department 100% of the actual cost of all
work performed by the Department. The estimated cost is
$7,500.
December 6, 2018
Item O
Page 10 of 11
NCDOT December 6, 2018 Board of Transportation Agenda
Division 8
Town of Aberdeen This Agreement is to provide de-icing salt to the
Moore County Municipality for the safe and efficient utilization of
36249.3879 transportation systems. The Municipality shall reimburse
the Department 100% of the actual cost of the material.
The estimated reimbursement to the Department is $93.73
per ton.
Division 10
The Silverman Group This Project consists of the construction of roadway
Cabarrus County improvements and the installation of traffic signals to
U-4910B facilitate traffic flow association with the Developer's
40373.1.F3 proposed logistics warehouse site (SL 1000 Derita Road).
40373.2.F2 The Developer shall reimburse the Department 100% of the
40373.3.2 DepartmenYs work. The estimated reimbursement is
$339,300.
Division 13
City of Asheville This Project consists of turn lane improvements from
Buncombe County SR 3503 (Overlook Road) onto US 25 (Hendersonville
47875 Highway) and a right turn lane from US 25 (Hendersonville
Highway) onto SR 3503 (Overlook Road). The Department
shall perform the work. At the request of the Municipality,
additional work by the Department will include bus shelter
improvements. The Municipality shall reimburse the
Department 100% for the additional work. The estimated
reimbursement is $2,200.
City of Asheville This Project consists of construction of sidewalk on New
Buncombe County Leicester Highway from the city limits to Patton Avenue.
U-5190 This Supplemental Agreement modifies the Project funding
45251.1.1 source with no change in the amount of funding. The
45251.2.1 Department shall reimburse $2,199,000 (80%) of eligible
45251.3.1 expenses from STP funds and $705,000 (80%) from
STP-DA funds allocation. The Municipality shall provide the
20% ($726,000) non-federal match and all costs that
exceed the total estimated cost of $3,630,000.
City of Asheville This Project consists of construction of sidewalk along US
Buncombe County 25 (Hendersonville Road) within the Asheville city limits
U-5189 from existing sidewalk near I-40 south to NC 146 (Long
45250.3.1 Shoals Road. This Supplemental Agreement is to extend
the completion date for the Project to January 31, 2019, in
lieu of May 30, 2018.
December 6, 2018
Item O
Page 11 of 11
NCDOT December 6, 2018 Board of Transportation Agenda
Division 14
Town of Lake Santeetlah This Project consists of patching on various streets within
Graham County the town limits. The Department shall perform the work.
36249.3958 The Municipality shall reimburse the Department 100% for
the work. The estimated reimbursement is $10,470.
City of Hendersonville This Project consists of the installation of a Rectangular
Henderson County Rapid Flashing Beacon (RRFB) at the intersection of US 64
36249.3963 and Valley Street in Hendersonville. The Municipality shall
reimburse the Department 100% for the work. The
estimated reimbursement is $14,000.
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
Approval of Municipal Street System Changes
Deletions to the State Highway System
Division County Municipality Road
7 Alamance City of SR 2205;
2018_11_M001 Mebane Burgess
Road
10 Union City of SR 3668;
2018_11_M001 Monroe Aeropointe
Parkway
Termini
To delete
Burgess Road
To delete
Aeropointe
Parkway
Total Miles =
Length
0.140
� •:
0.438
Item P
Page 1
December 6, 2018
NCDOT December 2018 Board of Transportation Agenda
No.
1
2
3
4
5
6
7
6
7
Preliminary Right of Way Plans
Final Right of Way Plans
Revisions of Final Right of Way Plans
Conveyance ROW Residue (HB 501)
Approval of Conveyance of Highway Right of Way Residues
Approval of Conveyance of Surplus Highway Right of Way
Approval of Revision in Control of Access
Advance Acquisition of Highway Right of Way
Release of Interest
Enacted
Paqe No.
R-1 &R-2
R-3&R-4
R-5&R-6
R-7—R-9
R-10
R-11
R-12
R-13
R-14
8 Award of Contracts to Private Firms for Engineering Services ROW R-15 — R-18
NCDOT December 2018 Board of Transportation Agenda
Preliminary Right of Way Plans
The Preliminary Right of Way Plans for the below projects, including Secondary Roads
and Industrial Access Roads, provide for the construction, design, drainage and control of
access as shown on the respective plans.
Based upon the recommendations of the Manager of the Right of Way Unit, the Board
finds that such rights of way as shown on these preliminary plans and drawings, including
existing public dedicated right of way, are for a public use and are necessary for the
construction of said projects.
The rights of way for the location, construction, relocation, and control of access of
R-1
highways embraced in the below projects shall be as shown in detail on the preliminary right of
ways plans and drawings for said projects on file in the Right of Way Branch in the Department
of Transportation in Raleigh.
The Board finds such right of way acquisition to be necessary and hereby authorizes the
Right of Way Branch to acquire right of way on the below projects either by negotiation or by
condemnation through the Attorney General's Office.
(Division 1)
Pasquotank County; I.D. No. U-5942; Project No. 45861.2.1:
Elizabeth City — Signal System (Utilities)
(Division 2)
Pitt County; I.D. No. B-4605; Project No. 38430.2.1:
Bridge No. 5 over Chicod Creek on SR 1777
Greene; I.D. No. R-5812; Project No. 46981.2.1:
US 13 Bypass from NC 58 (Kingold Boulevard) to NC 91
(Division 3)
Onslow County; I.D. No. U-4007E; Project No. 35008.3.8:
US 17 at NC 53 (Western Boulevard) and SR 1406 (Piney Green Road)
(Division 5)
Wake County; I.D. No. U-5302; Project No. 48000.2.1:
US 401 from South of SR 1006 (Old Stage Road) to South of SR 2538 (Mechanical
Boulevard) in Garner
NCDOT December 2018 Board of Transportation Agenda
Preliminary Right of Way Plans (continued)
R-2
(Division 8)
Moore County; I.D. No. U-5814; Project No. 44387.2.1:
US 15/501 / NC 211 from US 1(Sandhills Boulevard) to Brucewood Road in Aberdeen
and Southern Pines
Moore County; I.D. No. U-5815B; Project No. 54041.2.4:
US 1(Sandhills Boulevard) from Knight Street in Aberdeen to Old US 1 in Southern
Pines, SR 1112 (Roseland Road)
(Division 9)
Forsyth County; I.D. No. U-6003; Project No. 47138.2.1:
New Route from SR 1969 (Piney Grove Road) to NC 150 (North Main Street) in
Kernersville
(Division 10)
Union County; I.D. No. W-5710K; Project No. 44856.2.11:
NC 200 (Lancaster Highway) and SR 1128 (McWhorter Road) — Tom Starnes Road
Mecklenburg County; I.D. No. C-5613H; Project No. 43735.2.12:
Intersection of SR 2112 (Lakeview Road) and SR 2110 (Reames Road) and Lake View
Road from Beatties Ford Road to Reames Road in Charlotte
Union County; I.D. No. W-5710L; Project No. 44856.2.12
NC 16 (Providence Road) and Gray Byrum near Waxhaw
(Division 12)
Lincoln County; I.D. No. R-5712; Project No. 50208.2.1:
NC 16 Business at intersection of NC 16 Business and SR 1439 (Unity Church Road)/
SR 1387 (Triangle Circle)
(Division 13)
Burke County; I.D. No. I-5875; Project No. 53076.2.1:
I-40 at SR 1712 (Drexel Road)
Burke County; I.D. No. I-5874; Project No. 53075.2.1:
I-40 at SR 1142 (Jamestown Road) Exit 100
Burke County; I.D. No. I-5008; Project No. 41497.2.1:
I-40 at SR 1734 / SR 1826 (Exit 111)
PRELIMINARY RIGHT OF WAY PLANS 15 PROJECT(S) $ 0.00
NCDOT December 2018 Board of Transportation Agenda
Final Right of Way Plans
R-3
Right of way acquisition in accordance with the preliminary right of way plans on file in
the Right of Way Unit has been determined to be necessary for public use and was authorized
by the Board. Certain changes in the right of way have necessitated alteration of the
preliminary right of way plans. Final plans have been prepared and provide for the construction,
design, drainage and control of access for these projects. The Board finds that such rights of
way and control of access as shown on the final plans are for a public use and are necessary
for construction. The sections of roads which were shown on the preliminary plans as sections
of roads to be abandoned are hereby abandoned and removed from the State Highway System
for Maintenance upon the completion and acceptance of the project.
The rights of way for the location, design and construction of highways embraced in the
following projects shall be as shown in detail on the final plans for said projects as follows:
(Division 2)
Project No. 45834.2.2; Pitt County; I.D. No. U-5606:
Paving, drainage, grading, signals and retaining walls on SR 1598 / SR 1620 (Dickinson
Ave) from NC 11 (Memorial Dr) to SR 1610 (Reade Circle) with the right of way indicated
upon the final plans for said project.
(Division 3)
Project No. 40238.2.4; New Hanover County; I.D. No. U-4902D:
Grading, drainage, paving and signals in Wilmington — US 17 Business (Market Street)
from SR 1403 (Middle Sound Loop Road) to SR 2290 (Mendenhall Drive) / SR 2734
(Marsh Oaks Drive) with the right of way indicated upon the final plans for said project.
Project No. 50139.2.1; Onslow County; I.D. No. W-5602:
Drainage, paving and grading on NC 172 Camp Lejeune Gate to NC 210. Convert two
lane roadway to three lane roadway with a two-way left turn lane with the right of way
indicated upon the final plans for said project.
(Division 5/7)
Project No. 38664.2.FD1; Durham/Orange Counties; I.D. No. EB-4707A:
Drainage, paving and grading on SR 1838 / SR 2220 (Old Durham Road) from US 15 /
US 501 in Orange County to SR 1113 (Pope Road) in Durham County with the right of
way indicated upon the final plans for said project.
NCDOT December 2018 Board of Transportation Agenda
Final Right of Way Plans (continued)
R-4
(Division 11)
Project No. 46103.2.1; Alleghany County; I.D. No. B-5388:
Drainage, paving, grading and structure on Bridge No. 21 over Little River on NC 18 with
the right of way indicated upon the final plans for said project.
(Division 13)
Project No. 50225.2.1; Rutherford County; I.D. No. U-5833:
Grading, drainage, paving, signals and retaining wall on SR 2241 (Oak Street) from SR
2159 (Pine Ridge Road) to US 74 with the right of way indicated upon the final plans for
said project.
(Division 14)
Project No. 50231.2.1; Henderson County; I.D. No. U-5840:
Drainage, Paving and grading on SR 1547 (Old Airport Road) from US 25 to Mills Gap
Road. Widen Roadway with the right of way indicated upon the final plans for said
project.
FINAL RIGHT OF WAY PLANS 7 PROJECT(S) $ 0.00
NCDOT December 2018 Board of Transportation Agenda
Revisions of the Final Right of Way Plans
R-5
Right of way acquisition in accordance with the final right of way plans for the following
projects has been determined to be necessary and authorized by the Board. Plans are on file at
the Office of the Secretary to the Board of Transportation as an addendum to the minutes of the
meetings hereinafter indicated.
Certain changes in right of way, construction and drainage easements, and control of
access have been necessitated by alterations in the construction plans of these projects.
Amended plan sheets for these projects have been prepared which provide for changes of
certain right of way areas, construction and drainage easements and control of access.
The Board finds that the revised areas of right of way, construction and drainage
easements and control of access, as shown on the amended plan sheets hereinafter set out,
are for a public purpose and are necessary for the construction of projects.
The right of way, construction and drainage easements and control of access are hereby
revised as shown on the plan sheets incorporated herein as an addendum, said projects, date
of original final approval, and revised right of way, easements and access being as follows:
(Division 3)
Project No. 40191.2.1; I.D. No. U-4751; New Hanover County:
Final Right of Way plans approved on the minutes of the October 5, 2017 Board of
Transportation Meeting. Revised additional right of way, easements or control of access
shown on plan sheet(s) 6 as presented at the December 6, 2018 Board of
Transportation Meeting.
(Division 4)
Project No. 39930.2.2; I.D. No. U-4762; Edgecombe County:
Final Right of Way plans approved on the minutes of the March 8, 2018 Board of
Transportation Meeting. Revised additional right of way, easements or control of access
shown on plan sheet(s) 4& 5 as presented at the December 6,2018 Board of
Transportation Meeting.
(Division 5)
Project No. 34745.2.8; I.D. No. U-0071; Durham County:
Final Right of Way plans approved on the minutes of the November 6, 2014 Board of
Transportation Meeting. Revised additional right of way, easements or control of access
shown on plan sheet(s) 6 as presented at the December 6,2018 Board of Transportation
Meeting.
NCDOT December 2018 Board of Transportation Agenda
Revisions of the Final Right of Way Plans (continued)
R-6
(Division 12)
Project No. 34522.2.FR6; I.D. No. R-3100A; Catawba County:
Final Right of Way plans approved on the minutes of the April 6, 2017 Board of
Transportation Meeting. Revised additional right of way, easements or control of access
shown on plan sheet(s) 15 as presented at the December 6,2018 Board of
Transportation Meeting.
REVISION FINAL ROW PLANS 4 PROJECT(S) $0.00
NCDOT December 2018 Board of Transportation Agenda
R-7
Approval of Conveyance of Highway Right of Way Residues by Real Estate Agent and/or
Auctioneer per House Bill 501 Pilot Program
It is hereby resolved, based upon the recommendation of the Manager of the Right of
Way Unit, that the following highway right of way conveyances are approved:
(Division 2)
Project 34440.2.6, R2510B Parcel 013, US 17 from south of SR 1149 Price Road
and US 17 to north of SR 1509 Springs Road
Beaufort County
Conveyance of an approximate 2.289-acre landlocked B-class residue area to
Saravanan Bala for the highest offer amount of $2,500.00; commission $200.00
Project 34440.2., R-2510A Parcel 063, US 17 from south of SR 1127 Possum Track
Road to SR 1149 Price Road
Beaufort County
Conveyance of an approximate 0.348-acre landlocked C-class residue area to
Saravanan Bala for the highest offer amount of $2,000.00; commission $160.00
Project 34440.2.6, R-2510A Parcel 108, US 17 from south of SR 1127 Possum Track
Road to SR 1149 Price Road
Beaufort County
Conveyance of an approximate 0.576-acre landlocked C-class residue area to
Saravanan Bala for the highest offer amount of $2,500.00; commission $200.00
(Division 4)
Project 34459.2.7, R-2552C Parcel 016-018 US 70 Clayton Bypass from east of SR
1560 to US 70 east of Clayton
Johnston County
Conveyance of an approximate 0.791-acre landlocked B-class residue area to Neptali
Dominguez and Veronica Martinez for the highest offer amount of $10,000.00;
commission $600.00
Project 34363.2.8, R-1030D Parcel 006, US 117 Bypass from south of US 301 to US
264 Bypass
Wilson County
Conveyance of an approximate 0.640-acre landlocked C-class residue area to Wilson
Mini Storage, LLC for the highest offer amount of $2,000.00; commission $120.00
Project 34459.2.5, R-2552B Parcel 014, US 70 Clayton Bypass from east of NC 42
to east of SR 1560 Ranch Road
Johnston County
Conveyance of an approximate 1.090-acre A-class residue area to Steven Cogar for the
highest offer amount of $22,000.00; commission $1,320.00
NCDOT December 2018 Board of Transportation Agenda
R-8
Approval of Conveyance of Highway Right of Way Residues by Real Estate Agent and/or
Auctioneer per House Bill 501 Pilot Program (continued)
(Division 4) (continued)
Project 8.1330504, R-1030BA Parcel 015, US 117 Bypass from south of SR 1002 to
south of SR 1342
Wayne County
Conveyance of an approximate 24.040-acre landlocked B-class residue area to Janet L
Thomas for the highest offer amount of $5,000.00; commission $300.00
(Division 6)
Project 34866.2.2, U-2810B Parcel 063, SR 1003 Camden Road from NC 162 Hope
Mills Bypass to east of Oakland Ave.
Cumberland County
Conveyance of an approximate 0.110-acre landlocked C-class residue area to Everett
Johnson for the highest offer amount of $150.00; commission $15.00
Project 34886.2.2, X-2000C Parcels 031 & 032, US 24 extension Fayetteville Outer
Loop from east of NC 87/NC 210 to west of US 401
Cumberland County
Conveyance of an approximate combined 0.570-acre consisting of a landlocked B-class
and a landlocked C-class residue area to Jimmy Santos for the highest offer amount of
$1,550.00; commission $155.00
Project 34994.2.2, U-3849 Parcel 058, SR 1363 Elk Road from SR 1132 Legion Road
to US 301/I-95 Business
Cumberland County
Conveyance of an approximate 0.127-acre landlocked B-class residue area to John
Darrah for the highest offer amount of $800.00; commission $80.00
Project 34866.2.2, U-2810B Parcel 069, SR 1003 Camden Road from NC 162 Hope
Mills Bypass to east of Oakland Ave.
Cumberland County
Conveyance of an approximate 0.540-acre landlocked C-class residue area to Melissa
Brown for the highest offer amount of $7.50; commission $0.75
Project 34866.2.2, U-2810B Parcel 029, SR 1003 Camden Road from NC 162 Hope
Mills Bypass to east of Oakland Ave.
Cumberland County
Conveyance of an approximate 0.113-acre landlocked C-class residue area to Jimmy
Santos for the highest offer amount of $130.00; commission $13.00
NCDOT December 2018 Board of Transportation Agenda
R-9
Approval of Conveyance of Highway Right of Way Residues by Real Estate Agent and/or
Auctioneer per House Bill 501 Pilot Program (continued)
(Division 7)
Project 8.2493501, B-2834 Parcel 003, Bridge #101 over Horsepen Creek on SR
2182
Guilford County
Conveyance of an approximate 2.390-acre A-class residue area to Stephen Boskovic for
the highest offer amount of $10,000.00; commission $600.00
(Division 12)
Project 34517.2.2, R-2911A Parcel 049, US 70 from SR 2318 near Statesville to the
Rowan County line
Iredell County
Conveyance of an approximate 0.168-acre landlocked C-class residue area to Joshua
Nowlin for the highest offer amount of $113.00; commission $13.00
Project 8.1821403, R-1017AB Parcel 081, US 64/NC 90 from west of the Alexander
County line to west of I-40 at Statesville
Iredell County
Conveyance of an approximate 0.430-acre landlocked C-class residue area to Joshua
Nowlin for the highest offer amount of $270.00; commission $27.00
Project 34517.2.2, R-2911A Parcels 093 & 094, US 70 from SR 2318 near Statesville
to the Rowan County line
Iredell County
Conveyance of an approximate 2.584-acre landlocked B-class residue area to Michael
Sullivan for the highest offer amount of $8,673.00; commission $867.30
Project 34517.2.2, R-2911A Parcel 026, US 70 from SR 2318 near Statesville to the
Rowan County line
Iredell County
Conveyance of an approximate 0.970-acre landlocked C-class residue area to Michael
Sullivan for the highest offer amount of $1,628.00; commission $162.80
Project 34517.2.2, R-2911A Parcel 062, US 70 from SR 2318 near Statesville to the
Rowan County line
Iredell County
Conveyance of an approximate 1.088-acre landlocked B-class residue area to Hammad
Raza for the highest offer amount of $2,250.00; commission $225.00
Project 34517.2.2, R-2911A Parcel 020, US 70 from SR 2318 near Statesville to the
Rowan County line
Iredell County
Conveyance of an approximate 1.006-acre landlocked B-class residue area to Hammad
Raza for the highest offer amount of $7,600.00; commission $760.00
CONVEYANCE ROW RESIDUE (HB 501) 19 PROJECT(S) $ 79,171.50
NCDOT December 2018 Board of Transportation Agenda
Approval of Conveyance of Highway Right of Way Residues
R-10
It is hereby resolved, based upon the recommendation of the Manager of the Right of
Way Unit, that the following highway right of way conveyances are approved:
(Division 7)
Project 34802.2.3, Parcels U-2412B 080, 081, 082, SR 1486/ SR 1421 (Greensboro/
High Point Road) from SR 4228 (Vickrey Chapel Road) to SR 1424 (Hilltop Road)
Guilford County
Conveyance of an approximate 0.194-acre residue area to G.L. Wilson Building
Company for the high bid amount of $2,500.00.
(Division 9)
Project 40278.2.1, U-4909 024, SR 2643 (Union Cross Road)
Forsyth County
Conveyance of an approximate 0.346-acre residue area to Mark Franklin Icenhower for
the high bid amount of $10,000.00.
(Division 10)
Project 8.U671619, Parcel 922, I-485 (Charlotte Outer Loop) from South of NC 218
to North of NC 51
Mecklenburg County
Conveyance of an approximate 1.560-acre residue area to the Town of Mint Hill for no
monetary consideration. The Town of Mint Hill intends to use this property for the
expansion of their Veteran's Memorial Park. If the land use changes to anything other
than for the park's use, the property shall revert back to the Department. If any portion
of the property is needed for future transportation uses, the Town of Mint Hill will convey
back the Department the portion needed for transportation uses at no cost.
CONVEYANCE ROW RESIDUE 3 PROJECT(S) $ 12,500.00
NCDOT December 2018 Board of Transportation Agenda
Approval of Conveyance of Surplus Highway Right of Way
R-11
It is hereby resolved, based upon the recommendation of the Manager of the Right of
Way Unit that the following highway right of way conveyances are approved:
(Division 10)
Project 8.1636613, SR 2623 (Trailer Drive) and SR 2635
Mecklenburg County
Abandonment of an approximate 0.385-acre permanent easement area to C.A.T.
Industrial Properties, LLC for no monetary consideration.
CONVEYANCE OF SURPLUS RIGHT OF WAY 1 PROJECT(S) $ 0.00
NCDOT December 2018 Board of Transportation Agenda
Approval of Revision in Control of Access
R-12
It is hereby resolved, based upon the recommendation of the Manager of the Right of
Way Unit that the following highway right of way conveyances are approved:
(Division 7)
Project 8.1500602, Parcel U-2003B 007, US 15-501 (Fordham Blvd) at SR 1902
(Manning Drive) in Chapel Hill
Orange County
Grant of a revision in the existing control of access to the University of North Carolina for
an approximate 130-foot break on US 15-501 (Fordham Blvd) at SR 1902 (Manning
Drive) in Chapel Hill for no monetary consideration.
CONVEYANCE OF PERMANENT EASEMENT 1 PROJECT(S) $ 0.00
NCDOT December 2018 Board of Transportation Agenda
Advance Acquisition of Highway Right of Way
R-13
Upon recommendation of the Manager of the Right of Way Unit, the Board has been
requested to authorize the acquisition of the following properties through negotiation or
condemnation for purposes of highway construction in order to prevent undue hardship on
property owners or to protect the right of way corridor from development prior to regular project
approval. The Board finds such acquisitions to be necessary, and hereby authorizes the Right
of Way Branch to acquire said properties either by negotiation or by condemnation through the
Office of the Attorney General.
Division 5
Property of Capital Properties of Raleigh II, LLC
I.D. No. U-5825, Parcel #903
WBS 44396.1.1, F. A. Project N/A,
County of Wake
Division 8
Property of Joseph R. Cothran
I.D. No. R-5709, Parcel #900
WBS 50205.1.1, F. A. Project N/A,
County of Hoke/Moore
Division 9
Property of Busick Brothers Masonry, Inc. (Williams Printing, Inc. Tenant)
I.D. No. U-5899, Parcel 900
WBS 44689.1.1, F. A. Project N/A
County of Forsyth
APPROVAL OF ADVANCE ACQUISITION FOR HIGHWAY ROW 3 PROJECT(S) $ 0.00
NCDOT December 2018 Board of Transportation Agenda
Release of Interest to Morehead Street Investors, LLC
R-14
It is hereby resolved, based upon the recommendation of the Manager of the Right of
Way Unit that the following highway right of way conveyances are approved:
(Division 10)
The Department's Rail Division has been requested by Morehead Street Investors, LLC
to Quitclaim any interest the Department may have acquired in the original Right of Way
of Piedmont and Northern Co. Railroad as the tracts were originally located near West
Hill Street in Charlotte, Mecklenburg County. Since there is no record of any conveyance
to the Department from Piedmont and Northern Co. Railroad in the Mecklenburg County
Registry, the Department is seeking authority to Quitclaim any interest it may have
acquired to Morehead Street Investors, LLC. This is also to request authority for
Manager of Right of Way to execute appropriate instrument.
RELEASE OF INTEREST 1 PROJECT(S) $0.00
NCDOT December 2018 Board of Transportation Agenda
Award of Contracts to Private Firms for Engineering Services Right of Way
Branch
STATEWIDE:
R-15
After careful evaluation of the workload and schedules of the work that can be
accomplished by our staff, it was determined necessary to employ private firms to
perform asbestos inspections, abatement, and structure clearings for our Department to
obligate available funds. Our staff was authorized to proceed with the actions required
to employ private firms in accordance with the rules and regulations adopted by the
Board on April 7, 2005.
STATEWIDE
(1) Projects:
Firm:
Engineering Fee
DBE Utilization:
Various
4 Seasons Site & Demolition Inc., Wilmington, NC
$3,000,000.00
0%
(2) Projects: Various
Firm: A1 Consulting Group, Inc., Morrisville, NC
Engineering Fee: $3,000,000.00
DBE Utilization: 100%
(3) Projects: Various
Firm: Abatemaster, Inc., Winston-Salem, NC
Engineering Fee: $3,000,000.00
DBE Utilization: 100%
(4) Projects: Various
Firm: Abatement Technology and Construction Solutions,
Tobaccoville, NC
Engineering Fee: $3,000,000.00
DBE Utilization: 0%
(5) Projects: Various
Firm: Carolina Construction Worx, Inc., Raleigh, NC
Engineering Fee: $3,000,000.00
DBE Utilization: 0%
(6) Projects: Various
Firm: Carolina Envirotech Inc., Mooresville, NC
Engineering Fee: $3,000,000.00
DBE Utilization: 0%
NCDOT December 2018 Board of Transportation Agenda
Award of Contracts to Private Firms for Engineering Services Right of Way
Branch (continued)
(7) Projects:
Firm:
Engineering Fee
DBE Utilization:
Various
Clement Construction Corporation,
Winston-Salem, NC
$3,000,000.00
100%
(8) Projects: Various
Firm: Contaminant Control, Inc., Fayetteville, NC
Engineering Fee: $3,000,000.00
DBE Utilization: 0%
(9) Projects: Various
Firm: D.H. Griffin Wrecking Co., Inc., Greensboro, NC
Engineering Fee: $3,000,000.00
DBE Utilization: 0%
(10) Projects: Various
Firm: Double D Trucking, Inc., Winston-Salem, NC
Engineering Fee: $3,000,000.00
DBE Utilization: 100%
(11) Projects: Various
Firm: Elevated Environmental Corporation, Reidsville, NC
Engineering Fee: $3,000,000.00
DBE Utilization: 0%
(12) Projects:
Firm:
Engineering Fee
DBE Utilization:
Various
Enpuricon, Inc., Apex, NC
$3,000,000.00
0%
(13) Projects: Various
Firm: High Point Builders, LLC., Archdale, NC
Engineering Fee: $3,000,000.00
DBE Utilization: 0%
R-16
(14) Projects: Various
Firm: Janezic Building Group, LLC., Raleigh, NC
Engineering Fee: $3,000,000.00
DBE Utilization: 0%
NCDOT December 2018 Board of Transportation Agenda
Award of Contracts to Private Firms for Engineering Services Right of Way
Branch (continued)
(15) Projects: Various
Firm: KTF Contractor Services, LLC., Winston-Salem, NC
Engineering Fee: $3,000,000.00
DBE Utilization: 0%
(16) Projects: Various
Firm: M.B.H Enterprises, Inc., Rural Hall, NC
Engineering Fee: $3,000,000.00
DBE Utilization: 0%
(17) Projects: Various
Firm: Marley Trucking & Demolition, Inc., Asheboro, NC
Engineering Fee: $3,000,000.00
DBE Utilization: 100%
(18) Projects: Various
Firm: Mitch Contracting Company, Inc., Fairview, NC
Engineering Fee: $3,000,000.00
DBE Utilization: 0%
(19) Projects: Various
Firm: Nehemiah Builders, Inc., Raleigh, NC
Engineering Fee: $3,000,000.00
DBE Utilization: 100%
(20) Projects: Various
Firm: NEO Corporation, Canton, NC
Engineering Fee: $3,000,000.00
DBE Utilization: 0%
(21) Projects: Various
Firm: Premier Design Builders, Inc., Kernersville, NC
Engineering Fee: $3,000,000.00
DBE Utilization: 100%
(22) Projects: Various
Firm: T& T Abatement, Toast, NC
Engineering Fee: $3,000,000.00
DBE Utilization: 100%
R-17
NCDOT December 2018 Board of Transportation Agenda
Award of Contracts to Private Firms for Engineering Services Right of Way
Branch (continued)
(23) Projects:
Firm:
Engineering Fee
DBE Utilization:
Various
Tierney Commercial Construction, LLC.,
Greenville, NC
$3,000,000.00
0%
(24) Projects: Various
Firm: Vistabution, LLC, Raleigh, NC
Engineering Fee: $3,000,000.00
DBE Utilization: 100%
(25) Projects: Various
Firm: W& W Trucking & Demolition Services, LLC.,
Winston-Salem, NC
Engineering Fee: $3,000,000.00
DBE Utilization: 100%
(26) Projects: Various
Firm: W.C. Black and Sons, Inc., Charlotte, NC
Engineering Fee: $3,000,000.00
DBE Utilization: 0%
APPROVAL OF CONTRACTS PRIVATE FIRMS 26 PROJECTS $78,000,000.00
R-18
R-ITEM SUMMARY 80 PROJECT(S) TOTAL:$ 78,091,671.50
Item S
NORTH CAROLINA BOARD OF TRANSPORTATION
RECOMMENDED SUPPLEMENTAL ALLOCATION OF HIGHWAY MAINTENANCE
APPROPRIATIONS
FISCAL YEAR 2018-2019
There will be no Item S submitted to the Board for approval at the December 2018
Board meeting.
t �
It�iTE r-t
vavember 19. 2018
MEMORANDUM TO: Board of Transportation
FROM: Transportation Planning Division
SUB.iECT: Submission of the Martin County Comprehensive Transportation Plan for
Mutual Adoption �y the Board of Transportation
The Transportation Plaru�in� DivisEon has worked coo�erativel�� w•ith the Martin County on the
deve4opment of a Comp�-ehensive Transpo�tation Plan {CTP). �I'he plar� �va� adopted by Martin Co�nty
or� July 1 1. 2018, ihe Town of Bear Grass on April 12. 201 S, the Tow�n ot E��eretts an June 7. ?Ol $.
the Town of Hamilton on May �_ 2018. the Town of Hassel� on June t? 20] S, the Town of
Jamesville on May 14. 20] 8, the Tawn of Oak City on May 7. �018. the Tow�n of Parmele on May
l. 201 S. the Town of Roberson��lle on May S, 201 S. and the Town of Williamston on May 7. 2018.
It was endorsed by the Mid-East RPO on October S, 2018.
The plan is based on an analysis of existing a.nd projected travel and land use. public involvement
and field investigations oirecommended improvements. It is Iocated on the �r���b ac:
https:/Iconnect.ncdot.gov/projects/planning/Fa�esICTP-Details.aspx?stud� id—Martin County
'i'he Transportation Alarining Division recommends the mutuai adoption of the Martin County
Comprel�ensive Transportatian PIan as showr on the attached map. �°ith a recarrlmendation date of
October 1 �. 2� 18.
Sincerely,
4
.iarnal Alavi. P.E_
Director, Transportaiion Planning Division
Attachment
December 6, 20l 8
Adopted b�,�\
Marti rt�a u�iy�����
Date� .ol���'I 1�r�0'1�6;\ \�`��``
� � _� _ �. '�,�
Towr��of ����� (�rass � ` �`-��wn of Oak City
�#�: Apr`I�12�r,�Q18� � ,��a�'e: May 7, 2018
ToVYr� of Evel�etts T�e�iv�i of Parmele
Date:�.iune�7, 2018 ���''-�� � Date:��Vlay 1, 2018
Tornrn'�qf Hami��n � To�n of Rrgbersonville
Da��,111�y 3, 20� 8�,� , Dat�.:�J IVlay 8, 2018
Tov�`��f M�a s Hamilton , , J
��ell � ti�,,,�� vwrn o'� Willi�m_stqn
Date �n��'12�� - � 1 ��o � D�at 01�
Town o�slarr�esvill ' ����� 7�\� '
—,
f ,a �
�` , � _,- - _ ry �
Date: May 14;; �Q, ,;a�se;, � '
� " / � � �_
�
NCDOT � C: �% , �'se„ �dGPP
�s
Date: � � °°_� s �' � ��; ''
�.� � __ �"�_ ° �� �>_
Endg��ed; � 13 ' ��
.
� —_ ,
,\\v �
�
�ld-EasiRP�J �\� pa le ; " R berso v�lle .
,
Date: October �, �2g18 y . ! ;__� _��1 :�
��
��
/; :r '' \
.._--•�.�� � t
Recommended by: ��° ' -`
��
~'1
Transportation Planning Division �5
Date: October 10, 2018 ���--�
Notes:
,��
q
r @°4 ,
�
B E R T I E
C O U N T Y
� �
i i
, - ` /
� - � J mesville / / �
�� � , ,
, ,. . , �����
� ����� � , �
y�
I �/
� �
/ !'l
C�
:I �' j � � � •�
, _ _ �' P�i �,�
,\vy i � G�v
.f z
� o
� �
C� �
� __
T J
� o
� U
s�
Adoption Sheet
� '.
.
MA�TIN
_
Martin County
North Carolina
Comprehensive
Transportation Plan
RECOMMENDED MAP
(October 10, 2018)
Sheet 1 Adoption Sheet
Sheet 2 Highway Map
Sheet 3 Public Transportation
and Rail Map
Sheet 4 Bicycle Map
Sheet 5 Pedestrian Map
�__ _ j County Boundaries
Municipal Boundaries
Roads
Railroads
�= Airports
�• Hospitals/Medical Centers
scnools
Miles
0 1.5 3 6
N
Figure 1- Sheet 1 of 5 w�e
Base map date: November 2015 S
Refer to CTP document for more details
i��a►��•�
NORTH CAROLINA BOARD OF TRANSPORTATION
There will be no Item V submitted to the Board for approval at the December 5-6, 2018,
Board meeting.