Loading...
HomeMy WebLinkAbout150717_3097-F_Executed ContractContract Documents 407;7 OLD SALISBURY ROAD SEWER DAVIDSON COUNTY, NORTH CAROLINA 3097-F MAY 2015 \ CARO,'/// CoQ- FE��_ Sol. r' = 6097 GINE��' 0yN 1lv THE WOOTEN COMPANY k NG IN E E H I N G PLANNING AN C H I T EC i 0 GE 300 N ifCn C^,r SIIP"I Sutl^ ?h 0-het,rr i'i 77iU I .3?:' , L 51"% I, 3,r 62f }Ir: I ice nse Na F-0115 TABLE OF CONTENTS Document Title Pages 00010 Table of Contents 1-2 Bidding Requirements 00100 Advertisement for Bids 1-1 00200 Instruction to Bidders 1-11 00410a Bidder's Check List 1-1 00410 Bid Form 1-7 00430 Bid Bond 1-2 00432 Page for Attaching Power of Attorney 1-1 00490 Addendum (sample) 1-1 Contract Requirements 00510 Notice of Award 1-1 00520 Agreement 1-7 00550 Notice to Proceed 1-1 00610 Performance Bond 1-3 00615 Payment Bond 1-3 00616 Page for Attaching Power of Attorney 1-1 00618 Page for Attaching Certificate of Insurance 1-1 00634 Certificate of Owner's Attorney & Pre -Audit Statement 1-1 00700 General Conditions (EJCDC, 2007) 1-62 00810 Supplementary Conditions (to EJCDC, 2007, Gen. Cond.) 1-10 Minority Business Contract Provisions 1-11 Dispute Resolution 1-8 00621 Partial Payment Estimate 1-4 NC Sales Tax Certification 1-1 00625 Certificate of Substantial Completion 1-2 00941 Change Order 1-1 PERMITS: NCDENR Water Quality (WQ0037658) 1-8 NCDENR Land Quality (DAVID -2015-015) 1-3 NC DOT Encroachment (15 -024 -DE) 1-6 3097-F: 05/1915 00010-1 Table of Contents Section Title Pages Technical Specifications Division 1 - General Requirements 01100 Summary of Work 1-2 01270 Unit Prices 1-4 01312 Project Coordination 1-2 01314 Project Meetings 1-1 01330 Submittal Procedures 1-5 01450 Quality Control 1-2 01500 Temporary Facilities and Controls 1-4 01600 Product Requirements 1-3 01700 Execution Requirements 1-4 Division 2 - Site Construction 02230 Clearing and Grubbing 1-2 02315 Trenching for Utilities 1-10 02370 Erosion Control 1-3 02445 Bore & Jack Conduits 1-3 02530 Sanitary Sewer System 1-11 Table 1, Low Pressure Air Testing for Gravity Sewer Mains 1-1 02920 Lawns and Grasses 1-4 Divisions 3 — 16 NOT USED END OF DOCUMENT Table of Contents 00010-2 3097-F: 05/19/15 ADVERTISEMENT FOR BIDS Project: Old Salisbury Road Sewer Owner: Davidson County 925 North Main Street PO Box 1067 Lexington NC 27293 Engineer: The Wooten Company 350 N. Cox Street, Suite 26 Asheboro, NC 27203 (336)626-5322 Separate sealed Bids will be received until 2:00 pm, Thursday, June 11, 2015, in the Conference Room at 925 North Main Street Lexington NC 27292, at which time and place bids will be publicly opened and read aloud for the construction of the Old Salisbury Road Sewer project. After Bids are opened, the Owner shall evaluate them in accordance with the methods and criteria set forth in the Instructions to Bidders. The Owner reserves the right to waive any informality or to reject any or all Bids. Unless all Bids are rejected, Award will be made to the lowest responsible Bidder, taking into consideration quality, performance and the time specified in the proposals for the performance of the Contract. The Project consists of the following major items: Approximately 3,100 feet of 8 -inch gravity sewer and associated appurtenances. Bidding Documents may be examined at Engineer's and Owner's office and online at: Dodge Company, Association of General Contractors (AGC - isgft), Hispanic Contractors Association of the Carolinas (HCAC), Reed Construction Data, Construction Journal. Complete Bidding Documents may be obtained at the Issuing Office of the Engineer upon submitting a non-refundable payment in the amount of $50.00 for each set of documents, which includes all contracts. With request for Bidding Documents supply the following information: Company name, contact person, street address, and phone and fax numbers for Bidding office; N. C. contractor's license with limitation and classification, indicate if the firm will be a Bidder, Supplier or Sub -Contractor. Bidders will be required to show evidence that they are licensed to perform the work in the Bidding Documents as required by North Carolina General Statute, Chapter 87 and the Instructions to Bidders. Bid Security in the amount of five percent (5%) of the Bid must accompany each Bid and shall be subject to the conditions provided in the Instructions to Bidders. The Owner is an Equal Opportunity Employer and encourages bidding by small, minority and female contractors and does not discriminate on the basis of handicapped status. Bids from qualified disadvantaged business enterprise (DBE) are encouraged. Bidders shall be required to submit with their Bids affidavits of "Good Faith Efforts" in the recruitment of Minority Businesses. END OF DOCUMENT 3097-F : 05/19/15 00100-1 Advertisement for Bids Document in accordance with RUS Bulletin 1780-26, Exhibit E, 10/2009 INSTRUCTIONS TO BIDDERS TABLE OF ARTICLES ARTICLE 1 DEFINED TERMS..................................................................................1 ARTICLE 2 COPIES OF BIDDING DOCUMENTS....................................................1 ARTICLE 3 MINORITY PARTICIPATION GOALS.....................................................2 ARTICLE 4 QUALIFICATIONS OF BIDDERS...........................................................2 ARTICLE 5 EXAMINATION OF BIDDING DOCUMENTS, OTHER RELATED DATA, ANDSITE...............................................................................................3 ARTICLE 6 SITE AND OTHER AREAS....................................................................5 ARTICLE 7 INTERPRETATIONS AND ADDENDA...................................................5 ARTICLE 8 BID SECURITY......................................................................................6 ARTICLE 9 CONTRACT TIMES................................................................................6 ARTICLE 10 LIQUIDATED DAMAGES.......................................................................6 ARTICLE 11 SUBSTITUTE AND OR -EQUAL ITEMS.................................................6 ARTICLE 12 SUBCONTRACTORS, SUPPLIERS, AND OTHERS ..............................7 ARTICLE 13 FUNDING REQUIREMENTS..................................................................7 ARTICLE 14 PREPARATION OF BID.........................................................................7 ARTICLE 15 SUBMITTAL OF BID..............................................................................8 ARTICLE 16 MODIFICATION AND WITHDRAWAL OF BID.......................................9 ARTICLE 17 OPENING OF BIDS................................................................................9 ARTICLE 18 BIDS TO REMAIN SUBJECT TO ACCEPTANCE..................................9 ARTICLE 19 BASIS OF BID; COMPARISON OF BIDS...............................................9 ARTICLE 20 EVALUATION OF BIDS AND AWARD OF CONTRACT ....................... 10 ARTICLE 21 CONTRACT SECURITY AND INSURANCE........................................11 ARTICLE 22 SIGNING OF AGREEMENT.................................................................11 ARTICLE 23 SALES AND USE TAXES....................................................................11 ARTICLE 1 DEFINED TERMS 1.01 Terms used in these Instructions to Bidders will have the meanings indicated in the General Conditions and Supplementary Conditions. Additional terms used in these Instructions to Bidders have the meanings indicated below which are applicable to both the singular and plural thereof. A. Issuing Office: The office from which the Bidding Documents are to be issued and where the bidding procedures are to be administered. ARTICLE 2 COPIES OF BIDDING DOCUMENTS 2.01 Complete sets of the Bidding Documents in the number and for the amount stated in the Advertisement for Bids may be obtained from the Issuing Office as identified in the advertisement. The deposit/fee will be refunded in accordance with the conditions indicated in the Advertisement for Bids. 2.02 Complete set of Bidding Documents must be used in preparing bids; neither Owner nor Engineer assumes any responsibility for errors or misinterpretations resulting from the use of incomplete set of Bidding Documents. 3097-F: 05/18/15 00200-1 Instruction to Bidders Document in accordance with EJCDC No. C-200 (2007) & RUS Bulletin 1780-26, Attachment F, 10/2007 2.03 Owner and Engineer in making copies of Bidding Documents available on the above terms do so only for the purpose of obtaining Bids for the Work and do not confer a license or grant for any other use. ARTICLE 3 MINORITY PARTICIPATION GOALS 3.01 Bidders must make positive efforts to utilize minority businesses. The Owner has developed a goal of ten percent (10%) for participation of minority business enterprises in construction contracts awarded pursuant to NCGS 143-128(c). 3.02 Bidder shall be required to submit identification of firms and Affidavits as required in the Bid Form. ARTICLE 4 QUALIFICATIONS OF BIDDERS 4.01 Bidders are notified that Chapter 87, Article(s) 1 of the General Statutes of North Carolina, will be observed in receiving and awarding contracts. Bidders for this Project must be licensed in the following classifications and limitations: A. General: Must have a General Contractors license with one of the following classifications with a limitation appropriate to the bid amount. 1. Classifications: a. Unclassified b. Public Utilities Contractor c. Public Utilities (Water Lines and Sewer Lines) 2. Limitations: a. "Limited": Up to $500,000 b. "Intermediate": Up to $1,000,000 c. "Unlimited": No limit on contract value B. Plumbing: Must have a Class I license. 4.02 To demonstrate Bidder's qualifications to perform the Work prior to award, within five (5) days of Owner's request, Bidder shall submit written evidence which shall include, but not be limited to, the following: A. Official name of Bidder and length of time the organization has been in business under present name. B. Address, phone and fax numbers of main place of business. Address and phone numbers of company office that will manage the Project if different than above. C. Officers of the company. Name and resume of designated project manager and field superintendent. Number of regular employees of the organization. D. Latest financial statement showing assets and liabilities of the company. E. Name and home office address of the Surety proposed and the name and address of the responsible local claim agent. F. Listing of completed projects of similar size and type. Provide name and phone number of project owner representative. G. Existing work commitments. H. List of work to be subcontracted. Name and addresses of subcontractors. I. Names and addresses of major material Suppliers. Instruction to Bidders 00200-2 3097-F: 05/18/15 Document in accordance with EJCDC No. C-200 (2007) & RUS Bulletin 1780-26, Attachment F, 10/2007 J. Statement that bidder is capable of completing the project within the stated time. K. The apparent Low Bidder shall submit within 72 hours of the Bid Date the following Affidavits: 1. Affidavit C, Portion of the Work to be Performed by Minority Firms. 2. Affidavit D, Good Faith Efforts 4.03 Any additional submittals required with the General Conditions, Supplementary Conditions, or the State and Federal Special Conditions shall be submitted within the stated timeframes and on the supplied forms, where available. 4.04 Failure or refusal to furnish information requested shall constitute a basis for disqualification of Bidder and the withholding of the Bid Bond. ARTICLE 5 EXAMINATION OF BIDDING DOCUMENTS, OTHER RELATED DATA, AND SITE 5.01 Subsurface and Physical Conditions A. The Supplementary Conditions identify: 1. Those reports of explorations and tests of subsurface conditions at or contiguous to the Site that Engineer has used in preparing the Bidding Documents. 2. Those drawings of physical conditions in or relating to existing surface and subsurface structures at or contiguous to the Site (except Underground Facilities) that Engineer has used in preparing the Bidding Documents. B. Copies of reports and drawings referenced in Paragraph 5.01.A will be made available by Owner to any Bidder on request. Those reports and drawings are not part of the Contract Documents, but the "technical data" contained therein upon which Bidder is entitled to rely as provided in Paragraph 4.02 of the General Conditions has been identified and established in Paragraph 4.02 of the Supplementary Conditions. Bidder is responsible for any interpretation or conclusion Bidder draws from any "technical data" or any other data, interpretations, opinions or information contained in such reports or shown or indicated in such drawings. 5.02 Underground Facilities A. Information and data shown or indicated in the Bidding Documents with respect to existing Underground Facilities at or contiguous to the Site is based upon information and data furnished to Owner and Engineer by owners of such Underground Facilities, including Owner, or others. 5.03 Provisions concerning responsibilities for the adequacy of data furnished to prospective Bidders with respect to subsurface conditions, other physical conditions and Underground Facilities, and possible changes in the Bidding Documents due to differing or unanticipated conditions appear in paragraphs 4.02, 4.03, and 4.04 of the General Conditions. Provisions concerning responsibilities for the adequacy of data furnished to prospective Bidders with respect to a Hazardous Environmental Condition at the Site, if any, and possible changes in the Contract Documents due to any Hazardous Environmental Condition uncovered or revealed at the Site which was not shown or indicated in 3097-F: 05/18/15 00200-3 Instruction to Bidders Document in accordance with EJCDC No. C-200 (2007) & RUS Bulletin 1780-26, Attachment F, 10/2007 the Drawings or Specifications or identified in the Contract Documents to be within the scope of the Work appear in paragraph 4.06 of the General Conditions. 5.04 On request, Owner will provide Bidder access to the Site to conduct such examinations, investigations, explorations, tests, and studies as Bidder deems necessary for submission of a Bid. Bidder shall fill holes and clean up and restore the Site to its former condition upon completion of such explorations, investigations, tests, and studies. Bidder shall comply with all applicable Laws and Regulations relative to excavation and utility locates. 5.05 Additional Owner Provided Information: A. Reference is made to Article 7 of the Supplementary Conditions for the identification of the general nature of other work that is to be performed at the Site by Owner or others (such as utilities and other prime contractors) that relates to the Work contemplated by these Bidding Documents. On request, Owner will provide to each Bidder for examination access to or copies of Contract Documents (other than portions thereof related to price) for such other work. 5.06 It is the responsibility of each Bidder before submitting a Bid to: A. Examine and carefully study the Bidding Documents, the other related data identified in the Bidding Documents, and any Addenda; B. Visit the Site and become familiar with and satisfy Bidder as to the general, local and Site conditions that may affect cost, progress, and performance of the Work; C. Become familiar with and satisfy Bidder as to all federal, state and local Laws and Regulations that may affect cost, progress, and performance of the Work; D. Carefully study all: (1) reports of explorations and tests of subsurface conditions at or contiguous to the Site and all drawings of physical conditions in or relating to existing surface or subsurface structures at or contiguous to the Site (except Underground Facilities) which have been identified in the Supplementary Conditions as provided in paragraph 4.02 of the General Conditions, and (2) reports and drawings of Hazardous Environmental Condition at the Site which have been identified in the Supplementary Conditions as provided in paragraph 4.06 of the General Conditions; E. Obtain and carefully study (or assume responsibility for not doing so) all additional or supplementary examinations, investigations, explorations, tests, studies, and data concerning conditions (surface, subsurface, and Underground Facilities) at or contiguous to the Site which may affect cost, progress, or performance of the Work or which relate to any aspect of the means, methods, techniques, sequences, and procedures of construction to be employed by Bidder, including any specific means, methods, techniques, sequences, and procedures of construction expressly required by the Bidding Documents, and safety precautions and programs incident thereto; F. Agree at the time of submitting its Bid that no further examinations, investigations, explorations, tests, studies, or data are necessary for the determination of its Bid for performance of the Work at the price(s) bid and Instruction to Bidders 00200-4 3097-F: 05/18/15 Document in accordance with EJCDC No. C-200 (2007) & RUS Bulletin 1780-26, Attachment F, 10/2007 within the times and in accordance with the other terms and conditions of the Bidding Documents; G. Become aware of the general nature of the work to be performed by Owner and others at the Site that relates to the Work as indicated in the Bidding Documents; H. Correlate the information known to Bidder, information and observations obtained from visits to the Site, reports and drawings identified in the Bidding Documents, and all additional examinations, investigations, explorations, tests, studies, and data with the Bidding Documents; I. Promptly give Engineer written notice of all conflicts, errors, ambiguities, or discrepancies that Bidder discovers in the Bidding Documents and confirm that the written resolution thereof by Engineer is acceptable to Bidder; and J. Determine that the Bidding Documents are generally sufficient to indicate and convey understanding of all terms and conditions for the performance of the Work. 5.07 The submission of a Bid will constitute an incontrovertible representation by Bidder that Bidder has complied with every requirement of this Article, that without exception the Bid is premised upon performing and furnishing the Work required by the Bidding Documents and applying any specific means, methods, techniques, sequences, and procedures of construction that may be shown or indicated or expressly required by the Bidding Documents, that Bidder has given Engineer written notice of all conflicts, errors, ambiguities, and discrepancies that Bidder has discovered in Bidding Documents and the written resolutions thereof by Engineer are acceptable to Bidder, and that the Bidding Documents are generally sufficient to indicate and convey understanding of all terms and conditions for performing and furnishing the Work. 5.08 After Bids have been submitted, Bidder shall not assert that there was a misunderstanding concerning the quantities of Work or of the nature of Work to be done. 5.09 Bidding Documents contain the provisions required for construction of the Project. Information obtained from an officer, agent, or employee of the Owner or any other person shall not affect the risks or obligations assumed by the Bidder or relieve him from fulfilling the conditions of the contract. 5.10 Failure or omission of Bidder to do the foregoing shall in no way relieve Bidder from the obligations in respect to his Bid. ARTICLE 6 SITE AND OTHER AREAS 6.01 The Site is identified in the Bidding Documents. Easements for permanent structures or permanent changes in existing facilities are to be obtained and paid for by Owner unless otherwise provided in the Bidding Documents. Additional lands and access thereto required for temporary construction facilities, construction equipment, or storage of materials and equipment to be incorporated in the Work are to be obtained and paid for by Contractor. ARTICLE 7 INTERPRETATIONS AND ADDENDA 7.01 Questions about the meaning or intent of the Bidding Documents are to be submitted to Engineer in writing. Questions may be faxed or e-mailed. Questions 3097-F : 05/18/15 00200-5 Instruction to Bidders Document in accordance with EJCDC No. C-200 (2007) & RUS Bulletin 1780-26, Attachment F, 1012007 will not be taken by phone. Engineer's fax number is 1-336-626-5722. E-mail address is jgrey@thewootencompany.com. 7.02 Submittal with questions shall include the project name, the person's name submitting the question, firm, telephone number, fax number and e-mail when available. 7.03 Interpretations or clarifications considered necessary by Engineer in response to such questions will be issued by Addenda delivered to parties recorded by Engineer as having received the Bidding Documents. Questions received less than five working days prior to the date for opening of Bids may not be answered. Only questions answered by Addenda will be binding. Oral and other written interpretations or clarifications will be without legal effect. 7.04 Addenda may be issued to clarify, correct, or change the Bidding Documents as deemed advisable by Owner or Engineer. ARTICLE 8 BID SECURITY 8.01 Bid must be accompanied by Bid security made payable to Owner in an amount of 5 percent of Bidder's maximum Bid price and in the form of a certified or bank check or a Bid Bond (on the form attached) issued by a surety meeting the requirements of paragraphs 5.01 and 5.02 of the General Conditions. 8.02 The Bid security of the Successful Bidder will be retained until such Bidder has executed the Contract Documents, furnished the required contract security and met the other conditions of the Notice of Award, whereupon the Bid security will be returned. If the Successful Bidder fails to execute and deliver the Contract Documents and provide the required contract security within 10 days after the Notice of Award, Owner may annul the Notice of Award and the Bid security of that Bidder will be forfeited. The Bid security of other Bidders whom Owner believes to have a reasonable chance of receiving the award may be retained by Owner until the earlier of seven days after the Effective Date of the Agreement or the end of the Bid holding period as indicated in the Bid Form, whereupon Bid security furnished by such Bidders will be returned. 8.03 Bid security of other Bidders whom Owner believes do not have a reasonable chance of receiving the award will be returned within seven days after the Bid opening. ARTICLE 9 CONTRACT TIMES 9.01 The number of days within which, or the dates by which, the Work is to be substantially completed and ready for final payment are set forth in the Agreement. ARTICLE 10 LIQUIDATED DAMAGES 10.01 Provisions for liquidated damages, if any, are set forth in the Agreement. ARTICLE 11 SUBSTITUTE AND OR -EQUAL ITEMS 11.01 The Contract, if awarded, will be on the basis of materials and equipment specified or described in the Bidding Documents without consideration of possible substitute or "or -equal" items. Whenever it is specified or described in the Bidding Documents that a substitute or "or -equal" item of material of equipment may be furnished or used by Contractor if acceptable to Engineer, Instruction to Bidders 00200-6 3097-F: 05/18/15 Document in accordance with EJCDC No. C-200 (2007) & RUS Bulletin 1780-26, Attachment F, 1012007 application for such acceptance will not be considered by Engineer until after the Effective Date of the Agreement. ARTICLE 12 SUBCONTRACTORS, SUPPLIERS, AND OTHERS 12.01 If the Supplementary Conditions require the identity of certain Subcontractors, Suppliers, or others to be submitted to Owner in advance of a specified date prior to the Notice of Award, the apparent Successful Bidder, and any other Bidder so requested, shall within five days after Bid opening, submit to Owner a list of such Subcontractors, Suppliers, and others proposed for those portions of the Work for which such identification is required. An experience statement shall accompany such list with pertinent information regarding similar projects and other evidence of qualification for each such Subcontractor, Supplier, and others if requested by Owner. If Owner or Engineer, after due investigation, has reasonable objection to any proposed Subcontractor, Supplier, or others, Owner may, before the Notice of Award is given, request apparent Successful Bidder to submit a substitute, without an increase in the Bid. 12.02 If apparent Successful Bidder declines to make any such substitution, Owner may determine such Bidder to be non-responsive, reject the Bid, and award the Contract to the next lowest Bidder that proposes to use acceptable Subcontractors, Suppliers, individuals, or entities. Declining to make requested substitutions will not constitute grounds for forfeiture of the Bid security of any Bidder. Subcontractor, Supplier, or others so listed and against which Owner or Engineer makes no written objection prior to the giving of the Notice of Award will be deemed acceptable to Owner and Engineer subject to revocation of such acceptance after the Effective Date of the Agreement as provided in paragraph 6.06 of the General Conditions. 12.03 Contractor shall not be required to employ any Subcontractor, Supplier, individual, or entity against whom Contractor has reasonable objection. 12.04 The Contractor shall not award work to Subcontractor(s) in excess of the limits stated in SC 6.06. ARTICLE 13 FUNDING REQUIREMENTS 13.01 This material is based upon work supported in whole or part by the NC Rural Economic Development Center. Any opinions, findings, conclusions, or recommendations expressed in this publication are those of the author(s) and do not necessarily reflect the views and polices of the NC Rural Economic Development Center. ARTICLE 14 PREPARATION OF BID 14.01 The Bid form is included with the Bidding Documents. Additional copies may be obtained from Engineer. 14.02 Bids must be made on required Bid Form. Blanks on the Bid Form shall be completed by printing in ink. Erasures or alterations shall be initialed in ink by the person signing the Bid Form. A Bid Price shall be indicated for each item listed therein, or the words "No Bid," "No Change," or "Not Applicable' entered. Unsigned modifications to Bid Form may cause Bid to be rejected. 14.03 The Bid shall contain an acknowledgment of receipt of all Addenda, the numbers of which shall be filled in on the Bid form. It is the bidder's responsibility to confirm the final number of addendums with Engineer prior to submitting the bid. 3097-F: 05/18/15 00200-7 Instruction to Bidders Document in accordance with EJCDC No. C-200 (2007) & RUS Bulletin 1780-26, Attachment F, 10/2007 14.04 The postal and email addresses and telephone number for communication regarding the Bid shall be shown. 14.05 The Bid shall contain evidence of Bidder's authority and qualification to do business in the state or locality where the Project is located. Bidder's state contractor license number shall also be shown on the Bid form. 14.06 Bid Form shall be executed as follows: A. Sole Owner: Evidenced by word "owner" appearing after the name of the person -executing document. B. Partnership: Executed in the partnership name and signed by a partner, whose title shall appear under the signature, accompanied by evidence of authority to sign. C. Corporation: Executed in the corporate name by the president or vice- president or other corporate officer accompanied by evidence of authority to sign. Corporate seal shall be affixed and attested by secretary or assistant secretary and the title of the office of such person shall appear after their signatures. D. Joint Venture: Executed by each member of the Joint Venture in the above form for sole owner, partnership, or corporation, whichever form is applicable. E. Limited Liability Company: Executed in the name of the firm by a member and accompanied by evidence of authority to sign. F. Signatures shall be signed in ink and properly witnessed. G. Names shall be typed or printed in ink below the signatures. H. Official mailing address of owner, partnership, corporation, or joint venture shall be shown below the signature. 14.07 Bidder shall complete the form, Identification of Minority Business Participation, identifying the minority businesses that will be utilized on the project with corresponding total dollar value and Affidavit A, Listing of Good Faith Efforts, or Affidavit B, Intent to Perform Contract with own Workforce, as required by G.S. 143-128.2(c) and G.S. 143-128.2(f). Failure to comply with these requirements is grounds for rejection of the bid. ARTICLE 15 SUBMITTAL OF BID 15.01 The Owner, at the location and time indicated in the Advertisement for Bids, will receive sealed Bids. Bids received after the indicated time and date shall not be considered. 15.02 Bid form is to be completed and submitted with all the attachments outlined in Article 7 of the Bid Form, including the E -Verify Affidavit. The complete list of required bid documents can also be found in the attached Bidder's Checklist. The checklist shall be the first page of all bids submitted. 15.03 Submit Bid in an opaque sealed envelope plainly marked on the outside with the following: Bid for Old Salisbury Road Sewer Bidder's name and address N.C. Contractor's license number with classification and limitation Instruction to Bidders 00200-8 3097-F: 05/18/15 Document in accordance with EJCDC No. C-200 (2007) & RUS Bulletin 1780-26, Attachment F, 10/2007 15.04 If forwarded by mail or other delivery system, enclose sealed envelope containing Bid and information listed above in another envelope with notation "BID ENCLOSED" and addressed to: Dwayne Childress P.O. Box 1067 913 Greensboro St Lexington, N. C. 27293 When using the mail or other delivery system, the Bidder is totally responsible for the mail or other delivery system delivering the Bid at the place and prior to the time indicated in the Advertisement for Bid. ARTICLE 16 MODIFICATION AND WITHDRAWAL OF BID 16.01 A Bid may be modified or withdrawn by an appropriate document duly executed in the manner that a Bid must be executed and delivered to the place where Bids are to be submitted prior to the date and time for the opening of Bids. Modifications shall indicate only the amount to be added to or deducted from the Bidder's Bid amount as submitted on the Bid Form. 16.02 No Bid may be withdrawn after the Bid opening for a period of time as indicated in the Bid Form except in accordance with the provisions of N. C. General Statues 143-129.1. ARTICLE 17 OPENING OF BIDS 17.01 Bids will be opened at the time and place indicated in the Advertisement for Bids and, unless obviously non-responsive, read aloud publicly. An abstract of the amounts of the base Bids and major alternates, if any, will be made available to Bidders after the opening of Bids. ARTICLE 18 BIDS TO REMAIN SUBJECT TO ACCEPTANCE 18.01 Bids will remain subject to acceptance for the period of time stated in the Bid form, but Owner may, at its sole discretion, release any Bid and return the Bid security prior to the end of this period. ARTICLE 19 BASIS OF BID; COMPARISON OF BIDS 19.01 Unit Price A. Bidders shall submit a Bid on a unit price basis for each item of Work listed in the Bid schedule. S. The total of all bid prices will be determined as the sum of the products of the estimated quantity of each item and the corresponding unit price bid for the item. The final quantities and Contract Price will be determined in accordance with paragraph 11.03 of the General Conditions. C. Discrepancies between the multiplication of units of Work and unit prices will be resolved in favor of the unit prices. Discrepancies between the indicated sum of any column of figures and the correct sum thereof will be resolved in favor of the correct sum. Discrepancies between words and figures will be resolved in favor of the words. 3097-F: 05/18/15 00200-9 Instruction to Bidders Document in accordance with EJCDC No. C-200 (2007) & RUS Bulletin 1780-26, Attachment F, 10/2007 ARTICLE 20 EVALUATION OF BIDS AND AWARD OF CONTRACT 20.01 Owner reserves the right to reject any or all Bids, including without limitation, nonconforming, non-responsive, unbalanced, or conditional Bids. Owner further reserves the right to reject the Bid of any Bidder whom it finds, after reasonable inquiry and evaluation, to be non-responsive. Owner also reserves the right to waive informalities not involving price, time, or changes in the Work and to negotiate contract terms with the Successful Bidder. 20.02 More than one Bid for the same Work from an individual or entity under the same or different names will not be considered. Reasonable grounds for believing that any Bidder has an interest in more than one Bid for the Work may be cause for disqualification of that Bidder and the rejection of Bids in which that Bidder has an interest. 20.03 In evaluating Bids, Owner will consider whether or not the Bids comply with the prescribed requirements, and such alternates, unit prices and other data, as may be requested in the Bid Form or prior to the Notice of Award. 20.04 In evaluating Bidders, Owner will consider the qualifications of Bidders and may consider the qualifications and experience of Subcontractors, Suppliers, and other individuals or entities proposed for those portions of the Work for which the identity of Subcontractors, Suppliers, and other individuals or entities must be submitted as provided in the Supplementary Conditions. 20.05 Owner may conduct such investigations as Owner deems necessary to establish the responsibility, qualifications, and financial ability of Bidders, proposed Subcontractors, Suppliers, individuals, or entities to perform the Work in accordance with the contract Documents. 20.06 In determining the lowest responsible Bidder, Owner shall take into consideration the past performance of Bidder on construction contracts with particular concern given to completion times, quality of work, cooperation with other contractors, and cooperation with owner. 20.07 In determining the responsive Bidder, Owner shall take into consideration bidder's compliance with the requirements of G.S. 143-128.2(c). Failure of the low bidder to furnish affidavit(s) and documentation as required by the Bid Form for compliance with G.S. 143-128.2(c) may constitute a basis for disqualification of the Bid. 20.08 Owner reserves the right to reject Bid if the evidence submitted by, or investigation of, such Bidder fails to satisfy Owner that such Bidder is properly qualified to carry out the obligations of the Agreement and to complete the Work described therein. 20.09 Should the Owner adjudge that the apparent low Bidder is not the lowest responsible Bidder by virtue of the above information, said apparent low Bidder will be so notified and his Bid security shall be returned. 20.10 If the Contract is to be awarded, Owner will award the Contract to the responsible Bidder whose Bid, conforming with all the material terms and conditions of the Instruction to Bidders, is lowest, price and other factors considered. If detailed in the bid form, factors such as discounts, transportation costs, and life cycle costs may be used to determine which bidder, if any, is to be offered the award. Instruction to Bidders 00200-10 3097-F: 05/18/15 Document in accordance with EJCDC No. C-200 (2007) & RUS Bulletin 1780-26, Attachment F, 10/2007 ARTICLE 21 CONTRACT SECURITY AND INSURANCE 21.01 Article 5 of the General Conditions, as may be modified by the Supplementary Conditions, sets forth Owner's requirements as to Performance Bond, Payment Bond, and other Bonds and insurance. When the Successful Bidder delivers the executed Agreement to Owner, it must be accompanied by such Bonds. ARTICLE 22 SIGNING OF AGREEMENT 22.01 When Owner gives a Notice of Award to the Successful Bidder, it shall be accompanied by the required number of unsigned counterparts of the Agreement with the other contract Documents which are identified in the Agreement as attached thereto. Within 10 days thereafter, Successful Bidder shall sign and deliver the required number of counterparts of the Agreement, Bonds, Insurance, and other documents to Owner. Within 10 days thereafter, Owner shall deliver one fully signed counterpart to Successful Bidder with a complete set of the Drawings with appropriate identification. 22.02 In case of failure of Bidder to execute the Agreement, Owner may at his option consider Bidder in default, in which case Bid Bond accompanying Bid shall become the property of the Owner. 22.03 Applicable laws, ordinances, and the rules and regulations of authorities having jurisdiction over construction of the Project shall apply to the contract throughout. ARTICLE 23 SALES AND USE TAXES 23.01 The Owner is NOT exempt from sales tax. Said taxes must be included in the bid. END OF DOCUMENT 3097-F: 05/18/15 00200-11 Instruction to Bidders Document in accordance with EJCDC No. C-200 (2007) & RUS Bulletin 1780-26, Attachment F, 10/2007 BIDDER'S CHECKLIST This checklist shall be included as the first page of the submitted bidding documents. As outlined in article 7 of the Bid Form the following items shall be included with the submitted bidding documents: eroperly Executed Bid Form (Including the acknowledgement of all Addenda) Required Bid security in the form of a Bid Bond EJ CDC No C-430 or Certified A. (/Check (circle type of security provided�Bond shall be inclu a ai executed Power of Attorney.___ Identification of Minority Business Participation k s; or Affidavit B, Intent to Perform - Contract with Own Workforce C. E -Verify Affidavit G. I List of Proposed Subcontractors j 3097-F : 04/20/15 00410-a Bidder's Checklist Document in accnrdunce with RUS Bulletin 1780-26. Attachment G 1012009 BID FORM PROJECT: Old Salisbury Road Sewer BID FROM: R e(Kf)C. I N L TABLE OF ARTICLES page Article 1 — Bid Recipient 1 Article 2 — Bidders Acknowledgements Article 3 — Bidders Representations Article 4 — Bidder's Certification Article 5 — Basis of Bid Article 6 — Time of Completion Article 7 — Attachments to this Bid Article 8 — Defined Terms Article 9 — Bid Submittal ARTICLE 1 BID RECIPIENT 1.01 This Bid is Submitted To: Davidson County P.O. Box 1067 925 North Main Street Lexington, NC 27293 1.02 Undersigned bidder proposes and agrees, if this Bid is accepted, to enter into an Agreement with the Owner in the form included in the Bidding Documents to perform the Work as specified or indicated in the Bidding Documents for the prices and within the times indicated in the Bid and In accordance with the other terms and conditions of the Bidding Documents. ARTICLE 2 BIDDER'S ACKNOWLEDGEMENTS 2.01 Bidder accepts all of the terms and conditions of the Advertisement and Instructions to Bidders, including without limitation those dealing with the disposition of Bid security. This Bid will remain subject to acceptance for 60 days after the Bid opening, or for such longer period of time that Bidder may agree to in writing upon request of Owner. ARTICLE 3 BIDDER'S REPRESENTATIONS 3.01 In submitting this Bid, Bidder represents that: A. Bidder has examined and carefully studied the Bidding Documents, the other related data identified in the Bidding Documents, and the following Addenda, receipt of which is hereby acknowledged. g Addenda 1 , P, 3097-F: 05/19/15 00410-1 Bid Form Document in arcoMance with EJCDC No. C-010 (2007) 8 RUS Bulletin 1780-26, Attachment G. 10/2009 B. Bidder has visited the Site and become familiar with and is satisfied as to the general, local and Site conditions that may affect cost, progress, and performance of the Work. C. Bidder is familiar with and is satisfied as to federal, state and local Laws and Regulations that may affect cost, progress, and performance, of the Work. D. Bidder has carefully studied all: (1) reports of explorations and tests of subsurface conditions at or contiguous to the Site and all drawings of physical conditions in or relating to existing surface or subsurface structures at or contiguous to the Site (except Underground Facilities) which have been identified in SC -4.02, and (2) reports and drawings of Hazardous Environmental Conditions, if any, that have been identified in SC -4.06 as containing reliable 'technical data'. E. Bidder has considered the information known to Bidder; information commonly known to contractors doing business in the locality of the Site; information and observations obtained from visits to the Site; the Bidding Documents: and the Site - related reports and drawings identified in the Bidding Documents, with respect to the effect of such information, observations, and documents on (1) the cost, progress, and performance of the Work; (2) the means, methods, techniques, sequences, and procedures of construction to be employed by Bidder, including applying the specific means, methods, techniques, sequences, and procedures of construction expressly required by the Bidding Documents; and (3) Bidder's safety precautions and programs. F. Based on the information and observations referred to in Paragraph 3.01.E above, Bidder does not consider that any further examinations, investigations, explorations, tests, studies, or data are necessary for the determination of this Bid for performance of the Work at the price(s) bid and within the times and in accordance with the other terms and conditions of the Bidding Documents. G. Bidder is aware of the general nature of work to be performed by Owner and others at the Site that relates to the Work as indicated in the Bidding Documents. H. Bidder has given Engineer written notice of all conflicts, errors, ambiguities, or discrepancies that Bidder has discovered in the Bidding Documents, and the written resolution thereof by Engineer is acceptable to Bidder. I. The Bidding Documents are generally sufficient to indicate and convey understanding of all terms and conditions for the performance of the Work for which this Bid is submitted. J. Bidder will submit written evidence of its authority to do business in the state where the Project is located not later than the date of its execution of the Agreement. ARTICLE 4 BIDDER'S CERTIFICATION 4.01 Bidder further represents that: A. This Bid is genuine and not made in the interest of or on behalf of any undisclosed individual or entity and is not submitted in conformity with any agreement or rules of any group, association, organization or corporation; B. Bidder has not directly or indirectly induced or solicited any other Bidder to submit a false or sham Bid; Bid Form 00410-2 3097-F: 05/06/15 omimarrt in accordance with EJCOC No. C41012007) 8 RUS Bulletin 1760-26, Attachment G. 10/2009 C. Bidder has not solicited or induced any individual or entity to refrain from bidding; and D. Bidder has not engaged in corrupt, fraudulent, collusive, or coercive practices in competing for the Contract. For the purposes of this Paragraph 4.01.13: 1. "corrupt practice" means the offering, giving, receiving, or soliciting of any thing of value likely to influence the action of a public official in the bidding process; 2. "fraudulent practice" means an intentional misrepresentation of facts made (a) to influence the bidding process to the detriment of Owner, (b) to establish bid prices at artificial non-competitive levels, or (c) to deprive Owner of the benefits of free and open competition; 3. "collusive practice" means a scheme or arrangement between two or more Bidders, with or without the knowledge of Owner, a purpose of which is to establish bid prices at artificial, non-competitive levels; and 4. "coercive practice" means harming or threatening to harm, directly or indirectly, persons or their property to influence their participation in the bidding process or affect the execution of the Contract. ARTICLE 5 BASIS OF BID 5.01 Bidder will complete the Work in accordance with the Contract Documents for the following price(s): A. For Unit Price Work, an amount equal to the sum of the established unit price for each separately identified item of Unit Price Work times the estimated quantity of that item as indicated below. Item Descri tion P Unit Estimated Quantit Unit Price Total Estimated Price No. 1 obilization LS 1 1 n - i 2 " Sanita Sewer, Depth 0-6 ft LF 89 a2 .Ol3 T / LN2 3 " Santa Sewer Death 6-8 ft LF 1:010 • aU 4 " Sanita Sewer, Denth 8-10 ft LF 1,206 a� a� ♦ • r 5 " Sant Sewer, Death 10-12 ft LF 278 V 6 " Sanita Sewer, De th 12-14 ft LF 148 b Ln, 7 "Santa Sewer, De th 14-16 it LF 17 •. 8 "DIP Sanita Sewer, De th 0- fl LF 29 L' �. 1 I 6O r e 9 "DIPS nits Sewer, Depth 6-8 ft LF 129 10 "Dip Sanitary Sewer, De th B-10 ft LF 13 L& L 1 • 11 8" DIP Sanita Sewer, Death 10-12 ft LF 16 16 -a7161%-- 12 " DIP Sanita Sewer: Death 12-14 ft LF 8 r5 L OU 13 " DIP Sanita Sewer, De th 14-16 ft LF 52 1r 18" Steel Encasement Pipe By Bore And 14 ack With 8" DIP Installed In Encasement �. Pi e— Guaranteed Installation LF 100 3097-F : 05/19/15 00410-3 Bid Form Document in acc dance with EJCDC No. C-410 (2007)& RDS Bulletin 179040, Attachment G. 1012009 Item No. Description Unit Estimated Quandt Unit Price Total Estimated Price 15 ' Dia. Manholes, 0-6 it EA 1 a "00 ' •D0, " 16 ' Dia. Manholes 8-12 ft EA 7 r L/Op ' GO 17 4'Dia. Manholes, 10-12 ft FA 4 3"500.— j 00o' — t8 ' Dia. Manholes, 14-16 ft EA 1 L ov , — 19 " Sarritata Sewer Service EA 1 20 Connect New 8" Sanitary Sewer To Existin.9 Manhole EA 1 21 Rock Excavation CY 100 1 0 j,- 22 ndercutUnstable Pipe Foundation CY 300 LI c: 500," 23 elect Backfill CY 300 33s, I o " 24 Temporary Stream Crossing EA 3 60 3 0 00, 25 em Construction Entrance EA 4 Six,- r1 pav — 26 tone Outlet EA 12 3 � 1 — 0 "`) 27 Rock Check Dam EA 1 'r 00 00,- 28 Silt Fence LF 3,384 i 5 ('j 7 (o, — 29 lass B Rilrap SY 143 35.00 .� o , 30 rosion Control Matting SY 345 , a Total Bid Price Ci B. Unit Prices have been computed in accordance with paragraph 11-03.6 of the General Conditions. C. Bidder acknowledges that estimated quantities are not guaranteed, and are solely for the purpose of comparison of Bids, and final payment for Unit Price Bid items will be based on actual quantities, determined as provided in the Contract Documents. Determinations of actual quantities and classification are to be made by Engineer as provided in paragraph 9.07 of the General Conditions. ARTICLE 6 TIME OF COMPLETION 6.01 Bidder agrees that the Work will be completed and ready for final payment in accordance with paragraph 14.07 of the General Conditions on or before the dates or within the number of calendar days indicated in the Agreement. 6.02 Bidder accepts the provisions of the Agreement as to liquidated damages. ARTICLE 7 ATTACHMENTS TO THIS BID 7.01 The following documents are attached to and made a condition of this Bid. Failure to provide the documentation with the bid may be grounds for rejection of the bid. A. Required Bid security in the form of a Bid Bond (EJCDC No. C-430) or Certified Check (circle type of security provided). B. in accordance with GS 143-128.2(c), Bidder shall identify on its bid the minority businesses that it will use on the project and the total dollar value of the bid that will Bid Form 00410-4 3097-F: 05/06/15 Document in acmniance with EJCDC No. C410 (2007) & RUS Bulletin 1780-26, Attachment G, 1012009 be performed by the minority businesses and list the good faith efforts (Affidavit A) made to solicit participation. A Bidder that will perform ail of the work with its own workforce may submit an Affidavit (B) to that effect in lieu of the affidavit (A) required above - 1 - bove.1. Identification of Minority Business Participation. 2. Affidavit A, Listing of Good Faith Efforts; or Affidavit B, Intent to Perform Contract with Own Workforce. 7.02 Submit the Bidder's Checklist as provided in the bidding documents with the bid submittal. The Checklist shall be completed and included as the first page of the submittal. 7.03 After the bid opening the Owner will consider all bids and alternates and determine the lowest responsible, responsive bidder. Upon notification of being the apparent low Bidder, the Bidder shall then file within 72 hours of the notification of being the apparent lowest bidder, the following: A. An Affidavit (C) that includes a description of the portion of work to be executed by minority businesses, expressed as a percentage of the total contract price, which is equal to or more than the goal established by the Owner and indicated in the Instruction to Bidders, paragraph Minority Participation Goals. This affidavit shall give rise to the presumption that the bidder has made the required good faith effort; or B. Affidavit (D) of its good faith effort to meet the goal. The document must include evidence of all good faith efforts that were implemented, including any advertisements, solicitations and other specific actions demonstrating recruitment and selection of minority businesses for participation in the contract. 7.04 Bidder understands that if this Bid is accepted by the Owner, Bidder shall not substitute for the subcontractors named in the Bid Documents except as allowed in the Supplementary Conditions, ARTICLE 8 DEFINED TERMS 8.01 The terms used in this Bid with initial capital letters have the meanings stated in the Instructions to Bidders, the General Conditions, and the Supplementary Conditions. ARTICLE 9 BID SUBMITTAL 9.01 Contractor's License A. cr A. Number: / 7 I S B. Classification:� 1A%A.JV31 Sevvt) C. Limitation: (e Employer's Tax ID No.: Ll -1 fr'A 1 l Business Addre s Ota��S� S Phone No.:51c1 15 �7 3 q 3097-F:05/06/15 00410-5 Bid Form Dnwment in accordance with EJCDC No. C410 (2007) 8 RUS Bulletin 1780-26. Attachment G, 10/2000 Fax No.: E -Mail Address: Vq� " C0k0-rOSt P S,M411 „(0m 9.02 This Bid Submitted by: An Individual Nar By: Doing Business As: (Type or print) A Partnership Partnership Name: The Organization and Internal Affairs of thf Partnership are governed by the laws of the State of: By: Name: (Signature of gent{a`partntr, Itac4evidhme of authority to sign) Or Title: (Type or print) Attest: (Signature of Corporate Secretary) Bid Form 00410-6 3097-F: 05/06/15 Domment in accordance with EJCDC No. C410 (2007) & RUS Buttet n 1780-28, Attachment G, 10/2009 A Corporation Corporation Name: U�ji U\, State of Incorporation: k j Aa (' Type (General Business, PcQiess r,r Service, la ility): 0 attach evidence of authority to sign) Name: VIVI W 0 J� (�Type/o'r�print) Title: lJ C 1 (Type or print) - - Attest: S— Corporate Seal (Signature pff Corporate Secretary) , Date of Qualification to do business in North Carolina is _a 0 % Limited Liability Company — LLC Name of LLC: Name of State under whose Laws the Li ited Liability Company was formed: % _ By: _ Name: Title: or (Type or print) END OF DOCUMENT 3097-F : 05/06/15 00410-7 Bid Form Dooumert ir. accordam;e w th EJCDC NeC-410 (2007, & RUS Balleto 1780-26 AtLad-memG. '0 2009 PENAL SUM FC BID BOND (3 Any singular reference to Bidder, Surety, Owner or other party shall be considered plural where applicable. BIDDER (Nome and Address): BBUDC Inc. P.O. Box 52522 Durham, NC 27717-2552 SURETY,(.Name and Address of Principal Place ofl?tainess): The Ohio Casualty Insurance Company 62 Maple Ave. Keene, NH 03431 OWNER (Name and Address): Davidson County P.O, Box 1067 913 Greensboro Street Lexington, N.C. 27293 BID Bid Due Date: June 11, 2015 Description (Project Name and-Include.Location): Installation of approximately 3,100 linear feet of 8 -inch Davidson County Old Salisbury Road Sewer sanitary sewer and associated appurtenances. BOND Bond Number. N/A Date (Not earlier than Bid due date): June 11, 2015 Penal sum five percent of total amount bid $ 5% (Words) (Figures) Surety and Bidder, intending to be legally bound hereby, subject to the terms set forth below, do each cause this Bid Bond to be duly executed by an authorized officer, agent, or representative. ,,t . BIDDER BBUDC Inc. Bidder's a and Corporate Sea[ By: c7 Signature Print Name Title Attest: Signature <i S, t . . Title SURETY (Seal) The Ohio Casualty Insurance Compal (Seal) Surety's Name and Corporate Seal 6 ,v By: Signature (Attach Power of Aft<%rn>ay) David K. Mahler Print Name Attorney -In -Fact Title Attest: __ Si ature'Crystal Barrett Note; Above addresses are to be used for giving required notice. Attestee Title 3097-F: 04101115 00430-1 Bid Bond EJCDC No. C-430 (2467 Edition) PhNAL SUM FC %004 1. Bidder and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successo,s.. and assigns to pay to Owner upon default of Bidder the penal sum set .forth on the face of this Bond. Payment of the penal sum is the extent of Bidder's and Surety's liability. Recovery of such penal sum under the terms of this Bond shall be Owner's sole and exclusive remedy upon default ofBidder, 2. Default of Bidder shall occur upon the failure of Bidder to deliver within the time required by the Bidding Documents (or any extension thereof agreed to in writing by Owner) the executed Agreement required by the Bidding Documents and any performance and payment bonds required by the Bidding Documents. 3. This obligation shall be null and void if, 3.1 Owner accepts Bidder's Bid and Bidder delivers within the time required by the Bidding Documents (or any extension thereof agreed to in writing by Owner) the executed Agreement required by the Bidding Documents and any performance and payment bonds required by the Bidding Documents, or 3.2 All Bids are rejected by Owner, or 3.3 Owner fails to issue a Notice of Award to. Bidder within the time specified in the Bidding Documents (or any extension thereof agreed to in writing by Bidder and, if applicable, consented to by Surety when required by Paragraph 5 hereof). 4. Payment under this Bond will be due and payable upon default of Bidder and within 30 calendar days after receipt by Bidder and Surety of written notice of default from Owner, which notice will be given with reasonable promptness, identifying this Bond and the Project and including a statement of amount due. S. Surety waives notice of any and all defenses based on or arising out of any time extension to issue Notice of Award agreed to in writing by Owner and Bidder, provided that the total time for issuing Notice of Award including extensions shall not in the aggregate exceed 120 days from Bid due date without Surety's written consent. 6. No suit or action shall be commenced under this Bond prior to 30 calendar days after the notice of default required in Paragraph 4 above is received by Bidder and Surety and in no case later than one year after Bid due date. 7. Any suit or action under this Bond shall be commenced only in a court of competent jurisdiction located in the state in which the Project is located. 8. Notices required hereunder shall be in writing and sent to Bidder and Surety at their respective addresses shown on the face of this Bond. Such notices may be sent by personal delivery, commercial courier, or by United States Registered or Certified Mail, return receipt requested; postage pre -paid, and shall be deemed to be effective upon receipt by the party concerned. 9. Surety shall cause to be attached to this Bond a current and effective Power of Attorney evidencing the authority of the officer, agent, or representative who executed this Bond on behalf of Surety to execute, seal, and deliver such Bond and bind the Surety thereby. 10. This Bond is intended to conform to all applicable statutory requirements. Any applicable requirement of any applicable statute that has been omitted from. this Bond shall be deemed to be included herein as if set forth at length. if any provision of this Bond conflicts with any applicable statute, then the provision of said statute shall govern and the remainder of this Bond that is not in conflict therewith shall continue in full. force and effect. 11. The term "Bid" as used herein includes a Bid, offer, or proposal as applicable. 3097-F: 04/01/15 00430-2 Bid Bond £JCDC No. C-430 (2007 Moon) 2 m C {rp THIS POWER OF ATTORNEY IS NOT VALID UNLESS IT IS PRINTED ON RED BACKGROUND. This Power of Attomey limits the acts of those named herein, and they have no authorityto bind the Company except in the manner and to the extent herein stated. Certificate No. American Fire and Casualty Company Liberty Mutual Insurance Company The Ohio Casualty Insurance Company West American Insurance Company POWER OF ATTORNEY KNOWN ALL PERSONS BY THESE PRESENTS: ThatAmerican Fire 8 Casualty Company and The Oh"asualty Insurance Company are corporations duly organized underthe laws of the State of New Hampshire, that Liberty Mutual Insurance Company is a corporation duly organized underihe laws of the State of Massachusetts, and WestAmehican Insurance Company is a corporation duly, organized under the laws of the State of Indiana (herein collectively called the 'Companies"), pursuant to and by authority herein set forge, does hereby name, constitute and appoint, David F. Druml: David K. Mahler all of the city of Foster City , stale of CA each individually if there be more than one named, its true and lawful affomey-in-fact to make, execute, seal, acknowledge and deliver, for and on its behalf as surety and as its act and deed, any and all undertakings, bonds, reiwgnizances and other surety obligations, in pursuance of these presents and shall be as binding upon the Companies as if they have been duty signed by the president and attested by the secretary of the Companies in their own proper persons. IN WITNESS WHEREOF, this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this tom dayof April 2014 > American Fire and Casualty Company The Ohio Casually Insurance Company v as if ! f9D6 cf� a ) 1017 E Liberty Mutual Insurance Company West American Insurance Company ai w t , STATE OF PENNSYLVANIA ss David M. CaAssistant secretary m COUNTY OF MONTGOMERY = On this 10th day of APnI 20i4before me personally appeared David M. Cagy, who acknowledged himself to be the Assistant Secretary of American Fire and V 10- Casualty Company, Liberty Mutual Insurance Company, The Ohio Casualty Insurance Company, and WestAmerican Insurance Company, and that he, as such, being authorized so to do, ) execute the foregoing instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer. d G � IN WITNESS WHEREOF, I have hereunto This Power ofAttomey is made and executed{i Company, Liberty Mutual Insurance Company, id myname ,and affixed my notarial seal at Plymouth Meeting, Pennsylvania, on the day and year first above written. IrOMMONWEALTH OF PkNNSYi.wANtk 1a ( By: Z ' a . 1�r, Teresa Fastens , Notary Public ciM$ ri 9.1 2 timly of the following By-laws and Authorizations ofAmerican Fire and Casualty Company, The Ohio Casually Insurance Insurance Company which resolutions are crow in full force and effect reading as follows: ff0. ARTICLE IV -OFFICERS -Section 12. Power of Attorney. Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President, and subject to such limitation as the Chairman or the President may prescribe, shall appoint such athmeys-in-fact, as may be necessary to act in behalf of the Corporation to make, execute, seal, O S acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attorneys -in -fact, subject to the limitations set forth in their respective E aj powers of attorney, shall have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation. When so O R executed, such instruments shag be as binding as if signed by the President and attested to by the Secretary. Any power or authority granted to any representative or attomey-in-fact under Athe provisions of this article may be revoked at any time by the Board, the Chairman, the President or by the officer or officers granting such power or authority. ,p = ARTICLE XIII - Execution of Contracts - SECTION 5. Surety Bonds and Undertakings. Any officer of the Company authorized for that purpose in writing by the chairman or the president, w i and subect to such limitations as the chairman or the president may prescribe, shall appoint such attomeys-in-fact, as may be (necessary to act in behalf of the Company to make, execute, Zseal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obigations. Such attomeys-in-Nact subject to the limitations sal forth in their respective powers of attorney, shalt have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company: When so executed such instruments shall be as binding as if signed by the president and attested by the secretary. Certificate of Designation - The President of the Company, acting pursuant to the Bylaws of the Company, authorizes David M. Carey, Assistant Secretary to appoint such ahomeys-in- fact as may be necessary to act on behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizance; and other surety obligations. Authorization - By unanimous consent of the Companys Board of Directors, the Company consents that facsimile or mechanically reproduced signature of any assistant secretaryof the Company, wherever appearing upon a certified copy of any power of attorney issued by the Company in connection with surety bonds, shag be valid and binding upon the Company with the same force and effect as though manually affixed. I, Gregory W. Davenport, the undersigned, Assistant Secretary, of American Fire and Casualty Company, The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company do hereby certify that the original power of attorney of which the foregoing is a full, hue and correct copy of the Power of Attorney executed by said Companies, is in full force and effect and has not been revoked. t LI ion Q b IN TESTIMONY WHEREOF, I have hereunto set my hand and sKaed the seals of said Companies this 7 VV ay of e� U 1 ) , 20 113 1Hh > III By: 4 i Gregory W Davenport, Assistant Secretary LMS -12873 122013 - - 91 of 100 M 9 C R E NR 0 O ci c d O ao N M CD t0 r CALIFORAIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California ) County of San Mateo ) On June 9, 2015 Date before me, Soy Wong, Notary Public Here Insert Name and Title of the Officer personally appeared David K. Mahler Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. 17 SOY WONG _.WCommission M 2051554 xNotary Public - California iSan Mateo county r Gomm. Ex Ves Dec 12, 2017 Place Notary Seal Above I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature__ Sign re of Notary Public OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Number of Pages: Document Date: Signer(s) Other Than Named Above: Capacity(es) Claimed by Signer(s) Signer's Name: ❑ Corporate Officer — Title(s): ❑ Partner — ❑ Limited ❑ General ❑ Individual ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing: Signer's Name: ❑ Corporate Officer — Title(s): ❑ Partner — ❑ Limited ❑ General ❑ Individual ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing: ©2014 National Notary Association • www.Nationa[Notary.org • 1 -800 -US NOTARY (1-800-876-6827) Item #5907 STATE OF NORTH CAROLINA AFFIDAVIT COUNTY CIR MUNICIPALITY x»»»xxxxx»x»»»xxxxx»x»»»xx»»»x 1, rtS,?449 (-(the (the individual attesting below), being duly authorized by and on behalf of �- T�\J C (the entity bidding on project hereinafter "Employer") after first being duly sworn hereby swears or affirms as follows: 1. Employer understands that E-Verifv is the federal E -Verify program operated by the United States Department of Homeland Security and other federal agencies, or any successor or equivalent program used to verify the work authorization of newly hired employees pursuant to federal law in accordance with NCGS §64-25(5). 2. Employer understands that Employers Must Use E-Verifv. Each employer, after hiring an employee to work in the United States, shall verify the work authorization of the employee through E -Verify in accordance with NCGS§64-26(a). 3. Employer is a person, business entity, or other organization that transacts business in this State and that employs 25 or more employees in this State. (mark Yes or No) a. YES or b. NO 4. Employer's subcontractors comply with E -Verify, and if Employer is the winning bidder on this project Employer will ensure compliance with E -Verify by any subcontractors subsequently hired by Employer. Thiss Q f -day of 20 i L,� Signature of Affiant j Print or Type Name:�}�y� State of North Carolina County of .416 nm LA.. Signed and sworn to (or affirmed) before me, this the 10 day of Joy 2015 My Commission Expires: ftQb� Notary Public •.•P D. sc/y, ''•. �a• �GJ�. • '0 PUBLIC SECTION 00414 PROPOSED LIST OF SUBCONTRACTORS PART1 GENERAL 1.1 SCOPE A. The Contractor, shall attach the Proposed List of Subcontractors with the Bid Form to indicate the selected subcontractors for each subcontract greater than $10,000 in contract value. PART PRODUCTS not used PART 3 EXECUTION not used END OF SECTION 3097-F : 06/10/15 00414-1 Proposed List of Subcontractors Old Salisbury Road Sewer Davidson County, NC Proposed List of Subcontractors Name of Subcontractor Scope of Work 0 ru Resp tfully submi C itted: -r f (11 Uor Print (Signatu?) ,, 1 (Title) l� License Number: / 5) J Date: 6 -1 b `j S (SEAL - if bid is by a Corporation) 3097-F: 06/10/15 00414-2 Proposed List of Subcontractors OLD SALISBURY ROAD SEWER DAVIDSON COUNTY LEXINGTON, NORTH CAROLINA SUBJECT: ADDENDUM NO. 1 6/4/15 To the Plans and Specifications for: Old Salisbury Road Sewer Davidson County, N.C. To: PROSPECTIVE BIDDERS AND OTHER CONCERNED PARTIES This ADDENDUM forms a part of the Contract Documents and modifies the original Bidding Documents as noted below. Bidders shall acknowledge receipt of the ADDENDUM in the space provided on the Bid Form. Failure to do so may subject the Bidder to Disqualification. A. Contracting Requirements 1. Document 520, Agreement a. Article 4 – Contract Times, Paragraph 4.02.A. 1. Replace 60 days for final completion with 75 days. b. Add the following Paragraph Article 4 – Contract Times, Paragraph 4.02, add the following paragraph 4.02 B after 4.02.A. 1. Deflection Test for PVC pipe will not be required for substantial completion but will be required for final completion. Sewer line may be made active upon substantial completion. Bids will be received until 2:00 pm, Thursday June 11, 2015 FOR THE OWNER THE WOOTEN COMPANY BY Randy S. Freeman, P.E. Oq� END OF DOCUMENT p� °F� S% 0 jSE L -F- 4 4 3097-F: 06/04/15 00490-1 Addendum No. OLD SALISBURY ROAD SEWER DAVIDSON COUNTY LEXINGTON, NORTH CAROLINA SUBJECT: ADDENDUM NO. 2 6/10/15 To the Plans and Specifications for: Old Salisbury Road Sewer Davidson County, N.C. To: PROSPECTIVE BIDDERS AND OTHER CONCERNED PARTIES This ADDENDUM forms a part of the Contract Documents and modifies the original Bidding Documents as noted below. Bidders shall acknowledge receipt of the ADDENDUM in the space provided on the Bid Form. Failure to do so may subject the Bidder to Disqualification. A. Bidding Requirements 1. Document E -Verify Affidavit a. Submit the attached E -Verify Affidavit with your bid. 2. Document 00414 — Proposed List of Sub -contractors a. Submit the attached Sub -contractors List with your bid. Bids will be received until 2:00 pm, Thursday, June 11, 2015 FOR THE OWNER THE WOOTEN COMPANY BY Randy S. Freeman, P.E. END OF DOCUMENT�! �ARo O`�'FESS 0% e CL S. /l11110�� 6 io-/S 3097-F : 06/10/15 00490-2-1 Addendum No. 2 STATE OF NORTH CAROLINA AFFIDAVIT COUNTY OR MUNICIPALITY I. (the individual attesting below), being duly authorized by and on behalf of (the entity bidding on project hereinafter "Employer") after first being duly sworn hereby swears or affirms as follows: 1. Employer understands that E -Verify is the federal E -Verify program operated by the United States Department of Homeland Security and other federal agencies, or any successor or equivalent program used to verify the work authorization of newly hired employees pursuant to federal law in accordance with NCGS §64-25(5). 2. Employer understands that Employers Must Use E -Verify. Each employer, after hiring an employee to work in the United States, shall verify the work authorization of the employee through E -Verify in accordance with NCGS§64-26(a). 3. Employer is a person, business entity, or other organization that transacts business in this State and that employs 25 or more employees in this State. (mark Yes or No) a. YES or b. NO 4. Employer's subcontractors comply with E -Verify, and if Employer is the winning bidder on this project Employer will ensure compliance with E -Verify by any subcontractors subsequently hired by Employer. This day of 20 Signature of Affiant Print or Type Name: State of North Carolina County of Signed and sworn to (or affirmed) before me, this the day of 20_. My Commission Expires: Notary Public D X X� O 0 Z 0 v W CD m SECTION 00414 PROPOSED LIST OF SUBCONTRACTORS PART1 GENERAL 1.1 SCOPE A. The Contractor, shall attach the Proposed List of Subcontractors with the Bid Form to indicate the selected subcontractors for each subcontract greater than $10,000 in contract value. PART PRODUCTS not used PART 3 EXECUTION not used END OF SECTION 3097-F: 06/10/15 00414-1 Proposed List of Subcontractors Old Salisbury Road Sewer Davidson County, NC Proposed List of Subcontractors Name Respectfully submitted: (Type or Print Name) (Signature) (Title) License Number: Date: (SEAL - if bid is by a Corporation) 3097-F: 06/10/15 00414-2 Proposed List of Subcontractors Notice of Award 1-1 Bidder. Biddees Address: (seM Gentled Mail, Retum Receipt Requested) Durham, NC 27707 You are notified that your Bid dated June 11, 2015 for the above Contract has been considered. You are the Successful Bidder and are awarded a Contract for the following: Approximately 3,100 feet of 8 -inch gravity sewer and associated appurtenances. The Contract Price of your Contract is Two Hundred Twenty Five Thousand Nine Hundred Twenty Nine and 50/100's Dollars ($225.929.50). 3 copies of the proposed Contract Documents (except Drawings) accompany this Notice of Award. 5 sets of the Drawings will be delivered separately or otherwise made available to you immediately. You must comply with the following conditions precedent within 10 days of the date you receive this Notice of Award. 1. Deliver to the Engineer 3 fully executed counterparts of the Contract Documents. 2. Deliver with the executed Contract Documents the Contract Bonds as specified in the Instructions to Bidders, General Conditions Paragraph 5.01, and Supplementary Conditions Paragraph SC -5.01. Failure to comply with these conditions within the time specified will entitle Owner to consider you in default, annul this Notice of Award and declare your Bid security forfeited. Within 10 days after you comply with the above conditions, Owner will return to you one fully executed counterpart of the Contract Documents. Acceptance of Notice Receipt of the above Notice of Award is hereby acknowledged by BBUDC. Inc. this t day of 2015. By:_ Print Name: fi Lzd tri e 3"/ r TITIP' 3097-F : 06/23/15 00510-1 Notice of Award EJCDC No. C-510 (2007 Edition) Prepared by the Engineers' Joint Contract Documents Committee and endorsed by the Associated General Contractors of America and the Construction Specifications Institute. AGREEMENT THIS AGREEMENT is by and between Davidson County (Owner) and BBUDC, Inc. (Contractor). Owner and Contractor hereby agree as follows: ARTICLE 1 - WORK Contractor shall complete all Work as specified or indicated in the Contract Documents. The Work is generally described as follows: Old Salisbury Road Sewer ARTICLE 2 - PROJECT The Project for which the Work under the Contract Documents may be the whole or only a part is generally described as follows: Installation of approximately 3,100 linear feet of 8 -inch sanitary sewer and associated appurtenances. ARTICLE 3- ENGINEER The Project has been designed by The Wooten Company, 350 North Cox Street Suite 26, Asheboro, North Carolina 27203, (Engineer) which is to act as Owner's representative, assume all duties and responsibilities and have the rights and authority assigned to Engineer in the Contract Documents in connection with completion of the Work in accordance with the Contract Documents. ARTICLE 4 - CONTRACT TIMES 4.01 Time of the Essence A. All time limits for Milestones, if any, Substantial Completion, and completion and readiness for final payment as stated in the Contract Documents are of the essence of the Contract. 4.02 Days to Achieve Completion and Final Payment A. The Work will be substantially completed within 45 days after the date when the Contract Times commence to run as provided in Paragraph 2.03 of the General Conditions, and completed and ready for final payment in accordance with Paragraph 14.07 of the General Conditions within 75 days after the date when the Contract Times commence to run. 4.03 Liquidated Damages A. Contractor and Owner recognize that time is of the essence as stated in this Agreement and that Owner will suffer financial loss if the Work is not completed within the times specified in paragraph 4.02 above, plus any extensions thereof allowed in accordance with Article 12 of the General Conditions. The parties also recognize the delays, expense, and difficulties involved in proving in a legal or arbitration proceeding the actual loss suffered by Owner if the Work is not completed on time. Accordingly, instead of requiring any such proof, Owner and 3097-F: 06/23/15 00520-1 Agreement Document in accordance with EJCDC No. C-520 (2007) Contractor agree that as liquidated damages for delay (but not as a penalty), Contractor shall pay Owner 750 for each day that expires after the time specified in paragraph 4.02 for Substantial Completion until the Work is substantially complete. After Substantial Completion, if Contractor shall neglect, refuse, or fail to complete the remaining Work within the Contract Time or any proper extension thereof granted by Owner, Contractor shall pay Owner $750 for each day that expires after the time specified in Paragraph 4.02 above for completion and readiness for final payment until the Work is completed and ready for final payment. ARTICLE 5 - CONTRACT PRICE Owner shall pay Contractor for completion of the Work in accordance with the Contract Documents an amount in current funds equal to the sum of the amounts determined pursuant to the following paragraphs: A. For all Unit Price Work, an amount equal to the sum of the established unit price for each separately identified item of Unit Price Work times the estimated quantity of that item as indicated in the Bid Form. Total of all Unit Prices: Two Hundred Twenty Five Thousand Nine Hundred Twenty Nine and 50/100's Dollars ($225.929.50) As provided in paragraph 11.03 of the General Conditions, estimated quantities are not guaranteed, and determinations of actual quantities and classification are to be made by Engineer as provided in paragraph 9.07 of the General Conditions. Unit prices have been computed as provided in paragraph 11.03 of the General Conditions. ARTICLE 6 - PAYMENT PROCEDURES 6.01 Submittal and Processing of Payments A. Contractor shall submit Applications for Payment in accordance with Article 14 of the General Conditions. Engineer will process Applications for Payment as provided in the General Conditions. 6.02 Progress Payments; Retainage A. Owner shall make progress payments on account of the Contract Price on the basis of Contractor's Applications for Payment as recommended by Engineer, on or about the 25th day of each month during performance of the Work as provided in paragraphs 6.02.A.1 below. All such payments will be measured by the schedule of values established in paragraph 2.07.A of the General Conditions (and in the case of Unit Price Work based on the number of units completed) or, in the event there is no schedule of values, as provided in the General Requirements: 1. Prior to Substantial Completion, progress payments will be made in an amount equal to the percentage as indicated below but, in each case, less the aggregate of payments previously made and less such amounts as Engineer may determine, or Owner may withhold, in accordance with paragraph 14.02 of the General Conditions. 3097-F : 06/23/15 00520-2 Agreement Document in accordance with EJCDC No. C-520 (2007) a. 95 % of Work completed (with the balance being retainage). If Work has been 50% completed as determined by Engineer, if the Contractor has provided a written request to reduce the retainage along with a consent of its surety to the Engineer, and if the character and progress of the Work have been satisfactory to Owner and Engineer, Owner, on recommendation of Engineer, may determine that as long as the character and progress of the Work remain satisfactory to them, there will be no additional retainage on account of Work subsequently completed so that the retainage at the end of the project will be equal to 2.5%; and a. 95 % of Work completed (with the balance being retainage); and b. 95 % of cost of materials and equipment not incorporated in the Work (with the balance being retainage). Upon Substantial Completion, Owner shall pay an amount sufficient to increase total payments to the Contractor to 100 percent of the Work completed, less such amounts as Engineer shall determine in accordance with Paragraph 14.02.6.5 of the General Conditions and less 200 percent of Engineer's estimate of the value of Work to be completed or corrected as shown on the tentative list of items to be completed or corrected attached to the certificate of Substantial Completion. 6.03 Final Payment A. Upon final completion and acceptance of the Work in accordance with paragraph 14.07 of the General Conditions, Owner shall pay the remainder of the Contract Price as recommended by Engineer as provided in said DaraaraDh 14.07. ARTICLE 7 - INTEREST All moneys not paid when due as provided in Article 14 of the General Conditions shall bear interest at the maximum rate 8 percent per annum in accordance with North Carolina General Statute 24-1. ARTICLE 8 - CONTRACTOR'S REPRESENTATIONS 8.01 In order to induce Owner to enter into Agreement, Contractor makes the following representations: A. Contractor has examined and carefully studied the Contract Documents and other related data identified in the Bidding Documents. B. Contractor has visited the Site and become familiar with and is satisfied as to the general, local and Site conditions that may affect cost, progress, and performance of the Work. C. Contractor is familiar with and is satisfied as to all federal, state and local Laws and Regulations that may affect cost, progress, and performance of the Work. D. Contractor has carefully studied all: (1) reports of explorations and tests of subsurface conditions at or contiguous to the Site and all drawings of physical conditions relating to existing surface or subsurface structures at the Site (except Underground Facilities), if any, that have been identified in Paragraph SC -4.02 of the Supplementary Conditions as containing reliable "technical data," and (2) 3097-F : 06/23/15 00520-3 Agreement Document in accordance with EJCDC No. C-520 (2007) reports and drawings of Hazardous Environmental Conditions, if any, at the Site that have been identified in Paragraph SC -4.06 of the Supplementary Conditions as containing reliable "technical data." E. Contractor has considered the information known to Contractor; information commonly known to contractors doing business in the locality of the Site; information and observations obtained from visits to the Site; the Contract Documents; and the Site -related reports and drawings identified in the Contract Documents, with respect to the effect of such information, observations, and documents on (1) the cost, progress, and performance of the Work; (2)the means, methods, techniques, sequences, and procedures of construction to be employed by Contractor, including any specific means, methods, techniques, sequences, and procedures of construction expressly required by the Contract Documents; and (3) Contractor's safety precautions and programs. F. Based on the information and observations referred to in Paragraph 8.01.E above, Contractor does not consider that further examinations, investigations, explorations, tests, studies, or data are necessary for the performance of the Work at the Contract Price, within the Contract Times, and in accordance with the other terms and conditions of the Contract Documents. G. Contractor is aware of the general nature of work to be performed by Owner and others at the site that relates to the Work as indicated in the Contract Documents. H. Contractor has given Engineer written notice of all conflicts, errors, ambiguities or discrepancies that Contractor has discovered in the Contract Documents and the written resolution thereof by Engineer is acceptable to Contractor. I. The Contract Documents are generally sufficient to indicate and convey understanding of all terms and conditions for performance and furnishing of the Work. ARTICLE 9 - CONTRACT DOCUMENTS 9.01 Contents A. The Contract Documents consist of the following: Addenda 00490 as follows. a. Addendum No. 1, dated 6/4/15, (page 00490- -1) b. Addendum No. 2, dated 6/15/15, (page 00490-2-1 with attachments) 2. This Agreement (pages 00520-1 to 00520-7) 3. Performance Bond (pages 00610-1 to 00610-2) 4. Payment Bond (pages 00615-1 to 00615-2) 5. Certificate of Insurance (page 00620-1) 6. General Conditions (pages 00700-1 to 00700-62) Supplementary Conditions (pages 00800-1 to 00800-10) 8. Specifications as listed in the table of contents (pages 00010-1 to 00010-2) of the Project Manual. 3097-F: 06/23/15 00520-4 Agreement Document in accordance with EJCDC No. C-520 (2007) 9. Drawings consisting of sheets numbered 1 through 7 and are not attached to this Agreement, with each sheet bearing the following general title: Old Salisbury Road Sewer. 10. Exhibits to this Agreement as follows: a. Contractor's Bid (pages 00410-1 to 00410-7, inclusive); b. Notice of Award (pages 00510-1) c. Documentation submitted by Contractor prior to Notice of Award. 11. The following that may be delivered or issued on or after the Effective Date of the Agreement and are not attached hereto: a. Notice to Proceed (pages 00550-1) b. Work Change Directives; c. Change Order; B. The documents listed in paragraph 9.01.A are attached to this Agreement (except as expressly noted otherwise above). C. There are no Contract Documents other than those listed above in this Article 9. D. The Contract Documents may only be amended, modified or supplemented as provided in paragraphs 3.04 of the General Conditions. ARTICLE 10 - MISCELLANEOUS 10.01 Terms A. Terms used in this Agreement will have the meanings indicated in the General Conditions. 10.02 Assignment of Contract A. No assignment by a party hereto of any rights under or interests in the Contract will be binding on another party hereto without the written consent of the party sought to be bound; and, specifically but without limitation, moneys that may become due and moneys that are due may not be assigned without such consent (except to the extent that the effect of this restriction may be limited by law), and unless specifically stated to the contrary in any written consent to an assignment, no assignment will release or discharge the assignor from any duty or responsibility under the Contract Documents. 10.03 Successors and Assigns A. Owner and Contractor each binds itself, its partners, successors, assigns, and legal representatives to the other party hereto, its partners, successors, assigns, and legal representatives in respect to all covenants, agreements, and obligations contained in the Contract Documents. 10.04 Severability A. Any provision or part of the Contract Documents held to be void or unenforceable under any Law or Regulation shall be deemed stricken, and all remaining provisions shall continue to be valid and binding upon Owner and Contractor, who 3097-F: 06/23/15 00520-5 Agreement Document in accordance with EJCDC No. C-520 (2007) agree that the Contract Documents shall be reformed to replace such stricken provision or part thereof with a valid and enforceable provision that comes as close as possible to expressing the intention of the stricken provision. 10.05 Contractor Certifications A. Contractor certifies that it has not engaged in corrupt, fraudulent, collusive, or coercive practices in competing for or in executing the Contract. For the purposes of this Paragraph 10.05: a. "corrupt practice" means the offering, giving, receiving, or soliciting of any thing of value likely to influence the action of a public official in the bidding process or in the Contract execution; b. "fraudulent practice" means an intentional misrepresentation of facts made (a) to influence the bidding process or the execution of the Contract to the detriment of Owner, (b) to establish Bid or Contract prices at artificial non-competitive levels, or (c) to deprive Owner of the benefits of free and open competition; C. "collusive practice" means a scheme or arrangement between two or more Bidders, with or without the knowledge of Owner, a purpose of which is to establish Bid prices at artificial, non-competitive levels; and d. "coercive practice' means harming or threatening to harm, directly or indirectly, persons or their property to influence their participation in the bidding process or affect the execution of the Contract. THIS AREA LEFT BLANK INTENTIONALLY 3097-F: 06/23/15 00520-6 Agreement Document in accordance with EJCDC No. C-520 (2007) IN WITNESS WHEREOF, Owner and Contractor have signed this Agreement in triplicate. One counterpart each has been delivered to Owner, Contractor, and Engineer. All portions of the Contract Documents have been signed or have been identified by Owner and Contractor or identified by Engineer on their behalf. This Agreement will be effective on July 17, 2015 (which is the Effective Date of the Agreement). OWNER: DAVIDSON COUNTY Todd Yates Name Chairman Signature (SEAL) ATTEST: Deborah J. _..._ Name Title p Signature Address for giving notices Davidson County PO Box 1067 Lexington NC 27292-1067 CONTRACTOR: BBUDC, INC. Isaac Woods Name CEO Ttle Signature (SEAL) Print Name Jitle / Signature v BBUDC. Inc. PO Box 52522 Durham NC 27717-2552 License No. 75152 If Owner is a public body, attach evidence of authority to sign and resolution or other documents authorizing execution of Agreement. If Contractor is a corporation, partnership, or joint venture, attach evidence of authority to sign. END OF DOCUMENT 3097-F : 06/23/15 00520-7 Agreement Document in accordance with EJCDC No. C-520 (2007) Notice to Proceed Rl Project:: Old Salisbury Road Sewer Date: owner: owners Contract No.: Contract: Engineers Project No.: 3097-F Contractor: Contractors Address: (send Certified Mail, Return Receipt Requested) NC You are notified that the Contract Times under the above contract will commence to run on . On or before that date, you are to start performing your obligations under the Contract Documents. In accordance with Article 4 of the Agreement, the number of days to achieve Substantial Completion is _, and the number of days to achieve readiness for final payment — The date of completion of all work is therefore Before you may start any Work at the Site, Paragraph 2.01.6 of the General Conditions provides that you must deliver to the Owner (with copies to Engineer and other identified additional insureds) certificates of insurance which you are required to purchase and maintain in accordance with the Contract Documents. Also, before you may start any Work at the Site, you must: Given by: Authorized Signature Date Copy to Engineer Acceptance of Notice Receipt of the Notice of Proceed is hereby acknowledged by this the By:_ day of 20_ 3097-F : 04/20/15 00550-1 Notice to Proceed EJCDC No. C-510 (2007 Edition) Prepared by the Engineers' Joint Contract Documents Committee and endorsed by the Associated General Contractors of America and the Construction Specifications Institute. EJCDC ENGINEERS JOINT CONTRACT DOCUMENTS COMMITTEE CONTRACTOR (name and address): BBUDC, Inc. PO Box 52552 Durham NC 27717 OWNER (name and address): Davidson County P.O. Box 1067 913 Greensboro Street Lexington, N.C. 27293 CONSTRUCTION CONTRACT I Q 04 63 211 i SURETY (name and address ofprincipal place of business): The Ohio Casualty Insurance Company 62 Maple Avenue Keene, NH 03431 Effective Date of the Agreement: July 17, 2015 Amount: $225,929.50 Two Hundred Twenty Five Nine Hundred Twenty Nine and 50/100's dollars Description (name and location): Old Salisbury Road Sewer, Lexington NC BOND Bond Number: 070002958 Premium $6,778.00 Date (not earlier than the Effective Date of the Agreement of the Construction Contract): July 17, 2015 Amount: $225,929.50 Two Hundred Twenty Five Nine Hundred Twenty Nine and 50/100's dollars Modifications to this Bond Form: ❑x None ❑ See Paragraph 16 Surety and Contractor, intending to be legally bound hereby, subject to the terms set forth below, do each cause.: this Performance Bond to be duly executed by an authorized officer, agent, or representative.t' CONTRACTOR AS PRINCIPAL SURETY BBUDC, Inc. (seal) Contractor's, Name and Corporate Seal Sig�araie=-� __ Print Name - Title �2x & Signature U Title The Ohio Casualty Insurance Company (seal) Surety's Name andel Corporate Seal Signature (attach power ofatiorney) David K. Mahler Print Name Attorn -i -Fact Title Attest: L4&4�k� Signature Anita McKague Attestee Title Notes. (1) Aovide supplemental execution by any additional patties, such as joint venturers. (2) Any singular reference to Contractor, Surety, Owner, or other party shall be considered plural where applicable. 3097-F: 04/20/15 00610-1 Performance Bond EJCDC No. C-610 (2010 Edition) 1. The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors, and assigns to the Owner for the performance of the Construction Contract, wbich is incorporated herein by reference. 2. If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except when applicable to participate in a conference as provided in Paragraph 3. 3. If there is no Owner Default under the Construction Contract, the Surety's obligation under this Bond shall arise after: 3.1 The Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default. Such notice shall indicate whether the Owner is requesting a conference among the Owner, Contractor, and Surety to discuss the Contractor's performance. If the Owner does not request a conference, the Surety may, within five (5) business days after receipt of the Owner's notice, request such a conference. If the Surety timely requests a conference, the Owner shall attend. Unless the Owner agrees otherwise, any conference requested under this Paragraph 3.1 shall be held within ten (10) business days of the Surety's receipt of the Owner's notice. If the Owner, the Contractor, and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default; 3.2 The Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety; and 3.3 The Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. 4. Failure on the part of the Owner to comply with the notice requirement in Paragraph 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. 5. When the Owner has satisfied the conditions of Paragraph 3, the Surety shall promptly and at the Surety's expense take one of the following actions: 5.1 Arrange for the Contractor, with the consent of the Owner, to perform and complete the Construction Contract; 5.2 Undertake to perform and complete the Construction Contract itself, through its agents or independent contractors; 5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owners concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Paragraph 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default; or 5.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor, and with reasonable promptness under the circumstances: 5.4.1 After investigation, determine the amount for which it may be liable to the Owner and, as soon as practicable after the amount is determined, make payment to the Owner, or 5.4.2 Deny liability in whole or in part and notify the Owner, citing the reasons for denial. 6. If the Surety does not proceed as provided in Paragraph 5 with reasonable promptness, the Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Paragraph 5.4, and the Owner refuses the payment or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. 7. If the Surety elects to act under Paragraph 5.1, 5.2, or 5.3, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Connect. Subject to the commitment by the Owner to pay the Balance of the Contract Price, the Surety is obligated, without duplication for: 7.1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; 7.2 additional legal, design professional, and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Paragraph 5; and 7.3 liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non-performance of the Contractor. 8. If the Surety elects to act under Paragraph 5.1, 5.3, or 5.4, the Surety's liability is limited to the amount of this Bond. 9. The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, successors, and assigns. 10. The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders, and other obligations. 11. Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years 3097-F: 04/20/15 00610-2 Performance Bond EJCDC No. C-610 (2010 Edition) after the Surety refuses or fails to perform its obligations under this Bond, whichever occur: first. If the provisions of this paragraph are void or prohibited by law, the minimum periods of limitations available to sureties as a defense in the jurisdiction of the suit shall be applicable. 12. Notice to the Surety, the Owner, or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. 13. When this Bond has been famished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. 14. Definitions 14.1 Balance of the Contract Price: The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made including allowance for the Contractor for any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract 3097-F: 04/20/15 00610-3 EJCDC No. C-610 (2010 Edition) 14.2 Construction Contract The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents, 14.3 Contractor Default: Failure of the Contractor, which has not been remedied or waived, to perform or otherwise to comply with a material term of the Construction Contract, 14.4 Owner Default: Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. 14.5 Contract Documents: All the documents that comprise the agreement between the Owner and Contractor. 15. If this Bond is issued for an agreement between a contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. 16. Modifications to this Bond are as follows: Performance Bond EJCDC ENGINEER$ JOINT CONTRACT DOCUMEA=S COMMITTEE CONTRACTOR (name and address): BBUDC, Inc. PO Box 52552 Durham NC 27717 OWNER (name and address): Davidson County P.O. Box 1067 913 Greensboro Street Lexington, N.C. 27293 CONSTRUCTION CONTRACT PAYMENT BOND SURETY (name and address of principal place ofbusiness): The Ohio Casualty Insurance Company 62 Maple Avenue Keene, NH 03431 Effective Date of the Agreement: July 17, 2015 Amount: $225,929.50 Two Hundred Twenty Five Nine Hundred Twenty Nine and 50/100's dollars Description (name and location): Old Salisbury Road Sewer, Lexington NC BOND Bond Number: 070002958 Premium: Included Date (not earlier than the Effective Date of the Agreement of the Construction Contract): July 17, 2015 Amount: $225,929.50 Two Hundred Twenty Five Nine Hundred Twenty Nine and 50/100's dollars Modifications to this Bond Form: © None ❑ See Paragraph 18 Surety and Contractor, intending to be legally bound hereby, subject to the terms set forth below, do each cause this Payment Bond to be duly executed by an authorized officer, agent, or representative. CONTRACTOR AS PRINCIPAL BBUDC Inev (seal) ContniFwes Name and Corporate Seal w+ Signature Print Name ED Title Attest: 0 Signature Title SURETY The Ohio Casualty Insurance Company ' (seal) Surety's Name and Corporate Seal BY: Signature (attach power ofattorney) David K Mahler Print Name IM Attest: i[ f LL Signature Anita McKague Attestee Title Notes. (1) Provide supplemental execution by any additional parties, such as joint venturers. (2) Any singular reference to Contractor, Surety, Owner, or other parry shall be considered plural where applicable. 3097-F: 05/18/15 00615-1 Payment Bond EJCDC No. C-615 (2010 Edition) I . The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors, and assigns to the Owner to pay for labor, '—' materials, and equipment furnished for use in the performance of the Construction Contract, which is incorporated herein by reference, subject to the following terms. 2. If the Contractor promptly makes payment of all sums due to Claimants, and defends, indemnifies, and holds harmless the Owner from claims, demands, liens, or suits by any person or entity seeking payment for labor, materials,or equipment furnished for use in the performance of the Construction Contract, then the Surety and the Contractor shall have no obligation under this Bond. 3. If there is no Owner Default under the Construction Contract, the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety (at the address described in Paragraph 13) of claims, demands, liens, or suits against the Owner or the Owner's property by any person or entity seeking payment for labor, materials, or equipment furnished for use in the performance of the Construction Contract, and tendered defense of such claims, demands, liens, or suits to the Contractor and the Surety. 4. When the Owner has satisfied the conditions in Paragraph 3, the Surety shall promptly and at the Surety's expense defend, indemnify, and hold harmless the Owner against a duly tendered claim, demand, lien, or suit. 5. The Surety's obligations to a Claimant under this Bond shall arise after the following: 5.1 Claimants who do not have a direct contract with the Contractor, 5.1.1 have furnished a written notice of non- payment to the Contractor, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were, or equipment was, furnished or supplied or for whom the labor was done or performed, within ninety (90) days after having last performed labor or last famished materials or equipment included in the Claim; and 5.1.2 have sent a Claim to the Surety (at the address described in Paragraph 13). 5.2 Claimants who are employed by or have a direct contract with the Contractor have sent a Claim to the Surety (at the address described in Paragraph 13). 7. When a Claimant has satisfied the conditions of Paragraph 5.1 or 5.2, whichever is applicable, the Surety shall promptly and at the Surety's expense take the following actions: 7.1 Send an answer to the Claimant, with a copy to the Owner, within sixty (60) days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed; and 7.2 Pay or arrange for payment of any undisputed amounts. 7.3 The Surety's failure to discharge its obligations under Paragraph 7.1 or 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed amounts for which the Surety and Claimant have reached agreement. If, however, the Surety fails to discharge its obligations under Paragraph 7.1 or 7.2, the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant. 8. The Surety's total obligation shall not exceed the amount of this Bond, plus the amount of reasonable attorney's fees provided under Paragraph 7.3, and the amount of this Bond shall be credited for any payments made in good faith by the Surety. 9. Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any, under any construction performance bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond, subject to the Owner's priority to use the funds for the completion of the work. 10. The Surety shall not be liable to the Owner, Claimants, or others for obligations of the Contractor that are unrelated to the Construction Contract. The Owner shall not he liable for the payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligation to make payments to or give notice on behalf of Claimants, or otherwise have any obligations to Claimants under this Bond. 11. The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders, and other obligations. 12. No suit or action shall be commenced by a Claimant under 6. If a notice of non-payment required by Paragraph 5.1.1 is this Bond other than in a court of competent jurisdiction in given by the Owner to the Contractor, that is sufficient to the state in which the project that is the subject of the satisfy a Claimant's obligation to furnish a written notice of Construction Contract is located or after the expiration of non-payment under Paragraph 5.1.1, one year from the date (1) on which the Claimant sent a Claim to the Surety pursuant to Paragraph 5.1.2 or 5.2, or 3097-F: 05/18/15 00615-2 Payment Bond EJCDC No. C-615 (2010 Edition) (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, wbichever of (1) or (2) first occurs. If the provisions of this paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. 13. Notice and Claims to the Surety, the Owner, or the Contractor shall he mailed or delivered to the address shown on the page on which their signature appears. Actual receipt of notice or Claims, however accomplished, shall be sufficient compliance as of the date received. 14. When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. 15. Upon requests by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor and Owner shall promptly fumish a copy of this Bond or shall permit a copy to be made. 16. Definitions 16.1 Claim: A written statement by the Claimant including at a minimum: '�--- 1. The name of the Claimant, 2. The name of the person for whom the labor was done, or materials or equipment furnished; 3. A copy of the agreement or purchase order pursuant to which labor, materials, or equipment was furnished for use in the performance of the Construction Contract; 4. A brief description of the labor, materials, or equipment famished; 5. The dam on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; 6. The total amount earned by the Claimant for labor, materials, or equipment furnished as of the dam of the Claim; 7. The total amount of previous payments received by the Claimant; and 8. The total amount due and unpaid to the Claimant for labor, materials, or equipment furnished as of the date of the Claim 16.2 Claimant: An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor, materials, or equipment for use in the performance of the Construction Contract. The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located. The intent of this Bond shall be to include without limitation in the terms of "labor, materials, or equipment" that part of the water, gas, power, light, heat,oil, gasoline, telephone service, or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other items for which a mechanic's lien may be asserted in, the jurisdiction where the labor, materials, or equipment were furnished. 16.3 Construction Contract: The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents. 16.4 Owner Default: Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. 16.5 Contract Documents: All the documents that comprise the agreement between the Owner and Contractor. 17. If this Bond is issued for an agreement between a contractor and subcontractor, the term Contractor in this Bond shall be deemed to he Subcontractor and the term Owner shall be deemed to be Contractor. 18. Modifications to this Bond are as follows: 3097-F : 05/18/15 00615-3 Payment Bond EJCDC No. C-615 (2010 Edition) THIS POWER OF ATTORNEY IS NOT VALID UNLESS IT IS PRINTED ON RED BACKGROUND. This Power of Attorney limits the acts of those named herein, and they have no authority to bind the Company except in the manner and to the extent herein stated. Certificate No. 7010509 American Fire and Casually Company Liberty Mutual Insurance Company The Ohio Casualty Insurance Company West American Insurance Company POWER OF ATTORNEY KNOWN ALL PERSONS BY THESE PRESENTS: ThatAmerican Fire8 Casually Company and The Ohio Casualty Insurance Company are corporations duty organized under the laws of the State of New Hampshire, that liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts, and WestAmerican Insurance Company is a corporation duty organized under the laws of the State of Indiana (herein collectively called the "Companies'), pursuant to and by authority herein set forth, does hereby name, constitute and appoint, David F. Druml; David K. Mahler all of the city of Foster City , stale of CA each individually if there be more than one named, its true and lawful atomey-in-fact to make, execute, seal, acknowledge and deliver, for and on is behalf as surety and as its ad and deed, any and all undertakings, bonds, mcognizances and other surety obligations, in pursuance of these presents and shall be as binding upon the Corrpranies as if they have been duly signed by the president and attested by the secretary of the Companies in their own proper persons. IN WITNESS WHEREOF, this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 9th day of June 2015 American Fire and Casualty Company The Ohio Casualty Insurance Company Liberty Mutual Insurance Company WiestAmerican Insurance Company0(300 By: 4Z, STATE OF PENNSYLVANIA as David M. Cee , Assistant Secretary COUNTY OF MONTGOMERY On this 91h day of dune a 2015 before me personally appeared David M. Carey, who acknowledged himself to be the Assistant Secretary of American Fire and Casualty Company, Liberty Mutual Insurance Company, The Ohio Casualty Insurance Company, and West American Insurance Colrgtany, and that he, as such, being authorized so to do, execute the foregoing instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer. IN WITNESS WHEREOF, I have hereunto subscribed my name and affixed my notarial seal at Plymouth Meeting, Pennsylvania, on the day and year first -above ®written. 8P PAa7. COMMONWEALTH OF PENNSYLVANIA �Q��aoaw�tF!! Novaial3eai Teresa Pastelle, Nmery Pu61ie By; Or Pymoulh Twp., Montgomery County Teresa Pastella, Notary Public s My Commission Expires March 28, 2017 S W " Me ,, Penmyf a wAveatlmlon of Notaries nY This Power ofAttomey is made and executed pursuant to an by authority of the following By-laws and Authorizations ofArredicat Fire and CasuatyCompany, The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company which resolutions are now in full face and of act reading as follows: ARTICLE IV -OFFICERS - Section 12. Power of Attorney. Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President, and subject to such Imitation as the Chairman or the President may prescribe, shall appoint such atomeys-imiact, as may be necessary to act in behalf of the Corporation to make, execute, seal, acknowledge and deliver as surety any and all undertakings,bonds, recegnizances and other surety obligations. Such attomeys-in-fact, subject to the limitations set forth in their respective pourers of attorney, shalt have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation. When so executed, such instmments shall be as binding as if signed by the President and attested to by the Secretary Any power or authority granted to any representative or atomey4ri-fact under the provisions of this article may be revoked at any time by the Board, the Chairman, the President or by the officer or officers granting such power or authority. ARTICLE XIII - Execution of Contracts - SECTION 5. Surety Bonds and Undertakings. Any officer of the Company authorized for that purpose in writing by the chairman or the president, and subject to such limitations as the chairman or the president may prescribe, shall appoint such attomeys-in-fact, as may be necessary to act in behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizanoes and other surety obligations. Such attomeys-in-fact subject to the limitations set forth in their respective powers of attorney, shall have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company. When so executed such instruments shall be as binding as if signed by the president and attested by the secretary. Certificate of Designation - The President of the Company, acting pursuant to the Bylaws of the Company, authorizes David M. Caney, Assistant Secretary to appoint such attorneys -mi - fact as may be necessary to act on behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Authorization - By unanimous current of the Corpanys Board of Directors, the Company consents that facsimile or mechanically reproduced signature of any assistant secretary of the Company, wherever appearing upon a codified copy of any power of attorney issued by the Company in connection with surety bonds, shall be valid and binding upon the Company with the same force and effect as though manually affixed. I, Gregory W Davenport, the undersigned, Assistant Secretary, of American Fire and Casualty Company, The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company do hereby certify that the original power of attorney of which the foregoing is a full, true and correct copy of the Power of Attorney executed by said Companies, is in full force and effect and has not been revoked. IN TESTIMONY WHEREOF, I have hereunto set my hand PND Cg5U9C T 1729 Z LMS_12873_122013 SN Ind"Wc' a . 1"" Companies this _, day of , 20I„'j_, � . v►ti 7991 3 BY: W agPa Gregory W. Davenport, Assistant Secretary 9 of 100 c£ O CL Q M O� 10 W L to N W O ER V M 0 = �O mil ~� N = M `cop OC) I HO� CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of San Mateo On July 1, 2015 before me, Soy Wong, Notary Public Date Here Insert Name and Title of the Officer personally appeared David K. Mahler Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/herAheir authorized capacity(ies), and that by his/herAheir signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. SOY WONG Commission N 2051554 a X Notary Public - California z ` San Mateo county a M .comm. Ez fires Dec 12, 2017' Place Notary Seal Above I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature Signature Notary Public OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Number of Pages: Document Date: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: ❑ Corporate Officer — Title(s): ❑ Partner — ❑ Limited ❑ General ❑ Individual ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator rl Other: Signer Is Representing: Signer's Name: ❑ Corporate Officer — Title(s): ❑ Partner — ❑ Limited ❑ General ❑ Individual ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing: - '✓G'.v 'a 'ti4'�G'ei 'd_ _ -dG'y 'v 'a'1/.v✓'"%•.✓G'✓G'✓G\✓ -n�h :G\UG'v 'v 'v6'uN 6h !1 Erie CERTIFICATE OF INSURANCE0114, DATE ISSUED IMMIDD/YY) I nsurancee — THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY — 722/15 Home Office • 100 Erie Insurance Place • Erie, Pennsylvania 16530 • 814.870.2000 Toll free 1.600.458.0811 • Fax 814.870.3126 • w,ww,erieinsurance.com NAME AND ADDRESS OFAGENCY MARCUS L DAVIS AGENCY AGENT'S NO. 3901 BARRETT DR STE 312 JJl520 D PR RALEIGH, NC 27609-6611 Co.: E BE1r %RANO oE>�C iA14GE of p Ica e orne -In-Fact Y _GG.:�LAUSHIP CITY INSURANCE COMPANY This certificate is issued for information purposes only and confers no rights on the certificate holder, It does not affirmatively or negatively emend, extend, or otherwise atter the terms, exclusions and conditions of Insurance coverage contained In the policy(les) indicated below. The terms and conditions of the policypes) govern the insurance coverage as applied to any given situation. Limits shown may have been reduced by claims paid. This certificate of insurance does not constitute a contract between the Issuing insurers), authorized representative or producer and the certificate holder. (919)772-7698 NAME AND ADDRESS OF NAMED INSURED BBUDC INC PO BOX 52552 5223 EPHESUS CHURCH ROAD DURHAM, NC 27717 This is to certify that Collcles, as Indicated tY the Policy Number below are In force for the Named Insured at the time that the Certificate Is Doing issued. L n TYPE OF INSURANCE ' POLICY NUMBER " 7/22/15 LIMITS E X GENERAL LIABILITY ® COMMERCIAL GENERAL LIABILITY ❑ CLAIMS MADE X OCCUF ❑ Q312221259 7/22/16 EACH OCCURRENCE. 1000000 . ` FIRE DAMAGE Play One Fie MED EXP Om Prion 5,000 PERSONAL&ADV. INJURY 1,000,000 ❑ GENS14LAGGREGATE 2,000,000 GENTAGGREGATE UMITAPPUES PER: X POLICY ❑ FROM ❑ LOC PRODUCTS-COMP/OPAGG 2,000,000 E ® AUTOMOBILE LIABILITY ❑ "ANYAUT ' %1NED HIBEID, u FA Q07 2230797 7/22/15 7/22/16 '. BOBILYmJURY ODAYINAIRMR PERSON $ ® OWNED ED HIRED ® NON -OWNED ❑ GARAGE BODILY IRY $ (EMAOCIDEPROPERTYOAMAGE BODILYINJURYANO '. PROPERTYDAMAGE $ 1,000,000 COMBINED' E ❑ EXCESS LIABILITY ® OCWRHENCE Q31 2270228 7/22/15 7/22/16 FACHOOCORRBICE 5,000,000 AGGREGATE 5,000,000 ❑ RETENTION $ 0 -.. E WORKERS COMPENSATION & EMPLOYERS LIABILITY Q 91 2200656 7/22/1$ 7122116 BODILY "B. ACCIDENT $ 500,000 EACH ACCIDENT DISEASE $ 500,000 POLICY LIMIT DISEASE $ 500,000 EACH EMPLOYEE OTHER DESCRIPTION OF OPERATIONS/LOCATIONSNENICLFS/EXCIUSIONS ADDED BY ENDORSEMENT/SPECIAL PROVISIONS Davidson County is to be listed as an additional insured on the General Liability and Commercial Automobile Liability insurance policies. CANCELLATION: SHOULD ANY Or THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIV- ERED IN ACCORDANCE WITH THE POLICY PROVISIONS. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). NAME AND ADDRESS OF CERTIFICATE HOLDER DAVIDSON COUNTY AUTHORIZED REPRESENTATIVE PO BOX 1067 LEXINGTON, NC 27293 EIG6230 8/11 Page 1 of 1 Erie CERTIFICATE OF INSURANCE 0 1 nsuranc( — THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY — Home Office • 100 Erie Insurance Place - Erie, Pennsylvania 16530 • 814.870.2000 Toll free 1.800.458.0811 • Fax 814.870.3126 • wfiw.erieinsurance.00m DATE ISSUED (MM/DD/YY 7/22/15 NAME AND ADDRESS OF AGENCY MARCUS L DAVIS AGENCY AGENT'S NO. AIRF 3901 BARRETT DR STE 312 JJ1520 RALEIGH, NC 27609-6611 E �E EX Co.: E Ene IIN eUR N Co. Altana Eln-Fact of AdpNY able I F RK (919)772-7698 This certHicate is Issued for information purposes only and confers no rights on the certificate holder. It does not aRl motive] y or negatively amend, extend, or otherwise eller the terms, exclusions and conditions of insurance coverage contained in the policy(les) Indicated below. The terms and conditions of the policy(ies) govern the insurance coverage as applied to any given situation. Limits shown may have been reduced by claims paid. This certificate of insurance does not constitute a contract between the issuing insurer(s), authorized representative or producer and the certificate holder. NAME AND ADDRESS OF NAMED INSURED BBUDC INC PO BOX 52552 5223 EPHESUS CHURCH ROAD DURHAM, NC 27717 This SM is tO Cerli that policies, as indicated TYPE OF INSURANCE r by the Policy Number below, are POLICY NUMBER in force for the Named 7/22/15 Insured at the 7/22/16 time that the Certificate is bal issued. LIMITS E ® GENERAL LIABILITY © COMMEACWLGENERALLUIBILITY ❑ CLAIMS MADE ® occ ❑ Q31 2221259 _ EACH OCCURRENT 11000-10-0- 0 FIRE DAMAGE One Brill MED EXP My Oce Person 5,0100 PERSONAL&ADV INJURY 1,000,000 ❑ GENERALAGGREGATE 2,000000 GEN'LAGGREGATE LIMIT APPLIES PER ® POLICY ❑ PRO.ECT ❑ LOC PRODUCTS-COMP/OPAGG gi 2000000 E ® AUTOMOBIrLE LIABILITY ❑-ANYAUTO^'NOMI-E HIRE , Q07 2230797 7/22/15 7/22/16 BOaLYINJURY ODILYINJU .. $ © OWNED ❑ HIRED ® NON -OWNED ❑ GARAGE BODILYA�W JURY :. $ PROPERIYDAMAGE : $ BODILYINJURYAND - PROPERTYDAMAGE $ 1,000,000 CWME ❑ EXCESS UAB ® OCCURRENCECE Q312270228 7/22/15 7/22/16 EACH OCCURRENCE S 5,000000 - ` AGGREGATE $ 5,000,000 $ ❑ RETENTION $ 0 -STAIMRY E WORKERS COMPENSATION 8 EMPLOYERS LIABILITY Q 91 2200656 7/22/15 7/22/16FOODILY RY ACCIDENT S 500,000 EACH ACCIDENT DISEASE $ 500,000 POLICY Lima DISEASE $ 500,000 EACH EMPLOYEE OTHER DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES/EXCLUSIONS ADDED BY ENDORSEMENT/SPECIAL PROVISIONS The Wooten Company is to be listed as an additional insured on the General Liability and Commercial Automobile Liability insurance policies. CANCELLATION: SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIV- ERED IN ACCORDANCE WITH THE POLICY PROVISIONS. IMPORTANT. If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). NAME AND ADDRESS OF CERTIFICATE HOLDER THE WOOTEN COMPANY 350 N COX STREET ASHEBORO, NC 27203 AUTHORIZED REPRESENTATIVE Page 1 of 1 John Grey From: Isaac Woods <woodsprose@gmai l.com> Sent: Wednesday, July 22, 2015 6:59 PM To: John Grey Cc: Randy Freeman; Dwayne Childress (dwayne.childress@davidsoncountync.gov) Subject: Re: DavidsonCounty_COI_BBUDCInc_0001.pdf Attachments: AI -Davidson County (3).pdf John, You are correct, the 50,000 was erroneous omitted on the Erie Insurance COI, we will have it added. But it is included on the Per Project (Preferred Contractors Insurance) which I have attached again. All policies are effective, and therefore the proper coverage has been provided as required. Thanks On Wed, Jul 22, 2015 at 4:17 PM, John Grey <igrev@thewootencompany.com> wrote: Isaac, Looks like they are not showing the $50,000 Fire Damage portion on the current certificate and the $2 mil Contractual Liability (page 00800-5 of the project manual) is still not included. I have forwarded to the County for their review, but the way I read the contract those are required. Please check with your insurer to see about these. Thanks John John Grey, PE Project Manager Asheboro Branch Manager The Wooten Company 350 North Cox Street, Suite 26 Asheboro, NC 27203 336.626.5322 Fax 336.626.5722 www.thewootencompany.com I -----Original Message ----- From: Isaac[mailto:woodsprose(cr)gmail.com] Sent: Wednesday, July 22, 2015 3:23 PM To: Randy Freeman; John Grey; Alese King Subject: DavidsonCounty COI_BBUDCInc OOOI.pdf See the attached COI ISAAC 919 357 3828 AcoRO® CERTIFICATE OF LIABILITY INSURANCE F DATE(MMMD/YYYY) TYPE OF INSURANCEADDL 06/15/2015 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endomement(s). PRODUCER CONTACT NAME: PER PROJECT INSURANCE AGENCY HONN (688)269-0992 1 PAC (888)969-0247 09/10/2015 (PA 0. E : No: 3065 ROSECRANS PL STE 208 EMAILDDRESS: m@9q custoerserviceI uote.mm A INSURER(S) AFFORDING COVERAGE NAICY PERSONAL& ADV INJURY $ 1,000,000 INSURERA: Preferred Contractors Insurance Company RRG 12497 SAN DIEGO CA 92110-4822 INSURED INSURER B : ISAAC L WOODS INSURER C: ISAAC L WOODS INSURER D: PO BOX 52552 INSURER E: DURHAM NC 27717-2552 INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. ILTR TYPE OF INSURANCEADDL SUBR POLICY NUMBER POLICY EFF MMMD POLICY EXP mmmo YYYY LIMITS A COMMERCIAL GENERAL LIABILITY CLAIMS -MADE ® OCCUR X PC0006999-00-T1409 09/10/2014 09/10/2015 EACH OCCURRENCE $ 1,000,000 D 50,000 PREMISES PREMISES Ea occurtence $ MED EXP (Any one person) $ 5,000 I PERSONAL& ADV INJURY $ 1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: POLICY E:]JEo r7 LOC OTHER: GENERAL AGGREGATE $ 2,000,000 PRODUCTS-COMP/OP AGG $ 2,000,000 $ AUTOMOBILE LIABILITY ANY AUTO ALL OWNED SCHEDULED AUTOS AUTOS NON-0WNED HIRED AUTOS AUTOS COMBINED SINGLE LIMIT— Me Ea accident BODILY INJURY (Per person) $ BODILY INJURY (Per accident) $ PROPERTY DAMAGE $ Per accident UMBRELLA LIAB EXCESS LIAB OCCUR CLA, MADE EACH OCCURRENCE $ AGGREGATE $ DED RETENTION$ $ WORKERS COMPENSATION AND EMPLOYERS'LIABILITY Y/N ANY PROPRIETORIPARTNEREXECUIVE ❑N/A OFFICERIMEMBER EXCLUDED? (Mandatory in NH) Ryes, describe ander DESCRIPTION OF OPERATIONS bek PEROTH- STATUTE ER E.L. EACH ACCIDENT $ E.L. DISEASE - EA EMPLOYE $ E.L. DISEASE -POLICY LIMIT $ DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, AddiOonal Remarks Schedule, may be attached N mora space Is required) Davidson County and BBUDC Inc are named as a Additional Insured on this policy. Davidson County 925 North Main St. Lexington, NC 27293 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE ACORD 25 (2014/01) The ACORD name and logo are registered marks of ACORD Im reserved, EXHIBIT GC -A CERTIFICATE OF OWNER'S ATTORNEY I, the undersigned, Charles E. Frye, III, the duly authorized and acting legal representative of Davidson County do hereby certify as follows: I have examined the attached Contract(s) and Performance and Payment Bonds and the manner of execution thereof, and I am of the opinion that each of the aforesaid agreements is adequate and has been duly executed by the proper parties thereto acting through their duly authorized representatives; that said representatives have full power and authority to execute said agreements on behalf of the respective parties named thereon; and that the foregoing agreements constitute valid and legally binding obligations upon the parties executing the same in accordance with terms, conditions, and provisions thereof. Date PRE -AUDIT STATEMENT This instrument has been pre -audited in the manner required by the Local Government Budget and Fiscal Control Act. Davidson County Date: 7143 /d o fS By: �d • k4 Jane S. Kiker Title: Finance Director 3097-F : 07/14/15 00634-1 Owner's Certification This document has important legal consequences; consultation with an attorney is encouraged with respect to its use or modification. This document should be adapted to the particular circumstances of the contemplated Project and the controlling Laws and Regulations. STANDARD GENERAL CONDITIONS OF THE CONSTRUCTION CONTRACT Prepared by ENGINEERS JOINT CONTRACT DOCUMENTS COMMITTEE and Issued and Published Jointly by --_ u ACEC ®°_ AMGIUM1 COONLIL OP EVpNVA1NG COMPAN16i � SCEAmerican Society of Cita) Engineers National Society of Professional Engineers Professional Eaphmersin Private Practice AMERICAN COUNCIL OF ENGINEERING COMPANIES ASSOCIATED GENERAL CONTRACTORS OF AMERICA AMERICAN SOCIETY OF CIVIL ENGINEERS PROFESSIONAL ENGINEERS IN PRIVATE PRACTICE A Practice Division ojthe NATIONAL SOCIETY OF PROFESSIONAL ENGINEERS Endorsed by IV CONSTRUCTION SPECIFICATIONS INSTITUTE EJCDC C-700 Standard General Conditions of the Construction Contract Copyright 0 2007 National Society of Professional Engineers for EJCDC. All rights reserved. These General Conditions have been prepared for use with the Suggested Forms of Agreement Between Owner and Contractor (EJCDC C-520 or C-525, 2007 Editions). Their provisions are interrelated and a change in one may necessitate a change in the other. Comments concerning their usage are contained in the Narrative Guide to the EJCDC Construction Documents (EJCDC C-001, 2007 Edition). For guidance in the preparation of Supplementary Conditions, see Guide to the Preparation of Supplementary Conditions (EJCDC C-800, 2007 Edition). Copyright C 2007 National Society of Professional Engineers 1420 King Street, Alexandria, VA 22314-2794 (703)684-2882 www.nspe.org American Council of Engineering Companies 1015 15th Street N.W., Washington, DC 20005 (202)347-7474 www.acec.ore American Society of Civil Engineers 1801 Alexander Bell Drive, Reston, VA 20191-4400 (800)548-2723 www.asce.ore Associated General Contractors of America 2300 Wilson Boulevard, Suite 400, Arlington, VA 22201-3308 (703)548-3118 www.agc.org The copyright for this EJCDC document is owned jointly by the four EJCDC sponsoring organizations and held in trust for their benefit by NSPE. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright 0 2007 National Society of Professional Engineers for EJCDC. AH rights reserved. STANDARD GENERAL CONDITIONS OF THE CONSTRUCTION CONTRACT TABLE OF CONTENTS Page Article I — Definitions and Terminology........................................................................................................... l 1.01 Defined Terms...............................................................................................................................1 1.02 Terminology..................................................................................................................................5 Article 2 — Preliminary Matters.........................................................................................................................6 2.01 Delivery of Bonds and Evidence of Insurance .............................................................................6 2.02 Copies of Documents....................................................................................................................6 2.03 Commencement of Contract Times; Notice to Proceed...............................................................6 2.04 Starting the Work..........................................................................................................................7 2.05 Before Starting Construction........................................................................................................7 2.06 Preconstruction Conference; Designation of Authorized Representatives..................................7 2.07 Initial Acceptance of Schedules....................................................................................................7 Article 3 — Contract Documents: Intent, Amending, Reuse.............................................................................8 3.01 Intent.............................................................................................................................................. 8 3.02 Reference Standards......................................................................................................................8 3.03 Reporting and Resolving Discrepancies.......................................................................................9 3.04 Amending and Supplementing Contract Documents...................................................................9 3.05 Reuse of Documents...................................................................................................................10 3.06 Electronic Data............................................................................................................................10 Article 4 — Availability of Lands; Subsurface and Physical Conditions; Hazardous Environmental Conditions; Reference Points...........................................................................................................11 4.01 Availability of Lands................................................................................................................... 11 4.02 Subsurface and Physical Conditions...........................................................................................11 4.03 Differing Subsurface or Physical Conditions.............................................................................12 4.04 Underground Facilities................................................................................................................13 4.05 Reference Points..........................................................................................................................14 4.06 Hazardous Environmental Condition at Site..............................................................................14 Article 5 — Bonds and Insurance ......................................................................................................................16 5.01 Performance, Payment, and Other Bonds...................................................................................16 5.02 Licensed Sureties and Insurers....................................................................................................16 5.03 Certificates of Insurance..............................................................................................................17 5.04 Contractor's Insurance................................................................................................................17 5.05 Owner's Liability Insurance........................................................................................................19 5.06 Property Insurance.......................................................................................................................19 5.07 Waiver of Rights.........................................................................................................................20 5.08 Receipt and Application of Insurance Proceeds.........................................................................21 EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. An rights reserved 5.09 Acceptance of Bonds and Insurance; Option to Replace...........................................................21 5.10 Partial Utilization, Acknowledgment of Property Insurer..........................................................22 Article 6 - Contractor's Responsibilities.........................................................................................................22 6.01 Supervision and Superintendence ...............................................................................................22 6.02 Labor; Working Hours................................................................................................................22 6.03 Services, Materials, and Equipment...........................................................................................22 6.04 Progress Schedule.......................................................................................................................23 6.05 Substitutes and "Or-Equals".......................................................................................................23 6.06 Concerning Subcontractors, Suppliers, and Others....................................................................25 36 6.07 Patent Fees and Royalties............................................................................................................27 6.08 Permits.........................................................................................................................................27 6.09 Laws and Regulations.................................................................................................................28 6.10 Taxes............................................................................................................................................28 6.11 Use of Site and Other Areas ........................................................................................................28 6.12 Record Documents......................................................................................................................29 6.13 Safety and Protection...................................................................................................................29 6.14 Safety Representative..................................................................................................................30 6.15 Hazard Communication Programs..............................................................................................30 6.16 Emergencies................................................................................................................................30 6.17 Shop Drawings and Samples......................................................................................................31 6.18 Continuing the Work...................................................................................................................32 6.19 Contractor's General Warranty and Guarantee..........................................................................33 6.20 Indemnification...........................................................................................................................33 6.21 Delegation of Professional Design Services...............................................................................34 Article 7 - Other Work at the Site...................................................................................................................35 7.01 Related Work at Site...................................................................................................................35 7.02 Coordination................................................................................................................................35 7.03 Legal Relationships.....................................................................................................................36 Article 8 - Owner's Responsibilities...............................................................................................................36 8.01 Communications to Contractor...................................................................................................36 8.02 Replacement of Engineer............................................................................................................36 8.03 Furnish Data................................................................................................................................36 8.04 Pay When Due.............................................................................................................................36 8.05 Lands and Easements; Reports and Tests...................................................................................36 8.06 Insurance...................................................................................................................................... 36 8.07 Change Orders.............................................................................................................................37 8.08 Inspections, Tests, and Approvals...............................................................................................37 8.09 Limitations on Owner's Responsibilities....................................................................................37 8.10 Undisclosed Hazardous Environmental Condition....................................................................37 8.11 Evidence of Financial Arrangements..........................................................................................37 8.12 Compliance with Safety Program...............................................................................................37 Article 9 - Engineer's Status During Construction.........................................................................................37 9.01 Owner's Representative..............................................................................................................37 EJCDC C-700 Standard General Conditions of the Construction Contract Copyright m 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Pace ii 9.02 Visits to Site................................................................................................................................37 9.03 Project Representative.................................................................................................................38 9.04 Authorized Variations in Work...................................................................................................38 9.05 Rejecting Defective Work...........................................................................................................38 9.06 Shop Drawings, Change Orders and Payments..........................................................................39 9.07 Determinations for Unit Price Work...........................................................................................39 9.08 Decisions on Requirements of Contract Documents and Acceptability of Work .....................39 9.09 Limitations on Engineer's Authority and Responsibilities........................................................39 9.10 Compliance with Safety Program...............................................................................................40 Article 10 - Changes in the Work; Claims......................................................................................................40 10.01 Authorized Changes in the Work................................................................................................40 10.02 Unauthorized Changes in the Work............................................................................................41 10.03 Execution of Change Orders.......................................................................................................41 10.04 Notification to Surety..................................................................................................................41 10.05 Claims..........................................................................................................................................41 Article 11- Cost of the Work; Allowances; Unit Price Work.......................................................................42 11.01 Cost of the Work.........................................................................................................................42 11.02 Allowances..................................................................................................................................45 11.03 Unit Price Work--------------------------------------------------------------------------------------- _ _ 45 Article 12 - Change of Contract Price; Change of Contract Times................................................................46 12.01 Change of Contract Price ............................................................................................................46 12.02 Change of Contract Times..........................................................................................................47 12.03 Delays..........................................................................................................................................47 Article 13 - Tests and Inspections; Correction, Removal or Acceptance of Defective Work.......................48 13.01 Notice of Defects.........................................................................................................................48 13.02 Access to Work...........................................................................................................................48 13.03 Tests and Inspections..................................................................................................................49 13.04 Uncovering Work........................................................................................................................49 13.05 Owner May Stop the Work.........................................................................................................50 13.06 Correction or Removal of Defective Work................................................................................50 13.07 Correction Period........................................................................................................................50 13.08 Acceptance of Defective Work...................................................................................................51 13.09 Owner May Correct Defective Work..........................................................................................52 Article 14 - Payments to Contractor and Completion 14.01 Schedule of Values .................................. 14.02 Progress Payments ................................... 14.03 Contractor's Warranty of Title ................ 14.04 Substantial Completion .........................., 14.05 Partial Utilization ..................................., 14.06 Final Inspection ....................................... 14.07 Final Payment .......................................... 14.08 Final Completion Delayed ...................... ...................................................................... 52 ............................:......................................... 52 ...................................................................... 52 ...................................................................... 55 ...................................................................... 55 ...................................................................... 56 ...................................................................... 57 ...................................................................... 57 ...................................................................... 58 EJCDC C-700 Standard General Conditions of the Construction Contract Copyright 0 2007 National Society of Professional Engineers for EJCDC. All rights reserved. 14.09 Waiver of Claims........................................................................................................................58 Article 15 — Suspension of Work and Termination.........................................................................................59 15.01 Owner May Suspend Work.........................................................................................................59 15.02 Owner May Terminate for Cause................................................................................................59 15.03 Owner May Terminate For Convenience ...................................................................................60 15.04 Contractor May Stop Work or Terminate...................................................................................60 Article 16 — Dispute Resolution......................................................................................................................61 16.01 Methods and Procedures.............................................................................................................61 Article17 — Miscellaneous..............................................................................................................................61 17.01 Giving Notice..............................................................................................................................61 17.02 Computation of Times................................................................................................................62 17.03 Cumulative Remedies.................................................................................................................62 17.04 Survival of Obligations...............................................................................................................62 17.05 Controlling Law..........................................................................................................................62 17.06 Headings......................................................................................................................................62 EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page iv ARTICLE 1— DEFINITIONS AND TERMINOLOGY 1.01 Defined Terms A. Wherever used in the Bidding Requirements or Contract Documents and printed with initial capital letters, the terms listed below will have the meanings indicated which are applicable to both the singular and plural thereof. In addition to terms specifically defined, terms with initial capital letters in the Contract Documents include references to identified articles and paragraphs, and the titles of other documents or forms. 1. Addenda—Written or graphic instruments issued prior to the opening of Bids which clarify, correct, or change the Bidding Requirements or the proposed Contract Documents. 2. Agreement—The written instrument which is evidence of the agreement between Owner and Contractor covering the Work. 3. Application for Payment—The form acceptable to Engineer which is to be used by Contractor during the course of the Work in requesting progress or final payments and which is to be accompanied by such supporting documentation as is required by the Contract Documents. 4. Asbestos—Any material that contains more than one percent asbestos and is friable or is releasing asbestos fibers into the air above current action levels established by the United States Occupational Safety and Health Administration. 5. Bid—The offer or proposal of a Bidder submitted on the prescribed form setting forth the prices for the Work to be performed. 6. Bidder—The individual or entity who submits a Bid directly to Owner. 7. Bidding Documents—The Bidding Requirements and the proposed Contract Documents (including all Addenda). 8. Bidding Requirements—The advertisement or invitation to bid, Instructions to Bidders, Bid security of acceptable form, if any, and the Bid Form with any supplements. 9. Change Order—A document recommended by Engineer which is signed by Contractor and Owner and authorizes an addition, deletion, or revision in the Work or an adjustment in the Contract Price or the Contract Times, issued on or after the Effective Date of the Agreement. 10. Claim—A demand or assertion by Owner or Contractor seeking an adjustment of Contract Price or Contract Times, or both, or other relief with respect to the terms of the Contract. A demand for money or services by a third party is not a Claim. 11. Contract—The entire and integrated written agreement between the Owner and Contractor concerning the Work. The Contract supersedes prior negotiations, representations, or agreements, whether written or oral. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Paue 1 of 62 12. Contract Documents—Those items so designated in the Agreement. Only printed or hard copies of the items listed in the Agreement are Contract Documents. Approved Shop Drawings, other Contractor submittals, and the reports and drawings of subsurface and physical conditions are not Contract Documents. 13. Contract Price—The moneys payable by Owner to Contractor for completion of the Work in accordance with the Contract Documents as stated in the Agreement (subject to the provisions of Paragraph 11.03 in the case of Unit Price Work). 14. Contract Times—The number of days or the dates stated in the Agreement to: (i) achieve Milestones, if any; (ii) achieve Substantial Completion; and (iii) complete the Work so that it is ready for final payment as evidenced by Engineer's written recommendation of final payment. 15. Contractor—The individual or entity with whom Owner has entered into the Agreement. 16. Cost of the Work—See Paragraph 11.01 for definition. 17. Drawings—That part of the Contract Documents prepared or approved by Engineer which graphically shows the scope, extent, and character of the Work to be performed by Contractor. Shop Drawings and other Contractor submittals are not Drawings as so defined. 18. Effective Date of the Agreement—The date indicated in the Agreement on which it becomes effective, but if no such date is indicated, it means the date on which the Agreement is signed and delivered by the last of the two parties to sign and deliver. 19. Engineer—The individual or entity named as such in the Agreement. 20. Field Order—A written order issued by Engineer which requires minor changes in the Work but which does not involve a change in the Contract Price or the Contract Times. 21. General Requirements—Sections of Division 1 of the Specifications. 22. Hazardous Environmental Condition—The presence at the Site of Asbestos, PCBs, Petroleum, Hazardous Waste, or Radioactive Material in such quantities or circumstances that may present a substantial danger to persons or property exposed thereto. 23. Hazardous Waste—The term Hazardous Waste shall have the meaning provided in Section 1004 of the Solid Waste Disposal Act (42 USC Section 6903) as amended from time to time. 24. Laws and Regulations; Laws or Regulations—Any and all applicable laws, rules, regulations, ordinances, codes, and orders of any and all governmental bodies, agencies, authorities, and courts having jurisdiction. 25. Liens—Charges, security interests, or encumbrances upon Project funds, real property, or personal property. 26. Milestone—A principal event specified in the Contract Documents relating to an intermediate completion date or time prior to Substantial Completion of all the Work. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Pate 2 of 62 27. Notice of Award—The written notice by Owner to the Successful Bidder stating that upon timely compliance by the Successful Bidder with the conditions precedent listed therein, Owner will sign and deliver the Agreement. 28. Notice to Proceed—A written notice given by Owner to Contractor fixing the date on which the Contract Times will commence to run and on which Contractor shall start to perform the Work under the Contract Documents. 29. Owner—The individual or entity with whom Contractor has entered into the Agreement and for whom the Work is to be performed. 30. PCBs—Polychlorinated biphenyls. 31. Petroleum—Petroleum, including crude oil or any fraction thereof which is liquid at standard conditions of temperature and pressure (60 degrees Fahrenheit and 14.7 pounds per square inch absolute), such as oil, petroleum, fuel oil, oil sludge, oil refuse, gasoline, kerosene, and oil mixed with other non -Hazardous Waste and crude oils. 32. Progress Schedule—A schedule, prepared and maintained by Contractor, describing the sequence and duration of the activities comprising the Contractor's plan to accomplish the Work within the Contract Times. 33. Project—The total construction of which the Work to be performed under the Contract Documents may be the whole, or a part. 34. Project Manual—The bound documentary information prepared for bidding and constructing the Work. A listing of the contents of the Project Manual, which may be bound in one or more volumes, is contained in the table(s) of contents. 35. Radioactive Material—Source, special nuclear, or byproduct material as defined by the Atomic Energy Act of 1954 (42 USC Section 2011 et seq.) as amended from time to time. 36. Resident Project Representative—The authorized representative of Engineer who may be assigned to the Site or any part thereof. 37. Samples—Physical examples of materials, equipment, or workmanship that are representative of some portion of the Work and which establish the standards by which such portion of the Work will be judged. 38. Schedule of Submittals—A schedule, prepared and maintained by Contractor, of required submittals and the time requirements to support scheduled performance of related construction activities. 39. Schedule of Values—A schedule, prepared and maintained by Contractor, allocating portions of the Contract Price to various portions of the Work and used as the basis for reviewing Contractor's Applications for Payment. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright 0 2007 National Society of Professional Engineers for EJCDC. All rights reserved. 40. Shop Drawings All drawings, diagrams, illustrations, schedules, and other data or information which are specifically prepared or assembled by or for Contractor and submitted by Contractor to illustrate some portion of the Work. 41. Site—Lands or areas indicated in the Contract Documents as being finnished by Owner upon which the Work is to be performed, including rights-of-way and easements for access thereto, and such other lands furnished by Owner which are designated for the use of Contractor. 42. Specifications—That part of the Contract Documents consisting of written requirements for materials, equipment, systems, standards and workmanship as applied to the Work, and certain administrative requirements and procedural matters applicable thereto. 43. Subcontractor—An individual or entity having a direct contract with Contractor or with any other Subcontractor for the performance of a part of the Work at the Site. 44. Substantial Completion—The time at which the Work (or a specified part thereof) has progressed to the point where, in the opinion of Engineer, the Work (or a specified part thereof) is sufficiently complete, in accordance with the Contract Documents, so that the Work (or a specified part thereof) can be utilized for the purposes for which it is intended. The terms "substantially complete" and "substantially completed" as applied to all or part of the Work refer to Substantial Completion thereof. 45. Successful Bidder—The Bidder submitting a responsive Bid to whom Owner makes an award. 46. Supplementary Conditions—That part of the Contract Documents which amends or supplements these General Conditions. 47. Supplier—A manufacturer, fabricator, supplier, distributor, materialman, or vendor having a direct contract with Contractor or with any Subcontractor to furnish materials or equipment to be incorporated in the Work by Contractor or Subcontractor. 48. Underground Facilities—All underground pipelines, conduits, ducts, cables, wires, manholes, vaults, tanks, tunnels, or other such facilities or attachments, and any encasements containing such facilities, including those that convey electricity, gases, steam, liquid petroleum products, telephone or other communications, cable television, water, wastewater, storm water, other liquids or chemicals, or traffic or other control systems. 49. Unit Price Work—Work to be paid for on the basis of unit prices. 50. Work—The entire construction or the various separately identifiable parts thereof required to be provided under the Contract Documents. Work includes and is the result of performing or providing all labor, services, and documentation necessary to produce such construction, and famishing, installing, and incorporating all materials and equipment into such construction, all as required by the Contract Documents. 51. Work Change Directive—A written statement to Contractor issued on or after the Effective Date of the Agreement and signed by Owner and recommended by Engineer ordering an EJCDC C-700 Standard General Conditions of the Construction Contract Copyright® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 4 of 62 addition, deletion, or revision in the Work, or responding to differing or unforeseen subsurface or physical conditions under which the Work is to be performed or to emergencies. A Work Change Directive will not change the Contract Price or the Contract Times but is evidence that the parties expect that the change ordered or documented by a Work Change Directive will be incorporated in a subsequently issued Change Order following negotiations by the parties as to its effect, if any, on the Contract Price or Contract Times. 1.02 Terminology A. The words and terms discussed in Paragraph 1.02.B through F are not defined but, when used in the Bidding Requirements or Contract Documents, have the indicated meaning. B. Intent of Certain Terms or Adjectives: 1. The Contract Documents include the terms "as allowed," "as approved," "as ordered," "as directed" or terms of like effect or import to authorize an exercise of professional judgment by Engineer. In addition, the adjectives "reasonable," "suitable," "acceptable," "proper," "satisfactory," or adjectives of like effect or import are used to describe an action or determination of Engineer as to the Work. It is intended that such exercise of professional judgment, action, or determination will be solely to evaluate, in general, the Work for compliance with the information in the Contract Documents and with the design concept of the Project as a functioning whole as shown or indicated in the Contract Documents (unless there is a specific statement indicating otherwise). The use of any such term or adjective is not intended to and shall not be effective to assign to Engineer any duty or authority to supervise or direct the performance of the Work, or any duty or authority to undertake responsibility contrary to the provisions of Paragraph 9.09 or any other provision of the Contract Documents. C. Day: 1. The word "day" means a calendar day of 24 hours measured from midnight to the next midnight. D. Defective: 1. The word "defective," when modifying the word "Work," refers to Work that is unsatisfactory, faulty, or deficient in that it: a. does not conform to the Contract Documents; or b. does not meet the requirements of any applicable inspection, reference standard, test, or approval referred to in the Contract Documents; or c. has been damaged prior to Engineer's recommendation of final payment (unless responsibility for the protection thereof has been assumed by Owner at Substantial Completion in accordance with Paragraph 14.04 or 14.05). EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 5 of 62 E. Furnish, Install, Perform, Provide: The word "furnish," when used in connection with services, materials, or equipment, shall mean to supply and deliver said services, materials, or equipment to the Site (or some other specified location) ready for use or installation and in usable or operable condition. 2. The word "install," when used in connection with services, materials, or equipment, shall mean to put into use or place in final position said services, materials, or equipment complete and ready for intended use. 3. The words "perform" or "provide," when used in connection with services, materials, or equipment, shall mean to furnish and install said services, materials, or equipment complete and ready for intended use. 4. When "furnish," "install," "perform," or "provide" is not used in connection with services, materials, or equipment in a context clearly requiring an obligation of Contractor, "provide" is implied. F. Unless stated otherwise in the Contract Documents, words or phrases that have a well-known technical or construction industry or trade meaning are used in the Contract Documents in accordance with such recognized meaning. ARTICLE 2 — PRELIMINARY MATTERS 2.01 Delivery of Bonds and Evidence oflnsurance A. When Contractor delivers the executed counterparts of the Agreement to Owner, Contractor shall also deliver to Owner such bonds as Contractor may be required to furnish. B. Evidence oflnsurance: Before any Work at the Site is started, Contractor and Owner shall each deliver to the other, with copies to each additional insured identified in the Supplementary Conditions, certificates of insurance (and other evidence of insurance which either of them or any additional insured may reasonably request) which Contractor and Owner respectively are required to purchase and maintain in accordance with Article 5. 2.02 Copies of Documents A. Owner shall furnish to Contractor up to ten printed or hard copies of the Drawings and Project Manual. Additional copies will be furnished upon request at the cost of reproduction. 2.03 Commencement of Contract Times; Notice to Proceed A. The Contract Times will commence to run on the thirtieth day after the Effective Date of the Agreement or, if a Notice to Proceed is given, on the day indicated in the Notice to Proceed. A Notice to Proceed may be given at any time within 30 days after the Effective Date of the Agreement. In no event will the Contract Times commence to run later than the sixtieth day after the day of Bid opening or the thirtieth day after the Effective Date of the Agreement, whichever date is earlier. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright C 2007 National Society of Professional Engineers for EJCDC. AN rights reserved. Page 6 of 62 2.04 Starting the Work A. Contractor shall start to perform the Work on the date when the Contract Times commence to run. No Work shall be done at the Site prior to the date on which the Contract Times commence to run. 2.05 Before Starting Construction A. Preliminary Schedules: Within 10 days after the Effective Date of the Agreement (unless otherwise specified in the General Requirements), Contractor shall submit to Engineer for timely review: a preliminary Progress Schedule indicating the times (numbers of days or dates) for starting and completing the various stages of the Work, including any Milestones specified in the Contract Documents; 2. a preliminary Schedule of Submittals; and a preliminary Schedule of Values for all of the Work which includes quantities and prices of items which when added together equal the Contract Price and subdivides the Work into component parts in sufficient detail to serve as the basis for progress payments during performance of the Work. Such prices will include an appropriate amount of overhead and profit applicable to each item of Work. 2.06 Preconstruction Conference; Designation of Authorized Representatives A. Before any Work at the Site is started, a conference attended by Owner, Contractor, Engineer, and others as appropriate will be held to establish a working understanding among the parties as to the Work and to discuss the schedules referred to in Paragraph 2.05.A, procedures for handling Shop Drawings and other submittals, processing Applications for Payment, and maintaining required records. B. At this conference Owner and Contractor each shall designate, in writing, a specific individual to act as its authorized representative with respect to the services and responsibilities under the Contract. Such individuals shall have the authority to transmit instructions, receive information, render decisions relative to the Contract, and otherwise act on behalf of each respective party. 2.07 Initial Acceptance of Schedules A. At least 10 days before submission of the fust Application for Payment a conference attended by Contractor, Engineer, and others as appropriate will be held to review for acceptability to Engineer as provided below the schedules submitted in accordance with Paragraph 2.05.A. Contractor shall have an additional 10 days to make corrections and adjustments and to complete and resubmit the schedules. No progress payment shall be made to Contractor until acceptable schedules are submitted to Engineer. 1. The Progress Schedule will be acceptable to Engineer if it provides an orderly progression of the Work to completion within the Contract Times. Such acceptance will not impose on EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Paoe 7 of 62 Engineer responsibility for the Progress Schedule, for sequencing, scheduling, or progress of the Work, nor interfere with or relieve Contractor from Contractor's full responsibility therefor. 2. Contractor's Schedule of Submittals will be acceptable to Engineer if it provides a workable arrangement for reviewing and processing the required submittals. 3. Contractor's Schedule of Values will be acceptable to Engineer as to form and substance if it provides a reasonable allocation of the Contract Price to component parts of the Work. ARTICLE 3 — CONTRACT DOCUMENTS: INTENT, AMENDING, REUSE 3.01 Intent A. The Contract Documents are complementary; what is required by one is as binding as if required by all. B. It is the intent of the Contract Documents to describe a functionally complete project (or part thereof) to be constructed in accordance with the Contract Documents. Any labor, documentation, services, materials, or equipment that reasonably may be inferred from the Contract Documents or from prevailing custom or trade usage as being required to produce the indicated result will be provided whether or not specifically called for, at no additional cost to Owner. C. Clarifications and interpretations of the Contract Documents shall be issued by Engineer as provided in Article 9. 3.02 Reference Standards A. Standards, Specifications, Codes, Laws, and Regulations 1. Reference to standards, specifications, manuals, or codes of any technical society, organization, or association, or to Laws or Regulations, whether such reference be specific or by implication, shall mean the standard, specification, manual, code, or Laws or Regulations in effect at the time of opening of Bids (or on the Effective Date of the Agreement if there were no Bids), except as may be otherwise specifically stated in the Contract Documents. 2. No provision of any such standard, specification, manual, or code, or any instruction of a Supplier, shall be effective to change the duties or responsibilities of Owner, Contractor, or Engineer, or any of their subcontractors, consultants, agents, or employees, from those set forth in the Contract Documents. No such provision or instruction shall be effective to assign to Owner, Engineer, or any of their officers, directors, members, partners, employees, agents, consultants, or subcontractors, any duty or authority to supervise or direct the performance of the Work or any duty or authority to undertake responsibility inconsistent with the provisions of the Contract Documents. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 8 of 62 3.03 Reporting and Resolving Discrepancies A. Reporting Discrepancies: Contractor's Review of Contract Documents Before Starting Work: Before undertaking each part of the Work, Contractor shall carefully study and compare the Contract Documents and check and verify pertinent figures therein and all applicable field measurements. Contractor shall promptly report in writing to Engineer any conflict, error, ambiguity, or discrepancy which Contractor discovers, or has actual knowledge of, and shall obtain a written interpretation or clarification from Engineer before proceeding with any Work affected thereby. 2. Contractor's Review of Contract Documents During Performance of Work: If, during the performance of the Work, Contractor discovers any conflict, error, ambiguity, or discrepancy within the Contract Documents, or between the Contract Documents and (a) any applicable Law or Regulation, (b) any standard, specification, manual, or code, or (c) any instruction of any Supplier, then Contractor shall promptly report it to Engineer in writing. Contractor shall not proceed with the Work affected thereby (except in an emergency as required by Paragraph 6.16.A) until an amendment or supplement to the Contract Documents has been issued by one of the methods indicated in Paragraph 3.04. 3. Contractor shall not be liable to Owner or Engineer for failure to report any conflict, error, ambiguity, or discrepancy in the Contract Documents unless Contractor had actual knowledge thereof. B. Resolving Discrepancies: 1. Except as may be otherwise specifically stated in the Contract Documents, the provisions of the Contract Documents shall take precedence in resolving any conflict, error, ambiguity, or discrepancy between the provisions of the Contract Documents and: a. the provisions of any standard, specification, manual, or code, or the instruction of any Supplier (whether or not specifically incorporated by reference in the Contract Documents); or b. the provisions of any Laws or Regulations applicable to the performance of the Work (unless such an interpretation of the provisions of the Contract Documents would result in violation of such Law or Regulation). 3.04 Amending and Supplementing Contract Documents A. The Contract Documents may be amended to provide for additions, deletions, and revisions in the Work or to modify the terns and conditions thereof by either a Change Order or a Work Change Directive. B. The requirements of the Contract Documents may be supplemented, and minor variations and deviations in the Work may be authorized, by one or more of the following ways: EJCDC C-700 Standard General Conditions of the Construction Contract Copyright 0 2007 National Society of Professional Engineers for EJCDC. All rights reserved. 1. A Field Order; 2. Engineer's approval of a Shop Drawing or Sample (subject to the provisions of Paragraph 6.17.D.3); or 3. Engineer's written interpretation or clarification. 3.05 Reuse of Documents A. Contractor and any Subcontractor or Supplier -shall not: 1. have or acquire any title to or ownership rights in any of the Drawings, Specifications, or other documents (or copies of any thereof) prepared by or bearing the seal of Engineer or its consultants, including electronic media editions; or 2. reuse any such Drawings, Specifications, other documents, or copies thereof on extensions of the Project or any other project without written consent of Owner and Engineer and specific written verification or adaptation by Engineer. B. The prohibitions of this Paragraph 3.05 will survive final payment, or termination of the Contract. Nothing herein shall preclude Contractor from retaining copies of the Contract Documents for record purposes. 3.06 Electronic Data A. Unless otherwise stated in the Supplementary Conditions, the data furnished by Owner or Engineer to Contractor, or by Contractor to Owner or Engineer, that may be relied upon are limited to the printed copies (also known as hard copies). Files in electronic media format of text, data, graphics, or other types are furnished only for the convenience of the receiving party. Any conclusion or information obtained or derived from such electronic files will be at the user's sole risk. If there is a discrepancy between the electronic files and the hard copies, the hard copies govern. B. Because data stored in electronic media format can deteriorate or be modified inadvertently or otherwise without authorization of the data's creator, the party receiving electronic files agrees that it will perform acceptance tests or procedures within 60 days, after which the receiving party shall be deemed to have accepted the data thus transferred. Any errors detected within the 60 -day acceptance period will be corrected by the transferring patty. C. When transferring documents in electronic media format, the transferring party makes no representations as to long term compatibility, usability, or readability of documents resulting from the use of software application packages, operating systems, or computer hardware differing from those used by the data's creator. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright® 2007 National Society of professional Engineers for EJCDC. All rights reserved. ARTICLE 4 — AVAILABILITY OF LANDS; SUBSURFACE AND PHYSICAL CONDITIONS; HAZARDOUS ENVIRONMENTAL CONDITIONS; REFERENCE POINTS 4.01 Availability of Lands A. Owner shall furnish the Site. Owner shall notify Contractor of any encumbrances or restrictions not of general application but specifically related to use of the Site with which Contractor must comply in performing the Work. Owner will obtain in a timely manner and pay for easements for permanent structures or permanent changes in existing facilities. If Contractor and Owner are unable to agree on entitlement to or on the amount or extent, if any, of any adjustment in the Contract Price or Contract Times, or both, as a result of any delay in Owner's furnishing the Site or a part thereof, Contractor may make a Claim therefor as provided in Paragraph 10.05. B. Upon reasonable written request, Owner shall famish Contractor with a current statement of record legal title and legal description of the lands upon which the Work is to be performed and Owner's interest therein as necessary for giving notice of or filing a mechanic's or construction lien against such lands in accordance with applicable Laws and Regulations. C. Contractor shall provide for all additional lands and access thereto that may be required for temporary construction facilities or storage of materials and equipment. 4.02 Subsurface and Physical Conditions A. Reports and Drawings: The Supplementary Conditions identify: 1. those reports known to Owner of explorations and tests of subsurface conditions at or contiguous to the Site; and 2. those drawings known to Owner of physical conditions relating to existing surface or subsurface structures at the Site (except Underground Facilities). B. Limited Reliance by Contractor on Technical Data Authorized: Contractor may rely upon the accuracy of the "technical data" contained in such reports and drawings, but such reports and drawings are not Contract Documents. Such "technical data" is identified in the Supplementary Conditions. Except for such reliance on such "technical data," Contractor may not rely upon or make any claim against Owner or Engineer, or any of their officers, directors, members, partners, employees, agents, consultants, or subcontractors with respect to: 1. the completeness of such reports and drawings for Contractor's purposes, including, but not limited to, any aspects of the means, methods, techniques, sequences, and procedures of construction to be employed by Contractor, and safety precautions and programs incident thereto; or 2. other data, interpretations, opinions, and information contained in such reports or shown or indicated in such drawings; or 3. any Contractor interpretation of or conclusion drawn from any "technical data" or any such other data, interpretations, opinions, or information. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 11 of 62 4.03 Differing Subsurface or Physical Conditions A. Notice: If Contractor believes that any subsurface or physical condition that is uncovered or revealed either: 1. is of such a nature as to establish that any "technical data" on which Contractor is entitled to rely as provided in Paragraph 4.02 is materially inaccurate; or 2. is of such a nature as to require a change in the Contract Documents; or 3. differs materially from that shown or indicated in the Contract Documents; or 4. is of an unusual nature, and differs materially from conditions ordinarily encountered and generally recognized as inherent in work of the character provided for in the Contract Documents; then Contractor shall, promptly after becoming aware thereof and before further disturbing the subsurface or physical conditions or performing any Work in connection therewith (except in an emergency as required by Paragraph 6.16.A), notify Owner and Engineer in writing about such condition. Contractor shall not further disturb such condition or perform any Work in connection therewith (except as aforesaid) until receipt of written order to do so. B. Engineer's Review: After receipt of written notice as required by Paragraph 4.03.A, Engineer will promptly review the pertinent condition, determine the necessity of Owner's obtaining additional exploration or tests with respect thereto, and advise Owner in writing (with a copy to Contractor) of Engineer's findings and conclusions. C. Possible Price and Times Adjustments: 1. The Contract Price or the Contract Times, or both, will be equitably adjusted to the extent that the existence of such differing subsurface or physical condition causes an increase or decrease in Contractor's cost of, or time required for, performance of the Work; subject, however, to the following: a. such condition must meet any one or more of the categories described in Paragraph. 4.03.A; and b. with respect to Work that is paid for on a unit price basis, any adjustment in Contract Price will be subject to the provisions of Paragraphs 9.07 and 11.03. 2. Contractor shall not be entitled to any adjustment in the Contract Price or Contract Times if: a. Contractor knew of the existence of such conditions at the time Contractor made a final commitment to Owner with respect to Contract Price and Contract Times by the submission of a Bid or becoming bound under a negotiated contract; or b. the existence of such condition could reasonably have been discovered or revealed as a result of any examination, investigation, exploration, test, or study of the Site and EJCDC C-700 standard General Conditions of the Construction Contract Copyright C 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Pane 12 of 62 contiguous areas required by the Bidding Requirements or Contract Documents to be conducted by or for Contractor prior to Contractor's making such final commitment; or c. Contractor failed to give the written notice as required by Paragraph 4.03.A. 3. If Owner and Contractor are unable to agree on entitlement to or on the amount or extent, if any, of any adjustment in the Contract Price or Contract Times, or both, a Claim may be made therefor as provided in Paragraph 10.05. However, neither Owner or Engineer, or any of their officers, directors, members, partners, employees, agents, consultants, or subcontractors shall be liable to Contractor for any claims, costs, losses, or damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) sustained by Contractor on or in connection with any other project or anticipated project. 4.04 Underground Facilities A. Shown or Indicated: The information and data shown or indicated in the Contract Documents with respect to existing Underground Facilities at or contiguous to the Site is based on information and data furnished to Owner or Engineer by the owners of such Underground Facilities, including Owner, or by others. Unless it is otherwise expressly provided in the Supplementary Conditions: 1. Owner and Engineer shall not be responsible for the accuracy or completeness of any such information or data provided by others; and 2. the cost of all of the following will be included in the Contract Price, and Contractor shall have full responsibility for: a. reviewing and checking all such information and data; b. locating all Underground Facilities shown or indicated in the Contract Documents; c. coordination of the Work with the owners of such Underground Facilities, including Owner, during construction; and d. the safety and protection of all such Underground Facilities and repairing any damage thereto resulting from the Work. B. Not Shown or Indicated.- 1. ndicated: 1. If an Underground Facility is uncovered or revealed at or contiguous to the Site which was not shown or indicated, or not shown or indicated with reasonable accuracy in the Contract Documents, Contractor shall, promptly after becoming aware thereof and before further disturbing conditions affected thereby or performing any Work in connection therewith (except in an emergency as required by Paragraph 6.16.A), identify the owner of such Underground Facility and give written notice to that owner and to Owner and Engineer. Engineer will promptly review the Underground Facility and determine the extent, if any, to which a change is required in the Contract Documents to reflect and document the EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Pave 13 of 62 consequences of the existence or location of the Underground Facility. During such time, Contractor shall be responsible for the safety and protection of such Underground Facility. 2. If Engineer concludes that a change in the Contract Documents is required, a Work Change Directive or a Change Order will be issued to reflect and document such consequences. An equitable adjustment shall be made in the Contract Price or Contract Times, or both, to the extent that they are attributable to the existence or location of any Underground Facility that was not shown or indicated or not shown or indicated with reasonable accuracy in the Contract Documents and that Contractor did not know of and could not reasonably have been expected to be aware of or to have anticipated. If Owner and Contractor are unable to agree on entitlement to or on the amount or extent, if any, of any such adjustment in Contract Price or Contract Times, Owner or Contractor may make a Claim therefor as provided in Paragraph 10.05. 4.05 Reference Points A. Owner shall provide engineering surveys to establish reference points for construction which in Engineer's judgment are necessary to enable Contractor to proceed with the Work. Contractor shall be responsible for laying out the Work, shall protect and preserve the established reference points and property monuments, and shall make no changes or relocations without the prior written approval of Owner. Contractor shall report to Engineer whenever any reference point or property monument is lost or destroyed or requires relocation because of necessary changes in grades or locations, and shall be responsible for the accurate replacement or relocation of such reference points or property monuments by professionally qualified personnel. 4.06 Hazardous Environmental Condition at Site A. Reports and Drawings: The Supplementary Conditions identify those reports and drawings known to Owner relating to Hazardous Environmental Conditions that have been identified at the Site. B. Limited Reliance by Contractor on Technical Data Authorized: Contractor may rely upon the accuracy of the "technical data" contained in such reports and drawings, but such reports and drawings are not Contract Documents. Such "technical data" is identified in the Supplementary Conditions. Except for such reliance on such "technical data," Contractor may not rely upon or make any claim against Owner or Engineer, or any of their officers, directors, members, partners, employees, agents, consultants, or subcontractors with respect to: 1. the completeness of such reports and drawings for Contractor's purposes, including, but not limited to, any aspects of the means, methods, techniques, sequences and procedures of construction to be employed by Contractor and safety precautions and programs incident thereto; or 2. other data, interpretations, opinions and information contained in such reports or shown or indicated in such drawings; or any Contractor interpretation of or conclusion drawn from any "technical data" or any such other data, interpretations, opinions or information. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCM. AO rights reserved. Pace 14 of 62 C. Contractor shall not be responsible for any Hazardous Environmental Condition uncovered or revealed at the Site which was not shown or indicated in Drawings or Specifications or identified in the Contract Documents to be within the scope of the Work. Contractor shall be responsible for a Hazardous Environmental Condition created with any materials brought to the Site by Contractor, Subcontractors, Suppliers, or anyone else for whom Contractor is responsible. D. If Contractor encounters a Hazardous Environmental Condition or if Contractor or anyone for whom Contractor is responsible creates a Hazardous Environmental Condition, Contractor shall immediately: (i) secure or otherwise isolate such condition; (ii) stop all Work in connection with such condition and in any area affected thereby (except in an emergency as required by Paragraph 6.16.A); and (iii) notify Owner and Engineer (and promptly thereafter confirm such notice in writing). Owner shall promptly consult with Engineer concerning the necessity for Owner to retain a qualified expert to evaluate such condition or take corrective action, if any. Promptly after consulting with Engineer, Owner shall take such actions as are necessary to permit Owner to timely obtain required permits and provide Contractor the written notice required by Paragraph 4.06.E. E. Contractor shall not be required to resume Work in connection with such condition or in any affected area until after Owner has obtained any required permits related thereto and delivered written notice to Contractor: (i) specifying that such condition and any affected area is or has been rendered safe for the resumption of Work; or (ii) specifying any special conditions under which such Work may be resumed safely. If Owner and Contractor cannot agree as to entitlement to or on the amount or extent, if any, of any adjustment in Contract Price or Contract Times, or both, as a result of such Work stoppage or such special conditions under which Work is agreed to be resumed by Contractor, either party may make a Claim therefor as provided in Paragraph 10.05. F. If after receipt of such written notice Contractor does not agree to resume such Work based on a reasonable belief it is unsafe, or does not agree to resume such Work under such special conditions, then Owner may order the portion of the Work that is in the area affected by such condition to be deleted from the Work. If Owner and Contractor cannot agree as to entitlement to or on the amount or extent, if any, of an adjustment in Contract Price or Contract Times as a result of deleting such portion of the Work, then either party may make a Claim therefor as provided in Paragraph 10.05. Owner may have such deleted portion of the Work performed by Owner's own forces or others in accordance with Article 7. G. To the fullest extent permitted by Laws and Regulations, Owner shall indemnify and hold harmless Contractor, Subcontractors, and Engineer, and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to a Hazardous Environmental Condition, provided that such Hazardous Environmental Condition: (i) was not shown or indicated in the Drawings or Specifications or identified in the Contract Documents to be included within the scope of the Work, and (ii) was not created by Contractor or by anyone for whom Contractor is responsible. Nothing in this Paragraph 4.06.13 shall obligate Owner to indemnify any individual or entity from and against the consequences of that individual's or entity's own negligence. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. H. To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless Owner and Engineer, and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to a Hazardous Environmental Condition created by Contractor or by anyone for whom Contractor is responsible. Nothing in this Paragraph 4.06.11 shall obligate Contractor to indemnify any individual or entity from and against the consequences of that individual's or entity's own negligence. I. The provisions of Paragraphs 4.02, 4.03, and 4.04 do not apply to a Hazardous Environmental Condition uncovered or revealed at the Site. ARTICLE 5 — BONDS AND INSURANCE 5.01 Performance, Payment, and Other Bonds A. Contractor shall furnish performance and payment bonds, each in an amount at least equal to the Contract Price as security for the faithful performance and payment of all of Contractor's obligations under the Contract Documents. These bonds shall remain in effect until one year after the date when final payment becomes due or until completion of the correction period specified in Paragraph 13.07, whichever is later, except as provided otherwise by Laws or Regulations or by the Contract Documents. Contractor shall also furnish such other bonds as are required by the Contract Documents. B. All bonds shall be in the form prescribed by the Contract Documents except as provided otherwise by Laws or Regulations, and shall be executed by such sureties as are named in the list of "Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsuring Companies" as published in Circular 570 (amended) by the Financial Management Service, Surety Bond Branch, U.S. Department of the Treasury. All bonds signed by an agent or attorney-in-fact must be accompanied by a certified copy of that individual's authority to bind the surety. The evidence of authority shall show that it is effective on the date the agent or attorney-in-fact signed each bond. C. If the surety on any bond furnished by Contractor is declared bankrupt or becomes insolvent or its right to do business is terminated in any state where any part of the Project is located or it ceases to meet the requirements of Paragraph 5.013, Contractor shall promptly notify Owner and Engineer and shall, within 20 days after the event giving rise to such notification, provide another bond and surety, both of which shall comply with the requirements of Paragraphs 5.01.E and 5.02. 5.02 Licensed Sureties and Insurers A. All bonds and insurance required by the Contract Documents to be purchased and maintained by Owner or Contractor shall be obtained from surety or insurance companies that are duly licensed or authorized in the jurisdiction in which the Project is located to issue bonds or insurance policies for the limits and coverages so required. Such surety and insurance companies shall also EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. Ali rights reserved. Page 16 of 62 meet such additional requirements and qualifications as may be provided in the Supplementary Conditions. 5.03 Certificates of Insurance A. Contractor shall deliver to Owner, with copies to each additional insured and loss payee identified in the Supplementary Conditions, certificates of insurance (and other evidence of insurance requested by Owner or any other additional insured) which Contractor is required to purchase and maintain. B. Owner shall deliver to Contractor, with copies to each additional insured and loss payee identified in the Supplementary Conditions, certificates of insurance (and other evidence of insurance requested by Contractor or any other additional insured) which Owner is required to purchase and maintain. C. Failure of Owner to demand such certificates or other evidence of Contractor's full compliance with these insurance requirements or failure of Owner to identify a deficiency in compliance from the evidence provided shall not be construed as a waiver of Contractor's obligation to maintain such insurance. D. Owner does not represent that insurance coverage and limits established in this Contract necessarily will be adequate to protect Contractor. E. The insurance and insurance limits required herein shall not be deemed as a limitation on Contractor's liability under the indemnities granted to Owner in the Contract Documents. 5.04 Contractor's Insurance A. Contractor shall purchase and maintain such insurance as is appropriate for the Work being performed and as will provide protection from claims set forth below which may arise out of or result from Contractor's performance of the Work and Contractor's other obligations under the Contract Documents, whether it is to be performed by Contractor, any Subcontractor or Supplier, or by anyone directly or indirectly employed by any of them to perform any of the Work, or by anyone for whose acts any of them may be liable: 1. claims under workers' compensation, disability benefits, and other similar employee benefit acts; 2. claims for damages because of bodily injury, occupational sickness or disease, or death of Contractor's employees; 3. claims for damages because of bodily injury, sickness or disease, or death of any person other than Contractor's employees; 4. claims for damages insured by reasonably available personal injury liability coverage which are sustained: EJCDC C-700 Standard General Conditions of the Construction Contract Copyright 0 2007 National Society of professional Engineers for EJCDC. All rights reserved. a. by any person as a result of an offense directly or indirectly related to the employment of such person by Contractor, or b. by any other person for any other reason; 5. claims for damages, other than to the Work itself, because of injury to or destruction of tangible property wherever located, including loss of use resulting therefrom; and 6. claims for damages because of bodily injury or death of any person or property damage arising out of the ownership, maintenance or use of any motor vehicle. B. The policies of insurance required by this Paragraph 5.04 shall: I. with respect to insurance required by Paragraphs 5.04.A.3 through 5.04.A.6 inclusive, be written on an occurrence basis, include as additional insureds (subject to any customary exclusion regarding professional liability) Owner and Engineer, and any other individuals or entities identified in the Supplementary Conditions, all of whom shall be listed as additional insureds, and include coverage for the respective officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of all such additional insureds, and the insurance afforded to these additional insureds shall provide primary coverage for all claims covered thereby; 2. include at least the specific coverages and be written for not less than the limits of liability provided in the Supplementary Conditions or required by Laws or Regulations, whichever is greater; 3. include contractual liability insurance covering Contractor's indemnity obligations under Paragraphs 6.11 and 6.20; 4. contain a provision or endorsement that the coverage afforded will not be canceled, materially changed or renewal refused until at least 30 days prior written notice has been given to Owner and Contractor and to each other additional insured identified in the Supplementary Conditions to whom a certificate of insurance has been issued (and the certificates of insurance furnished by the Contractor pursuant to Paragraph 5.03 will so provide); 5. remain in effect at least until final payment and at all times thereafter when Contractor may be correcting, removing, or replacing defective Work in accordance with Paragraph 13.07; and 6. include completed operations coverage: a. Such insurance shall remain in effect for two years after final payment. b. Contractor shall furnish Owner and each other additional insured identified in the Supplementary Conditions, to whom a certificate of insurance has been issued, evidence satisfactory to Owner and any such additional insured of continuation of such insurance at final payment and one year thereafter. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 18 of 62 5.05 Owner's Liability Insurance A. In addition to the insurance required to be provided by Contractor under Paragraph 5.04, Owner, at Owner's option, may purchase and maintain at Owner's expense Owner's own liability insurance as will protect Owner against claims which may arise from operations under the Contract Documents. 5.06 Property Insurance A. Unless otherwise provided in the Supplementary Conditions, Owner shall purchase and maintain property insurance upon the Work at the Site in the amount of the full replacement cost thereof (subject to such deductible amounts as may be provided in the Supplementary Conditions or required by Laws and Regulations). This insurance shall: 1. include the interests of Owner, Contractor, Subcontractors, and Engineer, and any other individuals or entities identified in the Supplementary Conditions, and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them, each of whom is deemed to have an insurable interest and shall be listed as a loss payee; 2. be written on a Builder's Risk "all-risk" policy form that shall at least include insurance for physical loss or damage to the Work, temporary buildings, falsework, and materials and equipment in transit, and shall insure against at least the following perils or causes of loss: fire, lightning, extended coverage, theft, vandalism and malicious mischief, earthquake, collapse, debris removal, demolition occasioned by enforcement of Laws and Regulations, water damage (other than that caused by flood), and such other perils or causes of loss as may be specifically required by the Supplementary Conditions. 3. include expenses incurred in the repair or replacement of any insured property (including but not limited to fees and charges of engineers and architects); 4. cover materials and equipment stored at the Site or at another location that was agreed to in writing by Owner prior to being incorporated in the Work, provided that such materials and equipment have been included in an Application for Payment recommended by Engineer; 5. allow for partial utilization of the Work by Owner; 6. include testing and startup; and 7. be maintained in effect until final payment is made unless otherwise agreed to in writing by Owner, Contractor, and Engineer with 30 days written notice to each other loss payee to whom a certificate of insurance has been issued. B. Owner shall purchase and maintain such equipment breakdown insurance or additional property insurance as may be required by the Supplementary Conditions or Laws and Regulations which will include the interests of Owner, Contractor, Subcontractors, and Engineer, and any other individuals or entities identified in the Supplementary Conditions, and the officers, directors, EJCDC C-710 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of professional Engineers for EJCDC. An rights reserved. Page 19 of 62 members, partners, employees, agents, consultants and subcontractors of each and any of them, each of whom is deemed to have an insurable interest and shall be listed as a loss payee. C. All the policies of insurance (and the certificates or other evidence thereof) required to be purchased and maintained in accordance with this Paragraph 5.06 will contain a provision or endorsement that the coverage afforded will not be canceled or materially changed or renewal refused until at least 30 days prior written notice has been given to Owner and Contractor and to each other loss payee to whom a certificate of insurance has been issued and will contain waiver provisions in accordance with Paragraph 5.07. D. Owner shall not be responsible for purchasing and maintaining any property insurance specified in this Paragraph 5.06 to protect the interests of Contractor, Subcontractors, or others in the Work to the extent of any deductible amounts that are identified in the Supplementary Conditions. The risk of loss within such identified deductible amount will be borne by Contractor, Subcontractors, or others suffering any such loss, and if any of them wishes property insurance coverage within the limits of such amounts, each may purchase and maintain it at the purchaser's own expense. E. If Contractor requests in writing that other special insurance be included in the property insurance policies provided under this Paragraph 5.06, Owner shall, if possible, include such insurance, and the cost thereof will be charged to Contractor by appropriate Change Order. Prior to commencement of the Work at the Site, Owner shall in writing advise Contractor whether or not such other insurance has been procured by Owner. 5.07 WaiverofRtghts A. Owner and Contractor intend that all policies purchased in accordance with Paragraph 5.06 will protect Owner, Contractor, Subcontractors, and Engineer, and all other individuals or entities identified in the Supplementary Conditions as loss payees (and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them) in such policies and will provide primary coverage for all losses and damages caused by the perils or causes of loss covered thereby. All such policies shall contain provisions to the effect that in the event of payment of any loss or damage the insurers will have no rights of recovery against any of the insureds or loss payees thereunder. Owner and Contractor waive all rights against each other and their respective officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them for all losses and damages caused by, arising out of or resulting from any of the perils or causes of loss covered by such policies and any other property insurance applicable to the Work; and, in addition, waive all such rights against Subcontractors and Engineer, and all other individuals or entities identified in the Supplementary Conditions as loss payees (and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them) under such policies for losses and damages so caused. None of the above waivers shall extend to the rights that any party making such waiver may have to the proceeds of insurance held by Owner as trustee or otherwise payable under any policy so issued. B. Owner waives all rights against Contractor, Subcontractors, and Engineer, and the officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them for: EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. Aa rights reserved. Pace 20 of 62 1. loss due to business interruption, loss of use, or other consequential loss extending beyond direct physical loss or damage to Owner's property or the Work caused by, arising out of, or resulting from fire or other perils whether or not insured by Owner; and 2. loss or damage to the completed Project or part thereof caused by, arising out of, or resulting from fire or other insured peril or cause of loss covered by any property insurance maintained on the completed Project or part thereof by Owner during partial utilization pursuant to Paragraph 14.05, after Substantial Completion pursuant to Paragraph 14.04, or after final payment pursuant to Paragraph 14.07. C. Any insurance policy maintained by Owner covering any loss, damage or consequential loss referred to in Paragraph 5.07.B shall contain provisions to the effect that in the event of payment of any such loss, damage, or consequential loss, the insurers will have no rights of recovery against Contractor, Subcontractors, or Engineer, and the officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them. 5.08 Receipt and Application oflnsurance Proceeds A. Any insured loss under the policies of insurance required by Paragraph 5.06 will be adjusted with Owner and made payable to Owner as fiduciary for the loss payees, as their interests may appear, subject to the requirements of any applicable mortgage clause and of Paragraph 5.08.B. Owner shall deposit in a separate account any money so received and shall distribute it in accordance with such agreement as the parties in interest may reach. If no other special agreement is reached, the damaged Work shall be repaired or replaced, the moneys so received applied on account thereof, and the Work and the cost thereof covered by an appropriate Change Order. B. Owner as fiduciary shall have power to adjust and settle any loss with the insurers unless one of the parties in interest shall object in writing within 15 days after the occurrence of loss to Owner's exercise of this power. If such objection be made, Owner as fiduciary shall make settlement with the insurers in accordance with such agreement as the parties in interest may reach. If no such agreement among the parties in interest is reached, Owner as fiduciary shall adjust and settle the loss with the insurers and, if required in writing by any party in interest, Owner as fiduciary shall give bond for the proper performance of such duties. 5.09 Acceptance of Bonds and Insurance; Option to Replace A. If either Owner or Contractor has any objection to the coverage afforded by or other provisions of the bonds or insurance required to be purchased and maintained by the other party in accordance with Article 5 on the basis of non-conformance with the Contract Documents, the objecting party shall so notify the other party in writing within 10 days after receipt of the certificates (or other evidence requested) required by Paragraph 2.01.B. Owner and Contractor shall each provide to the other such additional information in respect of insurance provided as the other may reasonably request. If either party does not purchase or maintain all of the bonds and insurance required of such party by the Contract Documents, such party shall notify the other party in writing of such failure to purchase prior to the start of the Work, or of such failure to maintain prior to any change in the required coverage. Without prejudice to any other right or remedy, the other parry may elect to obtain equivalent bonds or insurance to protect such other party's EJCDC C-700 Standard General Conditions of the Construction Contract Copyright 0 2001 National Society of Professional Engineers for EJCDC. All rights reserved. interests at the expense of the party who was required to provide such coverage, and a Change Order shall be issued to adjust the Contract Price accordingly. 5.10 Partial Utilization, Acknowledgment of Property Insurer A. If Owner finds it necessary to occupy or use a portion or portions of the Work prior to Substantial Completion of all the Work as provided in Paragraph 14.05, no such use or occupancy shall commence before the insurers providing the property insurance pursuant to Paragraph 5.06 have acknowledged notice thereof and in writing effected any changes in coverage necessitated thereby. The insurers providing the property insurance shall consent by endorsement on the policy or policies, but the property insurance shall not be canceled or permitted to lapse on account of any such partial use or occupancy. ARTICLE 6 — CONTRACTOR'S RESPONSIBILITIES 6.01 Supervision and Superintendence A. Contractor shall supervise, inspect, and direct the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with the Contract Documents. Contractor shall be solely responsible for the means, methods, techniques, sequences, and procedures of construction. Contractor shall not be responsible for the negligence of Owner or Engineer in the design or specification of a specific means, method, technique, sequence, or procedure of construction which is shown or indicated in and expressly required by the Contract Documents. B. At all times during the progress of the Work, Contractor shall assign a competent resident superintendent who shall not be replaced without written notice to Owner and Engineer except under extraordinary circumstances. 6.02 Labor; Working Hours A. Contractor shall provide competent, suitably qualified personnel to survey and lay out the Work and perform construction as required by the Contract Documents. Contractor shall at all times maintain good discipline and order at the Site. B. Except as otherwise required for the safety or protection of persons or the Work or property at the Site or adjacent thereto, and except as otherwise stated in the Contract Documents, all Work at the Site shall be performed during regular working hours. Contractor will not permit the performance of Work on a Saturday, Sunday, or any legal holiday without Owner's written consent (which will not be unreasonably withheld) given after prior written notice to Engineer. 6.03 Services, Materials, and Equipment A. Unless otherwise specified in the Contract Documents, Contractor shall provide and assume full responsibility for all services, materials, equipment, labor, transportation, construction equipment and machinery, tools, appliances, fuel, power, light, heat, telephone, water, sanitary facilities, temporary facilities, and all other facilities and incidentals necessary for the performance, testing, start-up, and completion of the Work. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. AE rights reserved. Paae 22 of 62 B. All materials and equipment incorporated into the Work shall be as specified or, if not specified, shall be of good quality and new, except as otherwise provided in the Contract Documents. All special warranties and guarantees required by the Specifications shall expressly run to the benefit of Owner. If required by Engineer, Contractor shall furnish satisfactory evidence (including reports of required tests) as to the source, kind, and quality of materials and equipment. C. All materials and equipment shall be stored, applied, installed, connected, erected, protected, used, cleaned, and conditioned in accordance with instructions of the applicable Supplier, except as otherwise may be provided in the Contract Documents. 6.04 Progress Schedule A. Contractor shall adhere to the Progress Schedule established in accordance with Paragraph 2.07 as it may be adjusted from time to time as provided below. 1. Contractor shall submit to Engineer for acceptance (to the extent indicated in Paragraph 2.07) proposed adjustments in the Progress Schedule that will not result in changing the Contract Times. Such adjustments will comply with any provisions of the General Requirements applicable thereto. 2. Proposed adjustments in the Progress Schedule that will change the Contract Times shall be submitted in accordance with the requirements of Article 12. Adjustments in Contract Times may only be made by a Change Order. 6.05 Substitutes and "Or -Equals" A. Whenever an item of material or equipment is specified or described in the Contract Documents by using the name of a proprietary item or the name of a particular Supplier, the specification or description is intended to establish the type, function, appearance, and quality required. Unless the specification or description contains or is followed by words reading that no like, equivalent, or "or -equal" item or no substitution is permitted, other items of material or equipment or material or equipment of other Suppliers may be submitted to Engineer for review under the circumstances described below. 1. "Or -Equal " Items: If in Engineer's sole discretion an item of material or equipment proposed by Contractor is functionally equal to that named and sufficiently similar so that no change in related Work will be required, it may be considered by Engineer as an "or -equal" item, in which case review and approval of the proposed item may, in Engineer's sole discretion, be accomplished without compliance with some or all of the requirements for approval of proposed substitute items. For the purposes of this Paragraph 6.05.A.1, a proposed item of material or equipment will be considered functionally equal to an item so named if: a. in the exercise of reasonable judgment Engineer determines that: 1) it is at least equal in materials of construction, quality, durability, appearance, strength, and design characteristics; EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. An rights reserved. Page 23 of 62 2) it will reliably perform at least equally well the function and achieve the results imposed by the design concept of the completed Project as a functioning whole; and 3) it has a proven record of performance and availability of responsive service. b. Contractor certifies that, if approved and incorporated into the Work: 1) there will be no increase in cost to the Owner or increase in Contract Times; and 2) it will conform substantially to the detailed requirements of the item named in the Contract Documents. 2. Substitute Items: a. If in Engineer's sole discretion an item of material or equipment proposed by Contractor does not qualify as an `or -equal" item under Paragraph 6.05.A.1, it will be considered a proposed substitute item. b. Contractor shall submit sufficient information as provided below to allow Engineer to determine if the item of material or equipment proposed is essentially equivalent to that named and an acceptable substitute therefor. Requests for review of proposed substitute items of material or equipment will not be accepted by Engineer from anyone other than Contractor. c. The requirements for review by Engineer will be as set forth in Paragraph 6.05.A.2.d, as supplemented by the General Requirements, and as Engineer may decide is appropriate under the circumstances. d. Contractor shall make written application to Engineer for review of a proposed substitute item of material or equipment that Contractor seeks to furnish or use. The application: 1) shall certify that the proposed substitute item will: a) perform adequately the functions and achieve the results called for by the general design, b) be similar in substance to that specified, and c) be suited to the same use as that specified; 2) will state: a) the extent, if any, to which the use of the proposed substitute item will prejudice Contractor's achievement of Substantial Completion on time, b) whether use of the proposed substitute item in the Work will require a change in any of the Contract Documents (or in the provisions of any other direct contract with Owner for other work on the Project) to adapt the design to the proposed substitute item, and EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National society of Professional Engineers for EJCDC. All rights reserved. Page 24 of 62 c) whether incorporation or use of the proposed substitute item in connection with the Work is subject to payment of any license fee or royalty; 3) will identify: a) all variations of the proposed substitute item from that specified, and b) available engineering, sales, maintenance, repair, and replacement services; and 4) shall contain an itemized estimate of all costs or credits that will result directly or indirectly from use of such substitute item, including costs of redesign and claims of other contractors affected by any resulting change. B. Substitute Construction Methods or Procedures: If a specific means, method, technique, sequence, or procedure of construction is expressly required by the Contract Documents, Contractor may finnish or utilize a substitute means, method, technique, sequence, or procedure of construction approved by Engineer. Contractor shall submit sufficient information to allow Engineer, in Engineer's sole discretion, to determine that the substitute proposed is equivalent to that expressly called for by the Contract Documents. The requirements for review by Engineer will be similar to those provided in Paragraph 6.05.A.2. C. Engineer's Evaluation: Engineer will be allowed a reasonable time within which to evaluate each proposal or submittal made pursuant to Paragraphs 6.05.A and 6.05.13. Engineer may require Contractor to furnish additional data about the proposed substitute item. Engineer will be the sole judge of acceptability. No "or equal" or substitute will be ordered, installed or utilized until Engineer's review is complete, which will be evidenced by a Change Order in the case of a substitute and an approved Shop Drawing for an "or equal." Engineer will advise Contractor in writing of any negative determination. D. Special Guarantee: Owner may require Contractor to furnish at Contractor's expense a special performance guarantee or other surety with respect to any substitute. E. Engineer's Cost Reimbursement: Engineer will record Engineer's costs in evaluating a substitute proposed or submitted by Contractor pursuant to Paragraphs 6.05.A.2 and 6.05.13. Whether or not Engineer approves a substitute so proposed or submitted by Contractor, Contractor shall reimburse Owner for the reasonable charges of Engineer for evaluating each such proposed substitute. Contractor shall also reimburse Owner for the reasonable charges of Engineer for making changes in the Contract Documents (or in the provisions of any other direct contract with Owner) resulting from the acceptance of each proposed substitute. F. Contractor's Expense: Contractor shall provide all data in support of any proposed substitute or "or -equal" at Contractor's expense. 6.06 Concerning Subcontractors, Suppliers, and Others A. Contractor shall not employ any Subcontractor, Supplier, or other individual or entity (including those acceptable to Owner as indicated in Paragraph 6.06.13), whether initially or as a replacement, against whom Owner may have reasonable objection. Contractor shall not be EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. AE rights reserved. required to employ any Subcontractor, Supplier, or other individual or entity to furnish or perform any of the Work against whom Contractor has reasonable objection. B. If the Supplementary Conditions require the identity of certain Subcontractors, Suppliers, or other individuals or entities to be submitted to Owner in advance for acceptance by Owner by a specified date prior to the Effective Date of the Agreement, and if Contractor has submitted a list thereof in accordance with the Supplementary Conditions, Owner's acceptance (either in writing or by failing to make written objection thereto by the date indicated for acceptance or objection in the Bidding Documents or the Contract Documents) of any such Subcontractor, Supplier, or other individual or entity so identified may be revoked on the basis of reasonable objection after due investigation. Contractor shall submit an acceptable replacement for the rejected Subcontractor, Supplier, or other individual or entity, and the Contract Price will be adjusted by the difference in the cost occasioned by such replacement, and an appropriate Change Order will be issued. No acceptance by Owner of any such Subcontractor, Supplier, or other individual or entity, whether initially or as a replacement, shall constitute a waiver of any right of Owner or Engineer to reject defective Work. C. Contractor shall be fully responsible to Owner and Engineer for all acts and omissions of the Subcontractors, Suppliers, and other individuals or entities performing or furnishing any of the Work just as Contractor is responsible for Contractor's own acts and omissions. Nothing in the Contract Documents: 1. shall create for the benefit of any such Subcontractor, Supplier, or other individual or entity any contractual relationship between Owner or Engineer and any such Subcontractor, Supplier or other individual or entity; nor 2. shall create any obligation on the part of Owner or Engineer to pay or to see to the payment of any moneys due any such Subcontractor, Supplier, or other individual or entity except as may otherwise be required by Laws and Regulations. D. Contractor shall be solely responsible for scheduling and coordinating the Work of Subcontractors, Suppliers, and other individuals or entities performing or furnishing any of the Work under a direct or indirect contract with Contractor. E. Contractor shall require all Subcontractors, Suppliers, and such other individuals or entities performing or furnishing any of the Work to communicate with Engineer through Contractor. F. The divisions and sections of the Specifications and the identifications of any Drawings shall not control Contractor in dividing the Work among Subcontractors or Suppliers or delineating the Work to be performed by any specific trade. G. All Work performed for Contractor by a Subcontractor or Supplier will be pursuant to an appropriate agreement between Contractor and the Subcontractor or Supplier which specifically binds the Subcontractor or Supplier to the applicable terms and conditions of the Contract Documents for the benefit of Owner and Engineer. Whenever any such agreement is with a Subcontractor or Supplier who is listed as a loss payee on the property insurance provided in Paragraph 5.06, the agreement between the Contractor and the Subcontractor or Supplier will contain provisions whereby the Subcontractor or Supplier waives all rights against Owner, EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Pace 26 of 62 Contractor, Engineer, and all other individuals or entities identified in the Supplementary Conditions to be listed as insureds or loss payees (and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them) for all losses and damages caused by, arising out of, relating to, or resulting from any of the perils or causes of loss covered by such policies and any other property insurance applicable to the Work. If the insurers on any such policies require separate waiver forms to be signed by any Subcontractor or Supplier, Contractor will obtain the same. 6.07 Patent Fees and Royalties A. Contractor shall pay all license fees and royalties and assume all costs incident to the use in the performance of the Work or the incorporation in the Work of any invention, design, process, product, or device which is the subject of patent rights or copyrights held by others. If a particular invention, design, process, product, or device is specified in the Contract Documents for use in the performance of the Work and if, to the actual knowledge of Owner or Engineer, its use is subject to patent rights or copyrights calling for the payment of any license fee or royalty to others, the existence of such rights shall be disclosed by Owner in the Contract Documents. B. To the fullest extent permitted by Laws and Regulations, Owner shall indemnify and hold harmless Contractor, and its officers, directors, members, partners, employees, agents, consultants, and subcontractors from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals, and all court or arbitration or other dispute resolution costs) arising out of or relating to any infringement of patent rights or copyrights incident to the use in the performance of the Work or resulting from the incorporation in the Work of any invention, design, process, product, or device specified in the Contract Documents, but not identified as being subject to payment of any license fee or royalty to others required by patent rights or copyrights. C. To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless Owner and Engineer, and the officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to any infringement of patent rights or copyrights incident to the use in the performance of the Work or resulting from the incorporation in the Work of any invention, design, process, product, or device not specified in the Contract Documents. 6.08 Permits A. Unless otherwise provided in the Supplementary Conditions, Contractor shall obtain and pay for all construction permits and licenses. Owner shall assist Contractor, when necessary, in obtaining such permits and licenses. Contractor shall pay all governmental charges and inspection fees necessary for the prosecution of the Work which are applicable at the time of opening of Bids, or, if there are no Bids, on the Effective Date of the Agreement. Owner shall pay all charges of utility owners for connections for providing permanent service to the Work. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright® 2007 National Society of Professional Engineers for EJCDC. AR rights reserved. Pace 27 of 62 6.09 Laws and Regulations A. Contractor shall give all notices required by and shall comply with all Laws and Regulations applicable to the performance of the Work. Except where otherwise expressly required by applicable Laws and Regulations, neither Owner nor Engineer shall be responsible for monitoring Contractor's compliance with any Laws or Regulations. B. If Contractor performs any Work knowing or having reason to know that it is contrary to Laws or Regulations, Contractor shall bear all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such Work. However, it shall not be Contractor's responsibility to make certain that the Specifications and Drawings are in accordance with Laws and Regulations, but this shall not relieve Contractor of Contractor's obligations under Paragraph 3.03. C. Changes in Laws or Regulations not known at the time of opening of Bids (or, on the Effective Date of the Agreement if there were no Bids) having an effect on the cost or time of performance of the Work shall be the subject of an adjustment in Contract Price or Contract Times. If Owner and Contractor are unable to agree on entitlement to or on the amount or extent, if any, of any such adjustment, a Claim may be made therefor as provided in Paragraph 10.05. 6.10 Taxes A. Contractor shall pay all sales, consumer, use, and other similar taxes required to be paid by Contractor in accordance with the Laws and Regulations of the place of the Project which are applicable during the performance of the Work. 6.11 Use of Site and Other Areas A. Limitation on Use of Site and Other Areas: 1. Contractor shall confine construction equipment, the storage of materials and equipment, and the operations of workers to the Site and other areas permitted by Laws and Regulations, and shall not unreasonably encumber the Site and other areas with construction equipment or other materials or equipment. Contractor shall assume full responsibility for any damage to any such land or area, or to the owner or occupant thereof, or of any adjacent land or areas resulting from the performance of the Work. 2. Should any claim be made by any such owner or occupant because of the performance of the Work, Contractor shall promptly settle with such other party by negotiation or otherwise resolve the claim by arbitration or other dispute resolution proceeding or at law. 3. To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless Owner and Engineer, and the officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to any claim or action, legal or equitable, brought EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Pace 28 of 62 by any such owner or occupant against Owner, Engineer, or any other party indemnified hereunder to the extent caused by or based upon Contractor's performance of the Work. B. Removal of Debris During Performance of the Work. During the progress of the Work Contractor shall keep the Site and other areas free from accumulations of waste materials, rubbish, and other debris. Removal and disposal of such waste materials, rubbish, and other debris shall conform to applicable Laws and Regulations. C. Cleaning: Prior to Substantial Completion of the Work Contractor shall clean the Site and the Work and make it ready for utilization by Owner. At the completion of the Work Contractor shall remove from the Site all tools, appliances, construction equipment and machinery, and surplus materials and shall restore to original condition all property not designated for alteration by the Contract Documents. D. Loading Structures: Contractor shall not load nor permit any part of any structure to be loaded in any manner that will endanger the structure, nor shall Contractor subject any part of the Work or adjacent property to stresses or pressures that will endanger it. 6.12 Record Documents A. Contractor shall maintain in a safe place at the Site one record copy of all Drawings, Specifications, Addenda, Change Orders, Work Change Directives, Field Orders, and written interpretations and clarifications in good order and annotated to show changes made during construction. These record documents together with all approved Samples and a counterpart of all approved Shop Drawings will be available to Engineer for reference. Upon completion of the Work, these record documents, Samples, and Shop Drawings will be delivered to Engineer for Owner. 6.13 Safety and Protection A. Contractor shall be solely responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the Work. Such responsibility does not relieve Subcontractors of their responsibility for the safety of persons or property in the performance of their work, nor for compliance with applicable safety Laws and Regulations. Contractor shall take all necessary precautions for the safety of, and shall provide the necessary protection to prevent damage, injury or loss to: 1. all persons on the Site or who may be affected by the Work; 2. all the Work and materials and equipment to be incorporated therein, whether in storage on or off the Site; and 3. other property at the Site or adjacent thereto, including trees, shrubs, lawns, walks, pavements, roadways, structures, utilities, and Underground Facilities not designated for removal, relocation, or replacement in the course of construction. B. Contractor shall comply with all applicable Laws and Regulations relating to the safety of persons or property, or to the protection of persons or property from damage, injury, or loss; and EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of professional Engineers for EJCDC. All rights reserved. Page 29 of 62 shall erect and maintain all necessary safeguards for such safety and protection. Contractor shall notify owners of adjacent property and of Underground Facilities and other utility owners when prosecution of the Work may affect them, and shall cooperate with them in the protection, removal, relocation, and replacement of their property. C. Contractor shall comply with the applicable requirements of Owner's safety programs, if any. The Supplementary Conditions identify any Owner's safety programs that are applicable to the Work. D. Contractor shall inform Owner and Engineer of the specific requirements of Contractor's safety program with which Owner's and Engineer's employees and representatives must comply while at the Site. E. All damage, injury, or loss to any property referred to in Paragraph 6.13.A.2 or 6.13.A.3 caused, directly or indirectly, in whole or in part, by Contractor, any Subcontractor, Supplier, or any other individual or entity directly or indirectly employed by any of them to perform any of the Work, or anyone for whose acts any of them may be liable, shall be remedied by Contractor (except damage or loss attributable to the fault of Drawings or Specifications or to the acts or omissions of Owner or Engineer or anyone employed by any of them, or anyone for whose acts any of them may be liable, and not attributable, directly or indirectly, in whole or in part, to the fault or negligence of Contractor or any Subcontractor, Supplier, or other individual or entity directly or indirectly employed by any of them). F. Contractor's duties and responsibilities for safety and for protection of the Work shall continue until such time as all the Work is completed and Engineer has issued a notice to Owner and Contractor in accordance with Paragraph 14.07.13 that the Work is acceptable (except as otherwise expressly provided in connection with Substantial Completion). 6.14 Safety Representative A. Contractor shall designate a qualified and experienced safety representative at the Site whose duties and responsibilities shall be the prevention of accidents and the maintaining and supervising of safety precautions and programs. 6.15 Hazard Communication Programs A. Contractor shall be responsible for coordinating any exchange of material safety data sheets or other hazard communication information required to be made available to or exchanged between or among employers at the Site in accordance with Laws or Regulations. 6.16 Emergencies A. In emergencies affecting the safety or protection of persons or the Work or property at the Site or adjacent thereto, Contractor is obligated to act to prevent threatened damage, injury, or loss. Contractor shall give Engineer prompt written notice if Contractor believes that any significant changes in the Work or variations from the Contract Documents have been caused thereby or are required as a result thereof. If Engineer determines that a change in the Contract Documents is EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 30 of 62 required because of the action taken by Contractor in response to such an emergency, a Work Change Directive or Change Order will be issued. 6.17 Shop Drawings and Samples A. Contractor shall submit Shop Drawings and Samples to Engineer for review and approval in accordance with the accepted Schedule of Submittals (as required by Paragraph 2.07). Each submittal will be identified as Engineer may require. 1. Shop Drawings: a. Submit number of copies specified in the General Requirements. b. Data shown on the Shop Drawings will be complete with respect to quantities, dimensions, specified performance and design criteria, materials, and similar data to show Engineer the services, materials, and equipment Contractor proposes to provide and to enable Engineer to review the information for the limited purposes required by Paragraph 6.17.D. 2. Samples: a. Submit number of Samples specified in the Specifications. b. Clearly identify each Sample as to material, Supplier, pertinent data such as catalog numbers, the use for which intended and other data as Engineer may require to enable Engineer to review the submittal for the limited purposes required by Paragraph 6.17.D. B. Where a Shop Drawing or Sample is required by the Contract Documents or the Schedule of Submittals, any related Work performed prior to Engineer's review and approval of the pertinent submittal will be at the sole expense and responsibility of Contractor. C. Submittal Procedures: 1. Before submitting each Shop Drawing or Sample, Contractor shall have: a. reviewed and coordinated each Shop Drawing or Sample with other Shop Drawings and Samples and with the requirements of the Work and the Contract Documents; b. determined and verified all field measurements, quantities, dimensions, specified performance and design criteria, installation requirements, materials, catalog numbers, and similar information with respect thereto; c. determined and verified the suitability of all materials offered with respect to the indicated application, fabrication, shipping, handling, storage, assembly, and installation pertaining to the performance of the Work; and d. determined and verified all information relative to Contractor's responsibilities for means, methods, techniques, sequences, and procedures of construction, and safety precautions and programs incident thereto. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 31 of 62 2. Each submittal shall bear a stamp or specific written certification that Contractor has satisfied Contractor's obligations under the Contract Documents with respect to Contractor's review and approval of that submittal. 3. With each submittal, Contractor shall give Engineer specific written notice of any variations that the Shop Drawing or Sample may have from the requirements of the Contract Documents. This notice shall be both a written communication separate from the Shop Drawings or Sample submittal; and, in addition, by a specific notation made on each Shop Drawing or Sample submitted to Engineer for review and approval of each such variation. D. Engineer's Review: 1. Engineer will provide timely review of Shop Drawings and Samples in accordance with the Schedule of Submittals acceptable to Engineer. Engineer's review and approval will be only to determine if the items covered by the submittals will, after installation or incorporation in the Work, conform to the information given in the Contract Documents and be compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. 2. Engineer's review and approval will not extend to means, methods, techniques, sequences, or procedures of construction (except where a particular means, method, technique, sequence, or procedure of construction is specifically and expressly called for by the Contract Documents) or to safety precautions or programs incident thereto. The review and approval of a separate item as such will not indicate approval of the assembly in which the item functions. 3. Engineer's review and approval shall not relieve Contractor from responsibility for any variation from the requirements of the Contract Documents unless Contractor has complied with the requirements of Paragraph 6.17.C.3 and Engineer has given written approval of each such variation by specific written notation thereof incorporated in or accompanying the Shop Drawing or Sample. Engineer's review and approval shall not relieve Contractor from responsibility for complying with the requirements of Paragraph 6.17.C.1. E. Resubmittal Procedures: 1. Contractor shall make corrections required by Engineer and shall return the required number of corrected copies of Shop Drawings and submit, as required, new Samples for review and approval. Contractor shall direct specific attention in writing to revisions other than the corrections called for by Engineer on previous submittals. 6.18 Continuing the Work A. Contractor shall carry on the Work and adhere to the Progress Schedule during all disputes or disagreements with Owner. No Work shall be delayed or postponed pending resolution of any disputes or disagreements, except as permitted by Paragraph 15.04 or as Owner and Contractor may otherwise agree in writing. ETCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Paae 32 of 62 6.19 Contractor's General Warranty and Guarantee A. Contractor warrants and guarantees to Owner that all Work will be in accordance with the Contract Documents and will not be defective. Engineer and its officers, directors, members, partners, employees, agents, consultants, and subcontractors shall be entitled to rely on representation of Contractor's warranty and guarantee. B. Contractor's warranty and guarantee hereunder excludes defects or damage caused by: 1. abuse, modification, or improper maintenance or operation by persons other than Contractor, Subcontractors, Suppliers, or any other individual or entity for whom Contractor is responsible; or 2. normal wear and tear under normal usage. C. Contractor's obligation to perform and complete the Work in accordance with the Contract Documents shall be absolute. None of the following will constitute an acceptance of Work that is not in accordance with the Contract Documents or a release of Contractor's obligation to perform the Work in accordance with the Contract Documents: 1. observations by Engineer, 2. recommendation by Engineer or payment by Owner of any progress or final payment; 3. the issuance of a certificate of Substantial Completion by Engineer or any payment related thereto by Owner; 4. use or occupancy of the Work or any part thereof by Owner; 5. any review and approval of a Shop Drawing or Sample submittal or the issuance of a notice of acceptability by Engineer; 6. any inspection, test, or approval by others; or 7. any correction of defective Work by Owner. 6.20 Indemnification A. To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless Owner and Engineer, and the officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to the performance of the Work, provided that any such claim, cost, loss, or damage is attributable to bodily injury, sickness, disease, or death, or to injury to or destruction of tangible property (other than the Work itself), including the loss of use resulting therefrom but only to the extent caused by any negligent act or omission of Contractor, any Subcontractor, any Supplier, or any individual or entity directly or indirectly employed by any of them to perform any of the Work or anyone for whose acts any of them maybe liable. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright C 2007 National Society of Professional Engineers for EJCDC. AO rights reserved. Page 33 of 62 B. In any and all claims against Owner or Engineer or any of their officers, directors, members, partners, employees, agents, consultants, or subcontractors by any employee (or the survivor or personal representative of such employee) of Contractor, any Subcontractor, any Supplier, or any individual or entity directly or indirectly employed by any of them to perform any of the Work, or anyone for whose acts any of them may be liable, the indemnification obligation under Paragraph 6.20.A shall not be limited in any way by any limitation on the amount or type of damages, compensation, or benefits payable by or for Contractor or any such Subcontractor, Supplier, or other individual or entity under workers' compensation acts, disability benefit acts, or other employee benefit acts. C. The indemnification obligations of Contractor under Paragraph 6.20.A shall not extend to the liability of Engineer and Engineer's officers, directors, members, partners, employees, agents, consultants and subcontractors arising out of: 1. the preparation or approval of, or the failure to prepare or approve maps, Drawings, opinions, reports, surveys, Change Orders, designs, or Specifications; or 2. giving directions or instructions, or failing to give them, if that is the primary cause of the injury or damage. 6.21 Delegation of Professional Design Services A. Contractor will not be required to provide professional design services unless such services are specifically required by the Contract Documents for a portion of the Work or unless such services are required to cavy out Contractor's responsibilities for construction means, methods, techniques, sequences and procedures. Contractor shall not be required to provide professional services in violation of applicable law. B. If professional design services or certifications by a design professional related to systems, materials or equipment are specifically required of Contractor by the Contract Documents, Owner and Engineer will specify all performance and design criteria that such services must satisfy. Contractor shall cause such services or certifications to be provided by a properly licensed professional, whose signature and seal shall appear on all drawings, calculations, specifications, certifications, Shop Drawings and other submittals prepared by such professional. Shop Drawings and other submittals related to the Work designed or certified by such professional, if prepared by others, shall bear such professional's written approval when submitted to Engineer. C. Owner and Engineer shall be entitled to rely upon the adequacy, accuracy and completeness of the services, certifications or approvals performed by such design professionals, provided Owner and Engineer have specified to Contractor all performance and design criteria that such services must satisfy. D. Pursuant to this Paragraph 6.21, Engineer's review and approval of design calculations and design drawings will be only for the limited purpose of checking for conformance with performance and design criteria given and the design concept expressed in the Contract Documents. Engineer's review and approval of Shop Drawings and other submittals (except design calculations and design drawings) will be only for the purpose stated in Paragraph 6.17.D.1. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Paee34 of 62 E. Contractor shall not be responsible for the adequacy of the performance or design criteria required by the Contract Documents. ARTICLE 7 — OTHER WORK AT THE SITE 7.01 Related Work at Site A. Owner may perform other work related to the Project at the Site with Owner's employees, or through other direct contracts therefor, or have other work performed by utility owners. If such other work is not noted in the Contract Documents, then: 1. written notice thereof will be given to Contractor prior to starting any such other work; and 2. if Owner and Contractor are unable to agree on entitlement to or on the amount or extent, if any, of any adjustment in the Contract Price or Contract Times that should be allowed as a result of such other work, a Claim may be made therefor as provided in Paragraph 10.05. B. Contractor shall afford each other contractor who is a party to such a direct contract, each utility owner, and Owner, if Owner is performing other work with Owner's employees, proper and safe access to the Site, provide a reasonable opportunity for the introduction and storage of materials and equipment and the execution of such other work, and properly coordinate the Work with theirs. Contractor shall do all cutting, fitting, and patching of the Work that may be required to properly connect or otherwise make its several parts come together and properly integrate with such other work. Contractor shall not endanger any work of others by cutting, excavating, or otherwise altering such work; provided, however, that Contractor may cut or alter others' work with the written consent of Engineer and the others whose work will be affected. The duties and responsibilities of Contractor under this Paragraph are for the benefit of such utility owners and other contractors to the extent that there are comparable provisions for the benefit of Contractor in said direct contracts between Owner and such utility owners and other contractors. C. If the proper execution or results of any part of Contractor's Work depends upon work performed by others under this Article 7, Contractor shall inspect such other work and promptly report to Engineer in writing any delays, defects, or deficiencies in such other work that render it unavailable or unsuitable for the proper execution and results of Contractor's Work. Contractor's failure to so report will constitute an acceptance of such other work as fit and proper for integration with Contractor's Work except for latent defects and deficiencies in such other work. 7.02 Coordination A. If Owner intends to contract with others for the performance of other work on the Project at the Site, the following will be set forth in Supplementary Conditions: the individual or entity who will have authority and responsibility for coordination of the activities among the various contractors will be identified; 2. the specific matters to be covered by such authority and responsibility will be itemized; and 3. the extent of such authority and responsibilities will be provided. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 35 of 62 B. Unless otherwise provided in the Supplementary Conditions, Owner shall have sole authority and responsibility for such coordination. 7.03 Legal Relationships A. Paragraphs 7.01.A and 7.02 are not applicable for utilities not under the control of Owner. B. Each other direct contract of Owner under Paragraph 7.01.A shall provide that the other contractor is liable to Owner and Contractor for the reasonable direct delay and disruption costs incurred by Contractor as a result of the other contractor's wrongful actions or inactions. C. Contractor shall be liable to Owner and any other contractor under direct contract to Owner for the reasonable direct delay and disruption costs incurred by such other contractor as a result of Contractor's wrongful action or inactions. ARTICLE 8 — OWNER'S RESPONSIBILITIES 8.01 Communications to Contractor A. Except as otherwise provided in these General Conditions, Owner shall issue all communications to Contractor through Engineer. 8.02 Replacement of Engineer A. In case of termination of the employment of Engineer, Owner shall appoint an engineer to whom Contractor makes no reasonable objection, whose status under the Contract Documents shall be that of the former Engineer. 8.03 Furnish Data A. Owner shall promptly furnish the data required of Owner under the Contract Documents. 8.04 Pay When Due A. Owner shall make payments to Contractor when they are due as provided in Paragraphs 14.02.0 and 14.07.C. 8.05 Lands and Easements; Reports and Tests A. Owner's duties with respect to providing lands and easements and providing engineering surveys to establish reference points are set forth in Paragraphs 4.01 and 4.05. Paragraph 4.02 refers to Owner's identifying and making available to Contractor copies of reports of explorations and tests of subsurface conditions and drawings of physical conditions relating to existing surface or subsurface structures at the Site. 8.06 Insurance A. Owner's responsibilities, if any, with respect to purchasing and maintaining liability and property insurance are set forth in Article 5. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright® 2007 National Society of Professional Engineers for EJCDC. Ali rights reserved. Page 36 of 62 8.07 Change Orders A. Owner is obligated to execute Change Orders as indicated in Paragraph 10.03. 8.08 Inspections, Tests, and Approvals A. Owner's responsibility with respect to certain inspections, tests, and approvals is set forth in Paragraph 13.03.B. 8.09 Limitations on Owner's Responsibilities A. The Owner shall not supervise, direct, or have control or authority over, nor be responsible for, Contractor's means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the performance of the Work. Owner will not be responsible for Contractor's failure to perform the Work in accordance with the Contract Documents. 8.10 Undisclosed Hazardous Environmental Condition A. Owner's responsibility in respect to an undisclosed Hazardous Environmental Condition is set forth in Paragraph 4.06. 8.11 Evidence of Financial Arrangements A. Upon request of Contractor, Owner shall furnish Contractor reasonable evidence that financial arrangements have been made to satisfy Owner's obligations under the Contract Documents. 8.12 Compliance with Safety Program A. While at the Site, Owner's employees and representatives shall comply with the specific applicable requirements of Contractor's safety programs of which Owner has been informed pursuant to Paragraph 6.13.D. ARTICLE 9 — ENGINEER'S STATUS DURING CONSTRUCTION 9.01 Owner's Representative A. Engineer will be Owner's representative during the construction period. The duties and responsibilities and the limitations of authority of Engineer as Owner's representative during construction are set forth in the Contract Documents. 9.02 Visits to Site A. Engineer will make visits to the Site at intervals appropriate to the various stages of construction as Engineer deems necessary in order to observe as an experienced and qualified design professional the progress that has been made and the quality of the various aspects of Contractor's executed Work. Based on information obtained during such visits and observations, Engineer, for the benefit of Owner, will determine, in general, if the Work is proceeding in accordance with the Contract Documents. Engineer will not be required to make exhaustive or EJCDC C-700 Standard General Conditions of the Constroctlon Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. Aa rights reserved. Page 37 of 62 continuous inspections on the Site to check the quality or quantity of the Work. Engineer's efforts will be directed toward providing for Owner a greater degree of confidence that the completed Work will conform generally to the Contract Documents. On the basis of such visits and observations, Engineer will keep Owner informed of the progress of the Work and will endeavor to guard Owner against defective Work. B. Engineer's visits and observations are subject to all the limitations on Engineer's authority and responsibility set forth in Paragraph 9.09. Particularly, but without limitation, during or as a result of Engineer's visits or observations of Contractor's Work, Engineer will not supervise, direct, control, or have authority over or be responsible for Contractor's means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the performance of the Work. 9.03 Project Representative A. If Owner and Engineer agree, Engineer will furnish a Resident Project Representative to assist Engineer in providing more extensive observation of the Work. The authority and responsibilities of any such Resident Project Representative and assistants will be as provided in the Supplementary Conditions, and limitations on the responsibilities thereof will be as provided in Paragraph 9.09. If Owner designates another representative or agent to represent Owner at the Site who is not Engineer's consultant, agent or employee, the responsibilities and authority and limitations thereon of such other individual or entity will be as provided in the Supplementary Conditions. 9.04 Authorized Variations in Work A. Engineer may authorize minor variations in the Work from the requirements of the Contract Documents which do not involve an adjustment in the Contract Price or the Contract Times and are compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. These may be accomplished by a Field Order and will be binding on Owner and also on Contractor, who shall perform the Work involved promptly. If Owner or Contractor believes that a Field Order justifies an adjustment in the Contract Price or Contract Times, or both, and the parties are unable to agree on entitlement to or on the amount or extent, if any, of any such adjustment, a Claim may be made therefor as provided in Paragraph 10.05. 9.05 Rejecting Defective Work A. Engineer will have authority to reject Work which Engineer believes to be defective, or that Engineer believes will not produce a completed Project that conforms to the Contract Documents or that will prejudice the integrity of the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. Engineer will also have authority to require special inspection or testing of the Work as provided in Paragraph 13.04, whether or not the Work is fabricated, installed, or completed. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright C 2007 National Society of Professional Engineers for EJCDC. AO rights reserved. Pate 38 of 62 9.06 Shop Drawings, Change Orders and Payments A. In connection with Engineer's authority, and limitations thereof, as to Shop Drawings and Samples, see Paragraph 6.17. B. In connection with Engineer's authority, and limitations thereof, as to design calculations and design drawings submitted in response to a delegation of professional design services, if any, see Paragraph 6.21. C. In connection with Engineer's authority as to Change Orders, see Articles 10, 11, and 12. D. In connection with Engineer's authority as to Applications for Payment, see Article 14. 9.07 Determinations for Unit Price Work A. Engineer will determine the actual quantities and classifications of Unit Price Work performed by Contractor. Engineer will review with Contractor the Engineer's preliminary determinations on such matters before rendering a written decision thereon (by recommendation of an Application for Payment or otherwise). Engineer's written decision thereon will be final and binding (except as modified by Engineer to reflect changed factual conditions or more accurate data) upon Owner and Contractor, subject to the provisions of Paragraph 10.05. 9.08 Decisions on Requirements of Contract Documents and Acceptability of Work A. Engineer will be the initial interpreter of the requirements of the Contract Documents and judge of the acceptability of the Work thereunder. All matters in question and other matters between Owner and Contractor arising prior to the date final payment is due relating to the acceptability of the Work, and the interpretation of the requirements of the Contract Documents pertaining to the performance of the Work, will be referred initially to Engineer in writing within 30 days of the event giving rise to the question. B. Engineer will, with reasonable promptness, render a written decision on the issue referred. If Owner or Contractor believes that any such decision entitles them to an adjustment in the Contract Price or Contract Times or both, a Claim may be made under Paragraph 10.05. The date of Engineer's decision shall be the date of the event giving rise to the issues referenced for the purposes of Paragraph 10.05.13. C. Engineer's written decision on the issue referred will be final and binding on Owner and Contractor, subject to the provisions of Paragraph 10.05. D. When functioning as interpreter and judge under this Paragraph 9.08, Engineer will not show partiality to Owner or Contractor and will not be liable in connection with any interpretation or decision rendered in good faith in such capacity. 9.09 Limitations on Engineer's Authority and Responsibilities A. Neither Engineer's authority or responsibility under this Article 9 or under any other provision of the Contract Documents nor any decision made by Engineer in good faith either to exercise or not EJCDC C-700 Standard General Conditions of the Construction Contract Copyright C 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 39 of 62 exercise such authority or responsibility or the undertaking, exercise, or performance of any authority or responsibility by Engineer shall create, impose, or give rise to any duty in contract, tort, or otherwise owed by Engineer to Contractor, any Subcontractor, any Supplier, any other individual or entity, or to any surety for or employee or agent of any of them. B. Engineer will not supervise, direct, control, or have authority over or be responsible for Contractor's means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the performance of the Work. Engineer will not be responsible for Contractor's failure to perform the Work in accordance with the Contract Documents. C. Engineer will not be responsible for the acts or omissions of Contractor or of any Subcontractor, any Supplier, or of any other individual or entity performing any of the Work. D. Engineer's review of the final Application for Payment and accompanying documentation and all maintenance and operating instructions, schedules, guarantees, bonds, certificates of inspection, tests and approvals, and other documentation required to be delivered by Paragraph 14.07.A will only be to determine generally that their content complies with the requirements of, and in the case of certificates of inspections, tests, and approvals that the results certified indicate compliance with, the Contract Documents. E. The limitations upon authority and responsibility set forth in this Paragraph 9.09 shall also apply to the Resident Project Representative, if any, and assistants, if any. 9.10 Compliance with Safety Program A. While at the Site, Engineer's employees and representatives shall comply with the specific applicable requirements of Contractor's safety programs of which Engineer has been informed pursuant to Paragraph 6.13.D. ARTICLE 10 — CHANGES IN THE WORK; CLAIMS 10.01 Authorized Changes in the Work A. Without invalidating the Contract and without notice to any surety, Owner may, at any time or from time to time, order additions, deletions, or revisions in the Work by a Change Order, or a Work Change Directive. Upon receipt of any such document, Contractor shall promptly proceed with the Work involved which will be performed under the applicable conditions of the Contract Documents (except as otherwise specifically provided). B. If Owner and Contractor are unable to agree on entitlement to, or on the amount or extent, if any, of an adjustment in the Contract Price or Contract Times, or both, that should be allowed as a result of a Work Change Directive, a Claim may be made therefor as provided in Paragraph 10.05. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. AO rights reserved. Page 40 of 62 10.02 Unauthorized Changes in the Work A. Contractor shall not be entitled to an increase in the Contract Price or an extension of the Contract Times with respect to any work performed that is not required by the Contract Documents as amended, modified, or supplemented as provided in Paragraph 3.04, except in the case of an emergency as provided in Paragraph 6.16 or in the case of uncovering Work as provided in Paragraph 13.04.D. 10.03 Execution of Change Orders A. Owner and Contractor shall execute appropriate Change Orders recommended by Engineer covering: 1. changes in the Work which are: (i) ordered by Owner pursuant to Paragraph 10.01.A, (ii) required because of acceptance of defective Work under Paragraph 13.08.A or Owner's correction of defective Work under Paragraph 13.09, or (iii) agreed to by the parties; 2. changes in the Contract Price or Contract Times which are agreed to by the parties, including any undisputed sum or amount of time for Work actually performed in accordance with a Work Change Directive; and 3. changes in the Contract Price or Contract Times which embody the substance of any written decision rendered by Engineer pursuant to Paragraph 10.05; provided that, in lieu of executing any such Change Order, an appeal may be taken from any such decision in accordance with the provisions of the Contract Documents and applicable Laws and Regulations, but during any such appeal, Contractor shall carry on the Work and adhere to the Progress Schedule as provided in Paragraph 6.18.A. 10.04 Notification to Surety A. If the provisions of any bond require notice to be given to a surety of any change affecting the general scope of the Work or the provisions of the Contract Documents (including, but not limited to, Contract Price or Contract Times), the giving of any such notice will be Contractor's responsibility. The amount of each applicable bond will be adjusted to reflect the effect of any such change. 10.05 Claims A. Engineer's Decision Required: All Claims, except those waived pursuant to Paragraph 14.09, shall be referred to the Engineer for decision. A decision by Engineer shall be required as a condition precedent to any exercise by Owner or Contractor of any rights or remedies either may otherwise have under the Contract Documents or by Laws and Regulations in respect of such Claims. B. Notice: Written notice staring the general nature of each Claim shall be delivered by the claimant to Engineer and the other party to the Contract promptly (but in no event later than 30 days) after the start of the event giving rise thereto. The responsibility to substantiate a Claim shall rest with the party making the Claim. Notice of the amount or extent of the Claim, with supporting data EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. Ali rights reserved. Page 41 of 62 shall be delivered to the Engineer and the other party to the Contract within 60 days after the start of such event (unless Engineer allows additional time for claimant to submit additional or more accurate data in support of such Claim). A Claim for an adjustment in Contract Price shall be prepared in accordance with the provisions of Paragraph 12.01.13. A Claim for an adjustment in Contract Times shall be prepared in accordance with the provisions of Paragraph 12.02.B. Each Claim shall be accompanied by claimant's written statement that the adjustment claimed is the entire adjustment to which the claimant believes it is entitled as a result of said event. The opposing party shall submit any response to Engineer and the claimant within 30 days after receipt of the claimant's last submittal (unless Engineer allows additional time). C. Engineer's Action: Engineer will review each Claim and, within 30 days after receipt of the last submittal of the claimant or the last submittal of the opposing party, if any, take one of the following actions in writing: 1. deny the Claim in whole or in part; 2. approve the Claim; or 3. notify the parties that the Engineer is unable to resolve the Claim if, in the Engineer's sole discretion, it would be inappropriate for the Engineer to do so. For purposes of further resolution of the Claim, such notice shall be deemed a denial. D. In the event that Engineer does not take action on a Claim within said 30 days, the Claim shall be deemed denied. E. Engineer's written action under Paragraph 10.05.0 or denial pursuant to Paragraphs 10.05.C.3 or 10.05.D will be final and binding upon Owner and Contractor, unless Owner or Contractor invoke the dispute resolution procedure set forth in Article 16 within 30 days of such action or denial. F. No Claim for an adjustment in Contract Price or Contract Times will be valid if not submitted in accordance with this Paragraph 10.05. ARTICLE 11— COST OF THE WORK; ALLOWANCES; UNIT PRICE WORK 11.01 Cost of the Work A. Costs Included: The term Cost of the Work means the sum of all costs, except those excluded in Paragraph 11.01.13, necessarily incurred and paid by Contractor in the proper performance of the Work. When the value of any Work covered by a Change Order or when a Claim for an adjustment in Contract Price is determined on the basis of Cost of the Work, the costs to be reimbursed to Contractor will be only those additional or incremental costs required because of the change in the Work or because of the event giving rise to the Claim. Except as otherwise may be agreed to in writing by Owner, such costs shall be in amounts no higher than those prevailing in the locality of the Project, shall not include any of the costs itemized in Paragraph 11.013, and shall include only the following items: EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 42 of 62 1. Payroll costs for employees in the direct employ of Contractor in the performance of the Work under schedules of job classifications agreed upon by Owner and Contractor. Such employees shall include, without limitation, superintendents, foremen, and other personnel employed full time on the Work. Payroll costs for employees not employed full time on the Work shall be apportioned on the basis of their time spent on the Work. Payroll costs shall include, but not be limited to, salaries and wages plus the cost of fringe benefits, which shall include social security contributions, unemployment, excise, and payroll taxes, workers' compensation, health and retirement benefits, bonuses, sick leave, vacation and holiday pay applicable thereto. The expenses of performing Work outside of regular working hours, on Saturday, Sunday, or legal holidays, shall be included in the above to the extent authorized by Owner. 2. Cost of all materials and equipment furnished and incorporated in the Work, including costs of transportation and storage thereof, and Suppliers' field services required in connection therewith. All cash discounts shall accrue to Contractor unless Owner deposits funds with Contractor with which to make payments, in which case the cash discounts shall accrue to Owner. All trade discounts, rebates and refunds and returns from sale of surplus materials and equipment shall accrue to Owner, and Contractor shall make provisions so that they may be obtained. 3. Payments made by Contractor to Subcontractors for Work performed by Subcontractors. If required by Owner, Contractor shall obtain competitive bids from subcontractors acceptable to Owner and Contractor and shall deliver such bids to Owner, who will then determine, with the advice of Engineer, which bids, if any, will be acceptable. If any subcontract provides that the Subcontractor is to be paid on the basis of Cost of the Work plus a fee, the Subcontractor's Cost of the Work and fee shall be determined in the same manner as Contractor's Cost of the Work and fee as provided in this Paragraph 11.01. 4. Costs of special consultants (including but not limited to engineers, architects, testing laboratories, surveyors, attorneys, and accountants) employed for services specifically related to the Work. 5. Supplemental costs including the following: a. The proportion of necessary transportation, travel, and subsistence expenses of Contractor's employees incurred in discharge of duties connected with the Work. b. Cost, including transportation and maintenance, of all materials, supplies, equipment, machinery, appliances, office, and temporary facilities at the Site, and hand tools not owned by the workers, which are consumed in the performance of the Work, and cost, less market value, of such items used but not consumed which remain the property of Contractor. c. Rentals of all construction equipment and machinery, and the parts thereof whether rented from Contractor or others in accordance with rental agreements approved by Owner with the advice of Engineer, and the costs of transportation, loading, unloading, assembly, dismantling, and removal thereof. All such costs shall be in accordance with the terms of EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Pane 43 of 62 said rental agreements. The rental of any such equipment, machinery, or parts shall cease when the use thereof is no longer necessary for the Work. d. Sales, consumer, use, and other similar taxes related to the Work, and for which Contractor is liable, as imposed by Laws and Regulations. e. Deposits lost for causes other than negligence of Contractor, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable, and royalty payments and fees for permits and licenses. f. Losses and damages (and related expenses) caused by damage to the Work, not compensated by insurance or otherwise, sustained by Contractor in connection with the performance of the Work (except losses and damages within the deductible amounts of property insurance established in accordance with Paragraph 5.06.D), provided such losses and damages have resulted from causes other than the negligence of Contractor, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable. Such losses shall include settlements made with the written consent and approval of Owner. No such losses, damages, and expenses shall be included in the Cost of the Work for the purpose of determining Contractor's fee. g. The cost of utilities, fuel, and sanitary facilities at the Site. h. Minor expenses such as telegrams, long distance telephone calls, telephone service at the Site, express and courier services, and similar petty cash items in connection with the Work. i. The costs of premiums for all bonds and insurance Contractor is required by the Contract Documents to purchase and maintain. B. Costs Excluded: The term Cost of the Work shall not include any of the following items: 1. Payroll costs and other compensation of Contractor's officers, executives, principals (of partnerships and sole proprietorships), general managers, safety managers, engineers, architects, estimators, attorneys, auditors, accountants, purchasing and contracting agents, expediters, timekeepers, clerks, and other personnel employed by Contractor, whether at the Site or in Contractor's principal or branch office for general administration of the Work and not specifically included in the agreed upon schedule of job classifications referred to in Paragraph 11.0l.A.1 or specifically covered by Paragraph 11.0l.A.4, all of which are to be considered administrative costs covered by the Contractor's fee. 2. Expenses of Contractor's principal and branch offices other than Contractor's office at the Site. 3. Any part of Contractor's capital expenses, including interest on Contractor's capital employed for the Work and charges against Contractor for delinquent payments. 4. Costs due to the negligence of Contractor, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable, including but not EJCDC C-700 Standard General Conditions of the Construction Contract Copyright C 2007 National Society of professional Engineers for EJCDC. All rights reserved Page 44 of 62 limited to, the correction of defective Work, disposal of materials or equipment wrongly supplied, and making good any damage to property. 5. Other overhead or general expense costs of any kind and the costs of any item not specifically and expressly included in Paragraphs 11.0I.A. C. Contractor's Fee: When all the Work is performed on the basis of cost-plus, Contractor's fee shall be determined as set forth in the Agreement. When the value of any Work covered by a Change Order or when a Claim for an adjustment in Contract Price is determined on the basis of Cost of the Work, Contractor's fee shall be determined as set forth in Paragraph 12.01.C. D. Documentation: Whenever the Cost of the Work for any purpose is to be determined pursuant to Paragraphs 11.01.A and 11.01.13, Contractor will establish and maintain records thereof in accordance with generally accepted accounting practices and submit in a form acceptable to Engineer an itemized cost breakdown together with supporting data. 11.02 Allowances A. It is understood that Contractor has included in the Contract Price all allowances so named in the Contract Documents and shall cause the Work so covered to be performed for such sums and by such persons or entities as may be acceptable to Owner and Engineer. B. Cash Allowances: 1. Contractor agrees that: a. the cash allowances include the cost to Contractor (less any applicable trade discounts) of materials and equipment required by the allowances to be delivered at the Site, and all applicable taxes; and b. Contractor's costs for unloading and handling on the Site, labor, installation, overhead, profit, and other expenses contemplated for the cash allowances have been included in the Contract Price and not in the allowances, and no demand for additional payment on account of any of the foregoing will be valid. C. Contingency Allowance: 1. Contractor agrees that a contingency allowance, if any, is for the sole use of Owner to cover unanticipated costs. D. Prior to final payment, an appropriate Change Order will be issued as recommended by Engineer to reflect actual amounts due Contractor on account of Work covered by allowances, and the Contract Price shall be correspondingly adjusted. 11.03 Unit Price Work A. Where the Contract Documents provide that all or part of the Work is to be Unit Price Work, initially the Contract Price will be deemed to include for all Unit Price Work an amount equal to EJCDC C-700 Standard General Conditions of the Constroction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. An rights reserved. Pace 45 of 62 the sum of the unit price for each separately identified item of Unit Price Work times the estimated quantity of each item as indicated in the Agreement. B. The estimated quantities of items of Unit Price Work are not guaranteed and are solely for the purpose of comparison of Bids and determining an initial Contract Price. Determinations of the actual quantities and classifications of Unit Price Work performed by Contractor will be made by Engineer subject to the provisions of Paragraph 9.07. C. Each unit price will be deemed to include an amount considered by Contractor to be adequate to cover Contractor's overhead and profit for each separately identified item. D. Owner or Contractor may make a Claim for an adjustment in the Contract Price in accordance with Paragraph 10.05 if: 1. the quantity of any item of Unit Price Work performed by Contractor differs materially and significantly from the estimated quantity of such item indicated in the Agreement; and 2. there is no corresponding adjustment with respect to any other item of Work; and 3. Contractor believes that Contractor is entitled to an increase in Contract Price as a result of having incurred additional expense or Owner believes that Owner is entitled to a decrease in Contract Price and the parties are unable to agree as to the amount of any such increase or decrease. ARTICLE 12 — CHANGE OF CONTRACT PRICE; CHANGE OF CONTRACT TIMES 12.01 Change of Contract Price A. The Contract Price may only be changed by a Change Order. Any Claim for an adjustment in the Contract Price shall be based on written notice submitted by the party making the Claim to the Engineer and the other party to the Contract in accordance with the provisions of Paragraph 10.05. B. The value of any Work covered by a Change Order or of any Claim for an adjustment in the Contract Price will be determined as follows: where the Work involved is covered by unit prices contained in the Contract Documents, by application of such unit prices to the quantities of the items involved (subject to the provisions of Paragraph 11.03); or 2. where the Work involved is not covered by unit prices contained in the Contract Documents, by a mutually agreed lump sum (which may include an allowance for overhead and profit not necessarily in accordance with Paragraph 12.0l.C.2); or 3. where the Work involved is not covered by unit prices contained in the Contract Documents and agreement to a lump sum is not reached under Paragraph 12.01.11.2, on the basis of the Cost of the Work (determined as provided in Paragraph 11.01) plus a Contractor's fee for overhead and profit (determined as provided in Paragraph 12.01.Q. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 46 of 62 C. Contractor's Fee: The Contractor's fee for overhead and profit shall be determined as follows: 1. a mutually acceptable fixed fee; or 2. if a fixed fee is not agreed upon, then a fee based on the following percentages of the various portions of the Cost of the Work: a. for costs incurred under Paragraphs 11.0I.A.1 and 11.0I.A.2, the Contractor's fee shall be 15 percent; b. for costs incurred under Paragraph 11.0l.A.3, the Contractor's fee shall be five percent; c. where one or more tiers of subcontracts are on the basis of Cost of the Work plus a fee and no fixed fee is agreed upon, the intent of Paragraphs 12.0l.C.2.a and 12.0l.C.2.b is that the Subcontractor who actually performs the Work, at whatever tier, will be paid a fee of 15 percent of the costs incurred by such Subcontractor under Paragraphs 11.0I.A.1 and 11.0I.A.2 and that any higher tier Subcontractor and Contractor will each be paid a fee of five percent of the amount paid to the next lower tier Subcontractor; d. no fee shall be payable on the basis of costs itemized under Paragraphs 11.0l.A.4, 11.0l.A.5, and 11.01.13; e. the amount of credit to be allowed by Contractor to Owner for any change which results in a net decrease in cost will be the amount of the actual net decrease in cost plus a deduction in Contractor's fee by an amount equal to five percent of such net decrease; and f when both additions and credits are involved in any one change, the adjustment in Contractor's fee shall be computed on the basis of the net change in accordance with Paragraphs 12.0l.C.2.a through 12.0l.C.2.e,inclusive. 12.02 Change of Contract Times A. The Contract Times may only be changed by a Change Order. Any Claim for an adjustment in the Contract Times shall be based on written notice submitted by the party making the Claim to the Engineer and the other party to the Contract in accordance with the provisions of Paragraph 10.05. B. Any adjustment of the Contract Times covered by a Change Order or any Claim for an adjustment in the Contract Times will be determined in accordance with the provisions of this Article 12. 12.03 Delays A. Where Contractor is prevented from completing any part of the Work within the Contract Times due to delay beyond the control of Contractor, the Contract Times will be extended in an amount equal to the time lost due to such delay if a Claim is made therefor as provided in Paragraph 12.02.A. Delays beyond the control of Contractor shall include, but not be limited to, acts or EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Pate 47 of 62 neglect by Owner, acts or neglect of utility owners or other contractors performing other work as contemplated by Article 7, fires, floods, epidemics, abnormal weather conditions, or acts of God. B. If Owner, Engineer, or other contractors or utility owners performing other work for Owner as contemplated by Article 7, or anyone for whom Owner is responsible, delays, disrupts, or interferes with the performance or progress of the Work, then Contractor shall be entitled to an equitable adjustment in the Contract Price or the Contract Times, or both. Contractor's entitlement to an adjustment of the Contract Times is conditioned on such adjustment being essential to Contractor's ability to complete the Work within the Contract Times. C. If Contractor is delayed in the performance or progress of the Work by fire, flood, epidemic, abnormal weather conditions, acts of God, acts or failures to act of utility owners not under the control of Owner, or other causes not the fault of and beyond control of Owner and Contractor, then Contractor shall be entitled to an equitable adjustment in Contract Times, if such adjustment is essential to Contractor's ability to complete the Work within the Contract Times. Such an adjustment shall be Contractor's sole and exclusive remedy for the delays described in this Paragraph 12.03.C. D. Owner, Engineer, and their officers, directors, members, partners, employees, agents, consultants, or subcontractors shall not be liable to Contractor for any claims, costs, losses, or damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) sustained by Contractor on or in connection with any other project or anticipated project. E. Contractor shall not be entitled to an adjustment in Contract Price or Contract Times for delays within the control of Contractor. Delays attributable to and within the control of a Subcontractor or Supplier shall be deemed to be delays within the control of Contractor. ARTICLE 13 — TESTS AND INSPECTIONS; CORRECTION, REMOVAL OR ACCEPTANCE OF DEFECTIVE WORK 13.01 Notice of Defects A. Prompt notice of all defective Work of which Owner or Engineer has actual knowledge will be given to Contractor. Defective Work may be rejected, corrected, or accepted as provided in this Article 13. 13.02 Access to Work A. Owner, Engineer, their consultants and other representatives and personnel of Owner, independent testing laboratories, and governmental agencies with jurisdictional interests will have access to the Site and the Work at reasonable times for their observation, inspection, and testing. Contractor shall provide them proper and safe conditions for such access and advise them of Contractor's safety procedures and programs so that they may comply therewith as applicable. EJCDC C-700 Standard General Conditions of the Constraetion Contract Copyright C 2007 National Society of professional Engineers for EJCDC. AE rights reserved. Pose 48 of 62 13.03 Tests and Inspections A. Contractor shall give Engineer timely notice of readiness of the Work for all required inspections, tests, or approvals and shall cooperate with inspection and testing personnel to facilitate required inspections or tests. B. Owner shall employ and pay for the services of an independent testing laboratory to perform all inspections, tests, or approvals required by the Contract Documents except: 1. for inspections, tests, or approvals covered by Paragraphs 13.03.0 and 13.03.D below; 2. that costs incurred in connection with tests or inspections conducted pursuant to Paragraph 13.04.13 shall be paid as provided in Paragraph 13.04.C; and 3. as otherwise specifically provided in the Contract Documents. C. If Laws or Regulations of any public body having jurisdiction require any Work (or part thereof) specifically to be inspected, tested, or approved by an employee or other representative of such public body, Contractor shall assume full responsibility for arranging and obtaining such inspections, tests, or approvals, pay all costs in connection therewith, and furnish Engineer the required certificates of inspection or approval. D. Contractor shall be responsible for arranging and obtaining and shall pay all costs in connection with any inspections, tests, or approvals required for Owner's and Engineer's acceptance of materials or equipment to be incorporated in the Work; or acceptance of materials, mix designs, or equipment submitted for approval prior to Contractor's purchase thereof for incorporation in the Work. Such inspections, tests, or approvals shall be performed by organizations acceptable to Owner and Engineer. E. If any Work (or the work of others) that is to be inspected, tested, or approved is covered by Contractor without written concurrence of Engineer, Contractor shall, if requested by Engineer, uncover such Work for observation. F. Uncovering Work as provided in Paragraph 13.03.E shall be at Contractor's expense unless Contractor has given Engineer timely notice of Contractor's intention to cover the same and Engineer has not acted with reasonable promptness in response to such notice. 13.04 Uncovering Work A. If any Work is covered contrary to the written request of Engineer, it must, if requested by Engineer, be uncovered for Engineer's observation and replaced at Contractor's expense. B. If Engineer considers it necessary or advisable that covered Work be observed by Engineer or inspected or tested by others, Contractor, at Engineer's request, shall uncover, expose, or otherwise make available for observation, inspection, or testing as Engineer may require, that portion of the Work in question, furnishing all necessary labor, material, and equipment. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of professional Engineers for EJCDC. All rights reserved. Pane 49 of 62 C. If it is found that the uncovered Work is defective, Contractor shall pay all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such uncovering, exposure, observation, inspection, and testing, and of satisfactory replacement or reconstruction (including but not limited to all costs of repair or replacement of work of others); and Owner shall be entitled to an appropriate decrease in the Contract Price. If the parties are unable to agree as to the amount thereof, Owner may make a Claim therefor as provided in Paragraph 10.05. D. If the uncovered Work is not found to be defective, Contractor shall be allowed an increase in the Contract Price or an extension of the Contract Times, or both, directly attributable to such uncovering, exposure, observation, inspection, testing, replacement, and reconstruction. If the parties are unable to agree as to the amount or extent thereof, Contractor may make a Claim therefor as provided in Paragraph 10.05. 13.05 Owner May Stop the Work A. If the Work is defective, or Contractor fails to supply sufficient skilled workers or suitable materials or equipment, or fails to perform the Work in such a way that the completed Work will conform to the Contract Documents, Owner may order Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, this right of Owner to stop the Work shall not give rise to any duty on the part of Owner to exercise this right for the benefit of Contractor, any Subcontractor, any Supplier, any other individual or entity, or any surety for, or employee or agent of any of them. 13.06 Correction or Removal of Defective Work A. Promptly after receipt of written notice, Contractor shall correct all defective Work, whether or not fabricated, installed, or completed, or, if the Work has been rejected by Engineer, remove it from the Project and replace it with Work that is not defective. Contractor shall pay all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such correction or removal (including but not limited to all costs of repair or replacement of work of others). B. When correcting defective Work under the terms of this Paragraph 13.06 or Paragraph 13.07, Contractor shall take no action that would void or otherwise impair Owner's special warranty and guarantee, if any, on said Work. 13.07 Correction Period A. If within one year after the date of Substantial Completion (or such longer period of time as may be prescribed by the terms of any applicable special guarantee required by the Contract Documents) or by any specific provision of the Contract Documents, any Work is found to be defective, or if the repair of any damages to the land or areas made available for Contractor's use by Owner or permitted by Laws and Regulations as contemplated in Paragraph 6.1 LA is found to be defective, Contractor shall promptly, without cost to Owner and in accordance with Owner's written instructions: EJCDC C-700 Standard General Conditions of the Constmetion Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 50 of 62 1. repair such defective land or areas; or 2. correct such defective Work; or 3. if the defective Work has been rejected by Owner, remove it from the Project and replace it with Work that is not defective, and 4. satisfactorily correct or repair or remove and replace any damage to other Work, to the work of others or other land or areas resulting therefrom. B. If Contractor does not promptly comply with the terms of Owner's written instructions, or in an emergency where delay would cause serious risk of loss or damage, Owner may have the defective Work corrected or repaired or may have the rejected Work removed and replaced. All claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such correction or repair or such removal and replacement (including but not limited to all costs of repair or replacement of work of others) will be paid by Contractor. C. In special circumstances where a particular item of equipment is placed in continuous service before Substantial Completion of all the Work, the correction period for that item may start to run from an earlier date if so provided in the Specifications. D. Where defective Work (and damage to other Work resulting therefrom) has been corrected or removed and replaced under this Paragraph 13.07, the correction period hereunder with respect to such Work will be extended for an additional period of one year after such correction or removal and replacement has been satisfactorily completed. E. Contractor's obligations under this Paragraph 13.07 are in addition to any other obligation or warranty. The provisions of this Paragraph 13.07 shall not be construed as a substitute for, or a waiver of, the provisions of any applicable statute of limitation or repose. 13.08 Acceptance of Defective Work A. If, instead of requiring correction or removal and replacement of defective Work, Owner (and, prior to Engineer's recommendation of final payment, Engineer) prefers to accept it, Owner may do so. Contractor shall pay all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) attributable to Owner's evaluation of and determination to accept such defective Work (such costs to be approved by Engineer as to reasonableness) and for the diminished value of the Work to the extent not otherwise paid by Contractor pursuant to this sentence. If any such acceptance occurs prior to Engineer's recommendation of final payment, a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Work, and Owner shall be entitled to an appropriate decrease in the Contract Price, reflecting the diminished value of Work so accepted. If the parties are unable to agree as to the amount thereof, Owner may make a Claim therefor as provided in Paragraph 10.05. If the acceptance occurs after such recommendation, an appropriate amount will be paid by Contractor to Owner. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright* 2007 National Society of Professional Engineers for EJCDC. All rights reserved. 13.09 Owner May Correct Defective Work A. If Contractor fails within a reasonable time after written notice from Engineer to correct defective Work, or to remove and replace rejected Work as required by Engineer in accordance with Paragraph 13.06.A, or if Contractor fails to perform the Work in accordance with the Contract Documents, or if Contractor fails to comply with any other provision of the Contract Documents, Owner may, after seven days written notice to Contractor, correct, or remedy any such deficiency. B. In exercising the rights and remedies under this Paragraph 13.09, Owner shall proceed expeditiously. In connection with such corrective or remedial action, Owner may exclude Contractor from all or part of the Site, take possession of all or part of the Work and suspend Contractor's services related thereto, take possession of Contractor's tools, appliances, construction equipment and machinery at the Site, and incorporate in the Work all materials and equipment stored at the Site or for which Owner has paid Contractor but which are stored elsewhere. Contractor shall allow Owner, Owner's representatives, agents and employees, Owner's other contractors, and Engineer and Engineer's consultants access to the Site to enable Owner to exercise the rights and remedies under this Paragraph. C. All claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) incurred or sustained by Owner in exercising the rights and remedies under this Paragraph 13.09 will be charged against Contractor, and a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Work; and Owner shall be entitled to an appropriate decrease in the Contract Price. If the parties are unable to agree as to the amount of the adjustment, Owner may make a Claim therefor as provided in Paragraph 10.05. Such claims, costs, losses and damages will include but not be limited to all costs of repair, or replacement of work of others destroyed or damaged by correction, removal, or replacement of Contractor's defective Work. D. Contractor shall not be allowed an extension of the Contract Times because of any delay in the performance of the Work attributable to the exercise by Owner of Owner's rights and remedies under this Paragraph 13.09. ARTICLE 14 — PAYMENTS TO CONTRACTOR AND COMPLETION 14.01 Schedule of Values A. The Schedule of Values established as provided in Paragraph 2.07.A will serve as the basis for progress payments and will be incorporated into a form of Application for Payment acceptable to Engineer. Progress payments on account of Unit Price Work will be based on the number of units completed. 14.02 Progress Payments A. Applications for Payments: 1. At least 20 days before the date established in the Agreement for each progress payment (but not more often than once a month), Contractor shall submit to Engineer for review an EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EICDC. All rights reserved. Page 52 of 62 Application for Payment filled out and signed by Contractor covering the Work completed as of the date of the Application and accompanied by such supporting documentation as is required by the Contract Documents. If payment is requested on the basis of materials and equipment not incorporated in the Work but delivered and suitably stored at the Site or at another location agreed to in writing, the Application for Payment shall also be accompanied by a bill of sale, invoice, or other documentation warranting that Owner has received the materials and equipment free and clear of all Liens and evidence that the materials and equipment are covered by appropriate property insurance or other arrangements to protect Owner's interest therein, all of which must be satisfactory to Owner. 2. Beginning with the second Application for Payment, each Application shall include an affidavit of Contractor stating that all previous progress payments received on account of the Work have been applied on account to discharge Contractor's legitimate obligations associated with prior Applications for Payment. 3. The amount of retainage with respect to progress payments will be as stipulated in the Agreement. B. Review of Applications: Engineer will, within 10 days after receipt of each Application for Payment, either indicate in writing a recommendation of payment and present the Application to Owner or return the Application to Contractor indicating in writing Engineer's reasons for refusing to recommend payment. In the latter case, Contractor may make the necessary corrections and resubmit the Application. 2. Engineer's recommendation of any payment requested in an Application for Payment will constitute a representation by Engineer to Owner, based on Engineer's observations of the executed Work as an experienced and qualified design professional, and on Engineer's review of the Application for Payment and the accompanying data and schedules, that to the best of Engineer's knowledge, information and belief: a. the Work has progressed to the point indicated; b. the quality of the Work is generally in accordance with the Contract Documents (subject to an evaluation of the Work as a functioning whole prior to or upon Substantial Completion, the results of any subsequent tests called for in the Contract Documents, a final determination of quantities and classifications for Unit Price Work under Paragraph 9.07, and any other qualifications stated in the recommendation); and c. the conditions precedent to Contractor's being entitled to such payment appear to have been fulfilled in so far as it is Engineer's responsibility to observe the Work. 3. By recommending any such payment Engineer will not thereby be deemed to have represented that: a. inspections made to check the quality or the quantity of the Work as it has been performed have been exhaustive, extended to every aspect of the Work in progress, or EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Paee 53 of 62 involved detailed inspections of the Work beyond the responsibilities specifically assigned to Engineer in the Contract Documents; or b. there may not be other matters or issues between the parties that might entitle Contractor to be paid additionally by Owner or entitle Owner to withhold payment to Contractor. 4. Neither Engineer's review of Contractor's Work for the purposes of recommending payments nor Engineer's recommendation of any payment, including final payment, will impose responsibility on Engineer: a. to supervise, direct, or control the Work, or b. for the means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or c. for Contractor's failure to comply with Laws and Regulations applicable to Contractor's performance of the Work, or d. to make any examination to ascertain how or for what purposes Contractor has used the moneys paid on account of the Contract Price, or e. to determine that title to any of the Work, materials, or equipment has passed to Owner free and clear of any Liens. 5. Engineer may refuse to recommend the whole or any part of any payment if, in Engineer's opinion, it would be incorrect to make the representations to Owner stated in Paragraph 14.023.2. Engineer may also refuse to recommend any such payment or, because of subsequently discovered evidence or the results of subsequent inspections or tests, revise or revoke any such payment recommendation previously made, to such extent as may be necessary in Engineer's opinion to protect Owner from loss because: a. the Work is defective, or completed Work has been damaged, requiring correction or replacement; b. the Contract Price has been reduced by Change Orders; c. Owner has been required to correct defective Work or complete Work in accordance with Paragraph 13.09; or d. Engineer has actual knowledge of the occurrence of any of the events enumerated in Paragraph 15.02.A. C. Payment Becomes Due: 1. Ten days after presentation of the Application for Payment to Owner with Engineer's recommendation, the amount recommended will (subject to the provisions of Paragraph 14.02.D) become due, and when due will be paid by Owner to Contractor. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 54 of 62 D. Reduction in Payment: 1. Owner may refuse to make payment of the full amount recommended by Engineer because: a. claims have been made against Owner on account of Contractor's performance or furnishing of the Work; b. Liens have been filed in connection with the Work, except where Contractor has delivered a specific bond satisfactory to Owner to secure the satisfaction and discharge of such Liens; c. there are other items entitling Owner to a set-off against the amount recommended; or d. Owner has actual knowledge of the occurrence of any of the events enumerated in Paragraphs 14.02.B.5.a through 14.02.B.5.c or Paragraph 15.02.A. 2. If Owner refuses to make payment of the full amount recommended by Engineer, Owner will give Contractor immediate written notice (with a copy to Engineer) stating the reasons for such action and promptly pay Contractor any amount remaining after deduction of the amount so withheld. Owner shall promptly pay Contractor the amount so withheld, or any adjustment thereto agreed to by Owner and Contractor, when Contractor remedies the reasons for such action. 3. Upon a subsequent determination that Owner's refusal of payment was not justified, the amount wrongfully withheld shall be treated as an amount due as determined by Paragraph 14.02.C.I and subject to interest as provided in the Agreement. 14.03 Contractor's Warranty of Title A. Contractor warrants and guarantees that title to all Work, materials, and equipment covered by any Application for Payment, whether incorporated in the Project or not, will pass to Owner no later than the time of payment free and clear of all Liens. 14.04 Substantial Completion A. When Contractor considers the entire Work ready for its intended use Contractor shall notify Owner and Engineer in writing that the entire Work is substantially complete (except for items specifically listed by Contractor as incomplete) and request that Engineer issue a certificate of Substantial Completion. B. Promptly after Contractor's notification, Owner, Contractor, and Engineer shall make an inspection of the Work to determine the status of completion. If Engineer does not consider the Work substantially complete, Engineer will notify Contractor in writing giving the reasons therefor. C. If Engineer considers the Work substantially complete, Engineer will deliver to Owner a tentative certificate of Substantial Completion which shall fix the date of Substantial Completion. There shall be attached to the certificate a tentative list of items to be completed or corrected before EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 55 of 62 final payment. Owner shall have seven days after receipt of the tentative certificate during which to make written objection to Engineer as to any provisions of the certificate or attached list. If, after considering such objections, Engineer concludes that the Work is not substantially complete, Engineer will, within 14 days after submission of the tentative certificate to Owner, notify Contractor in writing, stating the reasons therefor. If, after consideration of Owner's objections, Engineer considers the Work substantially complete, Engineer will, within said 14 days, execute and deliver to Owner and Contractor a definitive certificate of Substantial Completion (with a revised tentative list of items to be completed or corrected) reflecting such changes from the tentative certificate as Engineer believes justified after consideration of any objections from Owner. D. At the time of delivery of the tentative certificate of Substantial Completion, Engineer will deliver to Owner and Contractor a written recommendation as to division of responsibilities pending final payment between Owner and Contractor with respect to security, operation, safety, and protection of the Work, maintenance, heat, utilities, insurance, and warranties and guarantees. Unless Owner and Contractor agree otherwise in writing and so inform Engineer in writing prior to Engineer's issuing the definitive certificate of Substantial Completion, Engineer's aforesaid recommendation will be binding on Owner and Contractor until final payment. E. Owner shall have the right to exclude Contractor from the Site after the date of Substantial Completion subject to allowing Contractor reasonable access to remove its property and complete or correct items on the tentative list. 14.05 Partial Utilization A. Prior to Substantial Completion of all the Work, Owner may use or occupy any substantially completed part of the Work which has specifically been identified in the Contract Documents, or which Owner, Engineer, and Contractor agree constitutes a separately fimctioning and usable part of the Work that can be used by Owner for its intended purpose without significant interference with Contractor's performance of the remainder of the Work, subject to the following conditions: 1. Owner at any time may request Contractor in writing to permit Owner to use or occupy any such part of the Work which Owner believes to be ready for its intended use and substantially complete. If and when Contractor agrees that such part of the Work is substantially complete, Contractor, Owner, and Engineer will follow the procedures of Paragraph 14.04.A through D for that part of the Work. 2. Contractor at any time may notify Owner and Engineer in writing that Contractor considers any such part of the Work ready for its intended use and substantially complete and request Engineer to issue a certificate of Substantial Completion for that part of the Work. 3. Within a reasonable time after either such request, Owner, Contractor, and Engineer shall make an inspection of that part of the Work to determine its status of completion. If Engineer does not consider that part of the Work to be substantially complete, Engineer will notify Owner and Contractor in writing giving the reasons therefor. If Engineer considers that part of the Work to be substantially complete, the provisions of Paragraph 14.04 will apply with respect to certification of Substantial Completion of that part of the Work and the division of responsibility in respect thereof and access thereto. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Pace 56 of 62 4. No use or occupancy or separate operation of part of the Work may occur prior to compliance with the requirements of Paragraph 5.10 regarding property insurance. 14.06 Final Inspection A. Upon written notice from Contractor that the entire Work or an agreed portion thereof is complete, Engineer will promptly make a final inspection with Owner and Contractor and will notify Contractor in writing of all particulars in which this inspection reveals that the Work is incomplete or defective. Contractor shall immediately take such measures as are necessary to complete such Work or remedy such deficiencies. 14.07 Final Payment A. Application for Payment: 1. After Contractor has, in the opinion of Engineer, satisfactorily completed all corrections identified during the final inspection and has delivered, in accordance with the Contract Documents, all maintenance and operating instructions, schedules, guarantees, bonds, certificates or other evidence of insurance, certificates of inspection, marked -up record documents (as provided in Paragraph 6.12), and other documents, Contractor may make application for final payment following the procedure for progress payments. 2. The final Application for Payment shall be accompanied (except as previously delivered) by: a. all documentation called for in the Contract Documents, including but not limited to the evidence of insurance required by Paragraph 5.04.13.6; b. consent of the surety, if any, to final payment; c. a list of all Claims against Owner that Contractor believes are unsettled; and d. complete and legally effective releases or waivers (satisfactory to Owner) of all Lien rights arising out of or Liens filed in connection with the Work. 3. In lieu of the releases or waivers of Liens specified in Paragraph 14.07.A.2 and as approved by Owner, Contractor may famish receipts or releases in full and an affidavit of Contractor that: (i) the releases and receipts include all labor, services, material, and equipment for which a Lien could be filed; and (ii) all payrolls, material and equipment bills, and other indebtedness connected with the Work for which Owner might in any way be responsible, or which might in any way result in liens or other burdens on Owner's property, have been paid or otherwise satisfied. If any Subcontractor or Supplier fails to finnish such a release or receipt in full, Contractor may furnish a bond or other collateral satisfactory to Owner to indemnify Owner against any Lien. B. Engineer's Review of Application and Acceptance: 1. If, on the basis of Engineer's observation of the Work during construction and final inspection, and Engineer's review of the final Application for Payment and accompanying EJCDC C-700 Standard General Conditions of the Construction Contract Copyright 9 2007 National Society of Professional Engineers for @./CDC. All rights reserved. documentation as required by the Contract Documents, Engineer is satisfied that the Work has been completed and Contractor's other obligations under the Contract Documents have been fulfilled, Engineer will, within ten days after receipt of the final Application for Payment, indicate in writing Engineer's recommendation of payment and present the Application for Payment to Owner for payment. At the same time Engineer will also give written notice to Owner and Contractor that the Work is acceptable subject to the provisions of Paragraph 14.09. Otherwise, Engineer will return the Application for Payment to Contractor, indicating in writing the reasons for refusing to recommend final payment, in which case Contractor shall make the necessary corrections and resubmit the Application for Payment. C. Payment Becomes Due: 1. Thirty days after the presentation to Owner of the Application for Payment and accompanying documentation, the amount recommended by Engineer, less any sum Owner is entitled to set off against Engineer's recommendation, including but not limited to liquidated damages, will become due and will be paid by Owner to Contractor. 14.08 Final Completion Delayed A. If, through no fault of Contractor, final completion of the Work is significantly delayed, and if Engineer so confirms, Owner shall, upon receipt of Contractor's final Application for Payment (for Work fully completed and accepted) and recommendation of Engineer, and without terminating the Contract, make payment of the balance due for that portion of the Work fully completed and accepted. If the remaining balance to be held by Owner for Work not fully completed or corrected is less than the retainage stipulated in the Agreement, and if bonds have been furnished as required in Paragraph 5.01, the written consent of the surety to the payment of the balance due for that portion of the Work fully completed and accepted shall be submitted by Contractor to Engineer with the Application for such payment. Such payment shall be made under the terms and conditions governing final payment, except that it shall not constitute a waiver of Claims. 14.09 Waiver of Claims A. The making and acceptance of final payment will constitute: 1. a waiver of all Claims by Owner against Contractor, except Claims arising from unsettled Liens, from defective Work appearing after final inspection pursuant to Paragraph 14.06, from failure to comply with the Contract Documents or the terms of any special guarantees specified therein, or from Contractor's continuing obligations under the Contract Documents; and 2. a waiver of all Claims by Contractor against Owner other than those previously made in accordance with the requirements herein and expressly acknowledged by Owner in writing as still unsettled. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Pace 58 of 62 ARTICLE 15 — SUSPENSION OF WORK AND TERMINATION 15.01 Owner May Suspend Work A. At any time and without cause, Owner may suspend the Work or any portion thereof for a period of not more than 90 consecutive days by notice in writing to Contractor and Engineer which will fix the date on which Work will be resumed. Contractor shall resume the Work on the date so fixed. Contractor shall be granted an adjustment in the Contract Price or an extension of the Contract Times, or both, directly attributable to any such suspension if Contractor makes a Claim therefor as provided in Paragraph 10.05. 15.02 Owner May Terminate for Cause A. The occurrence of anyone or more of the following events will justify termination for cause: 1. Contractor's persistent failure to perform the Work in accordance with the Contract Documents (including, but not limited to, failure to supply sufficient skilled workers or suitable materials or equipment or failure to adhere to the Progress Schedule established under Paragraph 2.07 as adjusted from time to time pursuant to Paragraph 6.04); 2. Contractor's disregard of Laws or Regulations of any public body having jurisdiction; 3. Contractor's repeated disregard of the authority of Engineer; or 4. Contractor's violation in any substantial way of any provisions of the Contract Documents. B. If one or more of the events identified in Paragraph 15.02.A occur, Owner may, after giving Contractor (and surety) seven days written notice of its intent to terminate the services of Contractor: 1. exclude Contractor from the Site, and take possession of the Work and of all Contractor's tools, appliances, construction equipment, and machinery at the Site, and use the same to the full extent they could be used by Contractor (without liability to Contractor for trespass or conversion); 2. incorporate in the Work all materials and equipment stored at the Site or for which Owner has paid Contractor but which are stored elsewhere; and 3. complete the Work as Owner may deem expedient C. If Owner proceeds as provided in Paragraph 15.02.13, Contractor shall not be entitled to receive any further payment until the Work is completed. If the unpaid balance of the Contract Price exceeds all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) sustained by Owner arising out of or relating to completing the Work, such excess will be paid to Contractor. If such claims, costs, losses, and damages exceed such unpaid balance, Contractor shall pay the difference to Owner. Such claims, costs, losses, and damages incurred by Owner will be reviewed by Engineer as to their reasonableness and, when EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. so approved by Engineer, incorporated in a Change Order. When exercising any rights or remedies under this Paragraph, Owner shall not be required to obtain the lowest price for the Work performed. D. Notwithstanding Paragraphs 15.02.13 and 15.02.C, Contractor's services will not be terminated if Contractor begins within seven days of receipt of notice of intent to terminate to correct its failure to perform and proceeds diligently to cure such failure within no more than 30 days of receipt of said notice. E. Where Contractor's services have been so terminated by Owner, the termination will not affect any rights or remedies of Owner against Contractor then existing or which may thereafter accrue. Any retention or payment of moneys due Contractor by Owner will not release Contractor from liability. F. If and to the extent that Contractor has provided a performance bond under the provisions of Paragraph 5.01.A, the termination procedures of that bond shall supersede the provisions of Paragraphs 15.02.13 and 15.02.C. 15.03 Owner May Terminate For Convenience A. Upon seven days written notice to Contractor and Engineer, Owner may, without cause and without prejudice to any other right or remedy of Owner, terminate the Contract. In such case, Contractor shall be paid for (without duplication of any items): 1. completed and acceptable Work executed in accordance with the Contract Documents prior to the effective date of termination, including fair and reasonable sums for overhead and profit on such Work; 2. expenses sustained prior to the effective date of termination in performing services and furnishing labor, materials, or equipment as required by the Contract Documents in connection with uncompleted Work, plus fair and reasonable sums for overhead and profit on such expenses; 3. all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) incurred in settlement of terminated contracts with Subcontractors, Suppliers, and others; and 4. reasonable expenses directly attributable to termination. B. Contractor shall not be paid on account of loss of anticipated profits or revenue or other economic loss arising out of or resulting from such termination. 15.04 Contractor May Stop Work or Terminate A. If, through no act or fault of Contractor, (i) the Work is suspended for more than 90 consecutive days by Owner or under an order of court or other public authority, or (ii) Engineer fails to act on any Application for Payment within 30 days after it is submitted, or (iii) Owner fails for 30 days E7CDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 60 of 62 to pay Contractor any sum finally determined to be due, then Contractor may, upon seven days written notice to Owner and Engineer, and provided Owner or Engineer do not remedy such suspension or failure within that time, terminate the Contract and recover from Owner payment on the same terms as provided in Paragraph 15.03. B. In lieu of terminating the Contract and without prejudice to any other right or remedy, if Engineer has failed to act on an Application for Payment within 30 days after it is submitted, or Owner has failed for 30 days to pay Contractor any sum finally determined to be due, Contractor may, seven days after written notice to Owner and Engineer, stop the Work until payment is made of all such amounts due Contractor, including interest thereon. The provisions of this Paragraph 15.04 are not intended to preclude Contractor from making a Claim under Paragraph 10.05 for an adjustment in Contract Price or Contract Times or otherwise for expenses or damage directly attributable to Contractor's stopping the Work as permitted by this Paragraph. ARTICLE 16 — DISPUTE RESOLUTION 16.01 Methods and Procedures A. Either Owner or Contractor may request mediation of any Claim submitted to Engineer for a decision under Paragraph 10.05 before such decision becomes final and binding. The mediation will be governed by the Construction Industry Mediation Rules of the American Arbitration Association in effect as of the Effective Date of the Agreement. The request for mediation shall be submitted in writing to the American Arbitration Association and the other party to the Contract. Timely submission of the request shall stay the effect of Paragraph 10.05.E. B. Owner and Contractor shall participate in the mediation process in good faith. The process shall be concluded within 60 days of filing of the request. The date of termination of the mediation shall be determined by application of the mediation rules referenced above. C. If the Claim is not resolved by mediation, Engineer's action under Paragraph 10.05.0 or a denial pursuant to Paragraphs 10.05.C.3 or 10.05.D shall become final and binding 30 days after termination of the mediation unless, within that time period, Owner or Contractor: elects in writing to invoke any dispute resolution process provided for in the Supplementary Conditions; or 2. agrees with the other party to submit the Claim to another dispute resolution process; or 3. gives written notice to the other party of the intent to submit the Claim to a court of competent jurisdiction. ARTICLE 17 — MISCELLANEOUS 17.01 Giving Notice A. Whenever any provision of the Contract Documents requires the giving of written notice, it will be deemed to have been validly given if E' fCnC C-700 Standard General Conditions of the Construction Contract Copyright® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Pace 61 of 62 delivered in person to the individual or to a member of the firm or to an officer of the corporation for whom it is intended; or 2. delivered at or sent by registered or certified mail, postage prepaid, to the last business address known to the giver of the notice. 17.02 Computation of Times A. When any period of time is referred to in the Contract Documents by days, it will be computed to exclude the first and include the last day of such period. If the last day of any such period falls on a Saturday or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction, such day will be omitted from the computation. 17.03 Cumulative Remedies A. The duties and obligations imposed by these General Conditions and the rights and remedies available hereunder to the parties hereto are in addition to, and are not to be construed in any way as a limitation of, any rights and remedies available to any or all of them which are otherwise imposed or available by Laws or Regulations, by special warranty or guarantee, or by other provisions of the Contract Documents. The provisions of this Paragraph will be as effective as if repeated specifically in the Contract Documents in connection with each particular duty, obligation, right, and remedy to which they apply. 17.04 Survival of Obligations A. All representations, indemnifications, warranties, and guarantees made in, required by, or given in accordance with the Contract Documents, as well as all continuing obligations indicated in the Contract Documents, will survive final payment, completion, and acceptance of the Work or termination or completion of the Contract or termination of the services of Contractor. 17.05 Controlling Law A. This Contract is to be governed by the law of the state in which the Project is located. 17.06 Headings A. Article and paragraph headings are inserted for convenience only and do not constitute parts of these General Conditions. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. AO rights reserved Page 62 of 62 SUPPLEMENTARY CONDITIONS These Supplementary Conditions amend or supplement the Standard General Conditions of the Construction Contract (C-700, 2007 Edition) and other provisions of the Contract Documents as indicated below. All provisions, which are not so amended or supplemented, remain in full force and effect. The terms used in these Supplementary Conditions will have the meanings indicated in the General Conditions. Additional terms used in these Supplementary Conditions have the meanings indicated below, which are applicable to both the singular and plural thereof. ARTICLE SC -1, ARTICLE SC -2, ARTICLE SC -3, ARTICLE SC -4, ARTICLE SC -5, ARTICLE SC -6, ARTICLE SC -9, ARTICLE SC -11, ARTICLE SC -12, ARTICLE SC -14, ARTICLE SC -16. TABLE OF CONTENTS DEFINITIONS AND TERMINOLOGY.............................................................1 PRELIMINARY MATTERS.............................................................................2 CONTRACT DOCUMENTS: INTENT, AMENDING, REUSE ..........................3 AVAILABILITY OF LANDS; SUBSURFACE AND PHYSICAL CONDITIONS; REFERENCEPOINTS...................................................................................3 BONDS AND INSURANCE............................................................................4 CONTRACTOR'S RESPONSIBILITIES.........................................................6 ENGINEER'S STATUS DURING CONSTRUCTION......................................8 COST OF THE WORK, CASH ALLOWANCES; UNIT PRICE WORK ........... 8 CHANGE OF CONTRACT PRICE; CHANGE OF CONTRACT TIMES .......... 9 PAYMENTS TO CONTRACTOR AND COMPLETION.................................10 DISPUTE RESOLUTION.............................................................................10 ARTICLE SC -1, DEFINITIONS AND TERMINOLOGY The Specifications are written in imperative mood and streamlined form. This imperative language is directed to the Contractor, unless specifically noted otherwise. The words "shall be" are included by inference where a colon (:) is used within sentences or phrases. SC -1.01.A.3. Add the following language to the end of Paragraph 1.01.A.3 The Application for Payment form to be used on this Project is EJCDC No. C-620. Contractor may use their standard computerized forms for providing detail payment breakdown as an attachment to summary sheet. Agency must approve all Applications for Payment before payment is made. SC -1.01.A.9. Add the following language to the end of Paragraph 1.01.A.9: The Change Order form to be used on this Project is EJCDC No. C-941. Agency approval is required before Change Orders are effective. The Engineer's Consultants on this project are: Add the following definitions to the General Conditions: A.52 The term "minority business" means a business: 3097-F: 05/18/15 00800-1 Supplementary Conditions Document prepared in accordance with EJCDC No. C-800 (2007) & RUS Bulletin 1780-26, Attachment H, 10/2009 In which at least fifty-one percent (51%) is owned by one or more minority persons or socially and economically disadvantaged individuals, or in the case of a corporation, in which at least fifty-one percent (51%) of the stock is owned by one or more minority persons or socially and economically disadvantaged individuals; and Of which the management and daily business operations are controlled by one or more of the minority persons or socially and economically disadvantaged individuals who own it. A.53 The term "minority person" means a person who is a citizen or lawful permanent resident of the United States and who is: a. Black, that is, a person having origins in any of the black racial groups in Africa; b. Hispanic, that is, a person of Spanish or Portuguese culture with origins in Mexico, South or Central America, or the Caribbean Islands, regardless of race; c. Asian American, that is, a person having origins in any of the original peoples of the Far East, Southeast Asia and Asia, the Indian subcontinent, or the Pacific Islands; d. American Indian, that is, a person having origins in any of the original Indian peoples of North America; or e. Female. A.54 The term "socially and economically disadvantaged individual' means the same as defined in 15 U.S.C. 637; "Socially disadvantaged individuals are those who have been subjected to racial or ethnic prejudice or cultural bias because of their identity as a member of a group without regard to their individual qualities". "Economically disadvantaged individuals are those socially disadvantaged individuals whose ability to compete in the free enterprise system has been impaired due to diminished capital and credit opportunities as compared to others in the same business area who are not socially disadvantaged." A.55 Notice of Violation: A written notification from a governmental agency that the Owner has violated a law or regulation that the agency has jurisdiction over. Notice will take the form used by the agency and may outline action to be taken by the Owner to correct the violation and may include a monetary fine. A.56 Regular Working Hours: Regular working hours for the project are defined as 8:00 am to 5:00 pm, Eastern Standard Time. ARTICLE SC -2, PRELIMINARY MATTERS SC -2.02 Delete the word "ten" and insert "five" in its place in paragraph 2.02. SC -2.03.A Delete paragraph 2.03.A in its entirety and insert the following in its place: 2.03.A The Contract Times will commence to run on the day indicated in the Notice to Proceed. A Notice to Proceed will be issued at any time within 30 days after the Effective Date of the Agreement or a date agreed to by the Owner and Contractor. Supplementary Conditions 00800-2 3097-F : 05/18/15 Document prepared in accordance with EJCDC No. C-800 (2007) & RUS Bulletin 1780-26, Attachment H, 10/2009 ARTICLE SC -3, CONTRACT DOCUMENTS: INTENT AMENDING REUSE SC -3.01.8 Add the following paragraph 3.01.13.1 to the General Conditions: 3.01.6.1 Division 1, General Requirements, govern the execution of the work of all sections of the specifications. ARTICLE SC -4, AVAILABILITY OF LANDS: SUBSURFACE AND PHYSICAL CONDITIONS: REFERENCE POINTS SC 4.01 Add the following paragraph 4.01.D to the General Conditions: The concrete driveway to Heavens Gate Church shall remain open and contractor shall be responsible for any damage to driveway. The old house behind Ernie's Tool Time shall not be damaged. SC 4.02 Add the following new paragraph(s) immediately after paragraph 4.02.B: C. In the preparation of Drawings and Specifications, Engineer or Engineer's Consultants relied upon the following reports of explorations and tests of subsurface conditions at the Site: Atlantic Coast Engineering and Testing, Inc 8 Lockheed Court Greensboro, NC 27409 "Drillers Report of Power Auger Borings Davidson County — Old Salisbury Road Project Lexington NC ACET File Number AC -5337 D. In the preparation of Drawings and Specifications, Engineer or Engineer's Consultants relied upon the following drawings of physical conditions to existing surface and subsurface structures (except Underground Facilities) which are at or contiguous to the site of the Work. Sheet C10 — Site Utility Plan Frenzelit North America, Inc. New Production Facility and Offices 4165 Old Salisbury Road Lexington NC 27295 Sealed by Steve Causey License Number 19701 E. Copies of reports and drawings itemized in SC -4.02.0 and SC -4.02.D that are not included with Bidding Documents may be examined at the Engineer's office during regular business hours. These reports and drawings are not part of the Contract Documents, but the "technical data" contained therein upon which Contractor may rely as identified and established above are incorporated therein by reference. Contractor is not entitled to rely upon other information and data utilized by Engineer and Engineer's Consultants in the preparation of Drawings and Specifications. SC -4.04.A.2 The following shall be added to paragraph 4.04.A.2: e. Contractor shall follow the North Carolina General Statutes, Chapter 87, Article 8 Underground Damage Prevention. 3097-F: 05/18/15 00800-3 Supplementary Conditions Document prepared in accordance with EJCDC No. C-800 (2007) & RUS Bulletin 1780-26, Attachment H, 10/2009 Notifying owners of underground facilities prior to start of Work. g. Investigating ahead of the Work to verify the existence of Underground Facilities h. Assuming risks and repairing damage caused by the Work to existing Underground Facilities whether indicated or not in the Contract Documents. Repairs to Underground Facilities shall be done to the satisfaction of the Underground Facility owner and may require material and methods, which are better than the existing Facility. Underground Facility owner reserves the right to repair damage by the Contractor to their underground Facilities. If the Owner exercises this right, the owner's cost of this Work shall be deducted from the money due the Contractor. Uncovering Underground Facilities, with that owners approval, that are located within the Work as necessary for Engineer to determine the requirements for the change in the work. SC 4.06 Delete paragraph 4.06.A and 4.06.13 in their entirety and insert the following: A. No reports or drawings of Hazardous Environmental Conditions at or contiguous to the Site are known to the Owner or Engineer. B. Not used. SC -4.07 Add the following new paragraph after SC -4.06: SC -4.07 Miscellaneous Site Conditions A. The Contractor shall perform video inspections and take photographs of the proposed construction areas before disturbing the site in order to establish an accurate record of the pre -construction conditions for comparison to the final work. The Contractor shall provide the Owner with copies of all video and photographic records at the appropriate times (i.e., pre -construction and post -construction). The cost of video and photographic work shall be incidental to the contract and no separate payment will be made by the Owner. ARTICLE SC -5, BONDS AND INSURANCE SC -5.01 Add the following paragraphs immediately following paragraph 5.01.0 D. The contractor shall provide the following Bonds in addition to the Performance and Payment Bonds required in the General Conditions: 1. A Performance and Indemnity Bond shall be expected and posted with the N.C. Division of Highways in the amount as required in the Project Encroachment Contract as attached to the end of this Section. SC -5.04 Add the following new paragraphs immediately after paragraph 5.04.6: C. Limits of liability for the insurance required by paragraph 5.04 of the General Conditions shall provide coverage for not less than the following amounts or greater where required by Laws and Regulations: Supplementary Conditions 00800-4 3097-F : 05/18/15 Document prepared in accordance with EJCDC No. C-800 (2007) & RUS Bulletin 1780-26, Attachment H, 10/2009 1. Worker's Compensation, and related coverage under paragraphs 5.04.A.1 and 5.04.A.2 of the General Conditions: a. State: Statutory - Per the Workers' Compensation Laws of the State of North Carolina. b. Applicable Federal (e.g., Longshoremen's) Statutory c. Employers Liability: $500,000 2. Contractor's General Liability under paragraphs 5.04.A.3 through 5.04.A.6 of the General Conditions, which shall include completed operations and product liability coverages and eliminate the exclusion with respect to property under the care, custody and control of the Contractor: a. General Aggregate b. Products & Completed Operations Aggregate c. Personal & Advertising Injury d. Each Occurrence (Bodily Injury & Property Damage) e. Property Damage liability insurance will provide Explosion, Collapse, and Under -ground coverages where applicable. f. Fire Damage g. Medical Expense 3. Excess or Umbrella Liability: 1) General Aggregate 2) Each Occurrence $2,000,000.00 $2,000,000.00 $1,000,000.00 $1,000,000.00 $50,000.00 $5,000.00 $5,000,000.00 $5,000,000.00 4. Automobile Liability under Paragraph 5.04.A.6 of the General Conditions: a. Bodily Injury: Each person Each Accident b. Property Damage: Each Accident $1,000,000.00 $1,000,000.00 $1,000,000.00 OR (i.e., either a. and b. or c.) c. Combined Single Limit of $1,000,000.00 5. The Contractual Liability coverage required by Paragraph 5.04.B.3 of the General Conditions shall provide coverage for not less than the following amounts: a. Bodily Injury: Each person Each Accident b. Property Damage: Each Accident Annual Aggregate $2,000,000.00 $2,000,000.00 $2,000,000.00 $2,000,000.00 3097-F: 05/18/15 00800-5 Supplementary Conditions Document prepared in accordance with EJCDC No. C-800 (2007) & RUS Bulletin 1780-26, Attachment H, 10/2009 SC -5.06.A Delete paragraph 5.06.A in its entirety and insert the following in its place. A. General Contractor shall purchase and maintain property insurance upon the Work at the Site in the amount as shown below. This insurance shall comply with Paragraphs 5.06.A.1 through 5.06.A.7 of the General Conditions which shall remain in effect. Property Insurance Full Replacement Cost of Work SC -5.06.A Add the following paragraphs after 5.06.A.7. 8. include a waiver of occupancy clause endorsement, which will enable the Owner to occupy the facility under construction / renovation during such activity. 9. be responsible for deductible or self-insured retention. 10. when a contract includes the installation of equipment into an existing structure, the above policy shall include an "Installation Floater' endorsement covering same. This includes installation and transit. 11. name Owner as insured in the policy. ARTICLE SC -6, CONTRACTOR'S RESPONSIBILITIES SC -6.02 Add the following paragraphs after 6.02.B: C. Overtime Work: If Contractor's Work requires inspection as determined by the Engineer more than 10 hours in a work day or 40 hours in a work week, Monday through Friday excluding holidays, or on the weekends he shall submit a written request to the Engineer five (5) working days prior to the scheduled Work. Contractor shall pay for the Resident Project Representative's time beyond the above hours at the rate of $75.00 / hour. D. The above will not prevent the Contractor from working outside the above time that will not require the inspector to be present. Such work may include; start up, clean up, seeding, painting (after the base surface has been approved by the inspector), and similar items. Contractor shall obtain approval of Work to be performed outside of the above work hours. Contractor shall not be charged for inspector's time for Work specifically identified by the Contract Documents to be performed outside the above Work time or on weekends. SC -6.05.0 Amend the paragraph by creating two subpagraphs under the title "C. Engineer's Evaluation." The paragraph text shall be retitled "6.05.C.2 After Effective Date of Agreement.". A new paragraph is added before this paragraph to read as follows: During Bidding. The Contract, if equipment specified or described in equipment as defined in paragraph materials and equipment approved materials and equipment described required type, function, and quality awarded, will be on the basis of materials and the Bidding Documents, or "or -equal" materials and 6.05 of the General Conditions, or those substitute by the Engineer and identified by Addendum. The in the Bidding Documents establish a standard of to be met by any proposed substitute or "or -equal" Supplementary Conditions 00800-6 3097-F: 05/18/15 Document prepared in accordance with EJCDC No. C-800 (2007) & RUS Bulletin 1780-26, Attachment H, 10/2009 item. Request for Engineer's clarification of materials and equipment considered "or - equal" prior to the Effective Date of the Agreement must be received by the Engineer at least 5 days prior to the date for receipt of Bids. No item of material or equipment will be considered by Engineer as a substitute unless written request for approval has been submitted by Bidder and has been received by Engineer at least 15 days prior to the date for receipt of Bids. Each request shall conform to the requirements of Paragraph 6.05 of the General Conditions. The burden of proof of the merit of the proposed item is upon the Bidder. Engineer's decision of approval or disapproval of a proposed item will be final. If Engineer approves any proposed substitute item, such approval will be set forth in an Addendum issued to all prospective Bidders. Bidders shall not rely upon approvals made in any other manner. SC -6.06.C.3 Add the following paragraph immediately after paragraph 6.06.C2: Owner or Engineer may furnish to any such Subcontractor or Supplier to the extent practical, information about amounts paid to Contractor on account of Work performed for Contractor by a particular Subcontractor or Supplier. SC -6.06 Add a new paragraph immediately after Paragraph 6.06.G: H. The Contractor shall not award work valued at more than fifty (50%) percent of the Contract Price to Subcontractor(s), without prior written approval of the Owner. SC -6.08 Add the following paragraph after 6.08.A: B. Owner shall obtain and pay for the following permits: 1. NCDENR Erosion Control Permit (project site only) 2. DWQ Wastewater Permit 3. N.C. DOT Encroachment Agreement These permits are made part of this contract and attached to the end of this Section. This paragraph does not relieve Contractor of his responsibility to comply with applicable Laws and Regulations as stated in Paragraph 6.09. SC -6.09 Add the following paragraph(s) after 6.09.C: D. Contractor shall be responsible for conforming to the requirements of the approved sedimentation control plan, the rules and regulations of the Erosion Control Laws of the State of North Carolina, specifically the Sedimentation Pollution Control Act of 1973 (G.S. 113A) as amended, and the local jurisdiction where the project is located as it relates to land disturbing activities undertaken by Contractor. Contractor shall be responsible to Owner for any fines imposed on Owner as a result of Contractor's failure to comply with the above as it is further described in the Erosion Control Section of the Specifications. E. Contractor shall be responsible for conforming to the requirements (including associated construction costs) of the N.C. Department of Transportation Encroachment Agreement, and all other local, state, and federal permits associated with the project. F. Should the Contractor cause the Owner to receive a Notice of Violation from a governmental agency, Contractor shall pay costs associated with Notice of Violation 3097-F : 05/18/15 00800-7 Supplementary Conditions Document prepared in accordance with EJCDC No. C-800 (2007) & RUS Bulletin 1780-26, Attachment H, 10/2009 within ten (10) days of receipt of written notification. Costs shall include, but not be limited to: 1. Fines imposed on the Owner by the agency. 2. Required legal newspaper publications concerning violation. 3. Required mailings to customers concerning notification of violation. 4. Administrative, engineering, and construction costs associated with resolving the Notice of Violation. G. Notice of Violation may include, but not be limited to, the following problems: 1. Sewage spill. 2. Inadequate erosion control measures. 3 Equipment failure during the warranty period. H. In the event of a sewage spill during construction, Contractor shall take the following steps as a minimum: 1. Take immediate action to contain the spill. 2. Notify the Owner and Engineer within 30 minutes of realizing a spill has occurred. 3. Clean up the spill as directed by the Owner. Contractor shall bare all costs associated with cleanup. SC -6.12 Add a new paragraph after paragraph 6.12.A: B. Record Documents shall be updated daily. Should the Engineer determine that the Record Documents are not being properly maintained, approval of future payment requests shall be withheld. SC -6.17 Add the following new paragraphs immediately after Paragraph 6.17.E: F. Contractor shall furnish required submittals with sufficient information and accuracy in order to obtain required approval of an item with no more than three submittals. Engineer will record Engineer's time for reviewing subsequent submittals of Shop Drawings, samples or other items requiring approval and Contractor shall reimburse Owner for Engineer's charges for such time. G. In the event that Contractor requests a substitution for a previously approved item, Contractor shall reimburse Owner for Engineer's charges for such time unless the need for such substitution is beyond the control of Contractor. ARTICLE SC -9, ENGINEER'S STATUS DURING CONSTRUCTION SC -9.03.A Add the following language at the end of paragraph 9.03.A: The Engineer will provide Part Time Construction Observation services for this project. The Duties, Responsibilities, and Limitations of Authority of the Part Time Construction Observer will be as stated in the Agreement Between Owner and Engineer. ARTICLE SC -11, COST OF THE WORK, CASH ALLOWANCES: UNIT PRICE WORK SC-11.01.A.5.c, Delete Paragraph 11.01.A.5.c in its entirety and insert the following in its place: Supplementary Conditions 00800-8 3097-F: 05/18/15 Document prepared in accordance with EJCDC No. C-800 (2007) & RUS Bulletin 1780-26, Attachment H, 10/2009 C. Construction Equipment and Machinery: 1. Rentals of all construction equipment and machinery, and the parts thereof in accordance with rental agreements approved by Owner with the advice of Engineer, and the costs of transportation, loading, unloading, assembly, dismantling, and removal thereof. All such costs shall be in accordance with the terms of said rental agreements. The rental of any such equipment, machinery, or parts shall cease when the use thereof is no longer necessary for the Work. 2. Costs for equipment and machinery owned by Contractor will be paid at a rate shown for such equipment in the Rental Rate Blue Book (latest edition). An hourly rate will be computed by dividing the monthly rates by 176. These computed rates will include all operating costs. Costs will include the time the equipment or machinery is in use on the changed Work and the costs of transportation, loading, unloading, assembly, dismantling, and removal when directly attributable to the changed Work. The cost of any such equipment or machinery, or parts thereof, shall cease to accrue when the use thereof is no longer necessary for the changed Work. Equipment or machinery with a value of less than $1,000 will be considered small tools. SC -11.03.D.1 Delete Paragraph 11.03.D.1 in its entirety and insert the following in its place: if the Bid price of a particular item of Unit Price Work amounts to 5 percent or more of the Contract Price and the variation in the quantity of that particular item of Unit Price Work performed by Contractor differs by more than 25 percent from the estimated quantity of such item indicated in the Agreement; and ARTICLE SC -12. CHANGE OF CONTRACT PRICE: CHANGE OF CONTRACT TIMES SC -12.02 Add the following paragraph after 12.02.B: C. Time Extension: Contract time extensions for weather delays do not entitle Contractor to "extended overhead" recovery. SC -12.03 Add the following paragraphs after 12.03.E: Time extension for weather delays due to rain shall only be considered for above average precipitation. NOAA Report No. 20 shall be used to determine the average number of days with precipitation greater than or equal to 0.10 inch for each month. A link to this report is as follows: http://cdo.ncdc.noaa.gov/climatenormals/clim20/state- pdf/nc.pdf . G. Claims for additional Contract Time for delays beyond the Contractor's control shall be submitted in accordance with Article 10 of the General Conditions with the Contractor's monthly pay request. Submittal shall include the number of days requested and the reason for the delay. Engineer shall notify the Owner and Contractor of his decision in accordance with Article 10 of the General Conditions. Approval of time shall be included in a Change Order. 3097-F : 05/18/15 00800-9 Supplementary Conditions Document prepared in accordance with EJCDC No. C-800 (2007) & RUS Bulletin 1780-26, Attachment H, 10/2009 ARTICLE SC -14, PAYMENTS TO CONTRACTOR AND COMPLETION SC -14.02.A Add the following to the end of paragraph 14.02.A.3: No payments will be made that would deplete the retainage, place in escrow any funds that are required for retainage, or invest the retainage for the benefit of the Contractor. SC -14.02.A Add the following new paragraph after paragraph 14.02.A.3: 4. The Application for Payment form to be used on this project is EJCDC No. C-620. The Agency must approve all Applications for Payment before payment is made. SC -14.02.0 Delete paragraph 14.02.C.1 in its entirety and insert the following in its place: The Application for Payment with Engineer's recommendations will be presented to the Owner and Agency for consideration. If both the Owner and Agency find the Application for Payment acceptable, the recommended amount less any reduction under the provisions of Paragraph 14.02.D will become due 20 days after the Application for Payment is presented to the Owner, and the Owner will make payment to the Contractor. ARTICLE SC -16, DISPUTE RESOLUTION SC -16.01.A, Delete the second and third sentence in Paragraph 16.01 A. SC -16.01.8, Delete Paragraph 16.01.B in its entirety and replace it with the following: B. Disputes shall be resolved in accordance with the dispute resolution process adopted on February 26, 2002 by the N. C. State Building Commission. The "Rules Implementing Mediated Settlement Conferences in North Carolina Public Construction Projects" are attached to this section. SC -16.01.C, Delete Paragraph 16.01.0 in its entirety and replace it with the following: C. All parties agree that only the North Carolina courts shall have jurisdiction over the Contract and any controversies arising out of this Contract and this agreement shall be governed by and construed in accordance with the laws of the State of North Carolina. END OF DOCUMENT Supplementary Conditions 00800-10 3097-F : 05/18/15 Document prepared in accordance with EJCDC No. C-800 (2007) B RUS Bulletin 1780-26, Attachment H, 10/2009 Minority Business Contract Provisions - Minority Business Subcontract Goals: The goals for participation by minority firms as subcontractors on this project have been set at 10%. The bidder must identify on its bid, the minority business that will be utilized on the project with corresponding total dollar value of the bid and affidavit (Affidavit A) listing good faith efforts or affidavit (Affidavit B) of self -performance of work, if the bidder will perform work under contract by its own workforce, as required by GS 143-128.2(c) and GS 143-128.2(f). The lowest responsible, responsive bidder must provide Affidavit C, that includes a description of the portion of work to be executed by minority businesses, expressed as a percentage of the total contract price, which is equal to or more than the applicable goal. Provide Affidavit D, that includes a description of the portion of work to be executed by minority businesses, expressed as a percentage of the total contract price, with documentation of Good Faith Effort, if the percentage is not equal to the applicable goal. OR Provide Affidavit B, which includes sufficient information for the Owner to determine that the bidder does not customarily subcontract work on this type project. The above information must be provided as required. Failure to submit these documents is grounds for rejection of the bid. Minimum Compliance Requirements: All written statements, affidavits or intentions made by the Bidder shall become a part of the agreement between the Contractor and the Owner for the performance of this contract. Failure to comply with any of these statements, affidavits or intentions, or with the minority business guidelines shall constitute a breach of the contract. A finding by the Owner that any information submitted either prior to award of the contract or during the performance of the contract is inaccurate, false or incomplete, shall also constitute a breach of the contract. Any such breach may result in termination of the contract in accordance with the termination provisions contained in the contract. It shall be solely at the option of the Owner whether to terminate the contract for breach. In determining whether a contractor has made Good Faith Efforts, the Owner will evaluate all efforts made by the Contractor and will determine compliance in regard to quantity, intensity, and results of these efforts. Good Faith Efforts include: 1. Contracting minority businesses that reasonably could have been expected to submit a quote and that were known to the contractor or available on State or local government maintained lists at least 10 days before the bid or proposal date and notifying them of the nature and scope of the work to be performed. 2. Making the construction plans, specifications and requirements available for review by prospective minority businesses, or providing these documents to them at least 10 days before the bid or proposals are due. 3. Breaking down or combining elements of work into economically feasible units to facilitate minority participation. 4. Worked with minority trade, community, or contractor organizations identified by the Office of Historically Underutilized Businesses and included in the bid documents that provide assistance in recruitment of minority businesses. 5. Attended pre-bid meetings scheduled by the public owner. 6. Provided assistance in getting required bonding or insurance or provided alternatives to bonding or insurance for subcontractors. 7. Negotiated in good faith with interested minority businesses and did not reject them as unqualified without sound reasons based on their capabilities. Any rejection of a minority business based on lack of qualification should have the reasons documented in writing. 8. Provided assistance to an otherwise qualified minority business in need of equipment, loan capital, lines of credit, or joint pay agreements to secure loans, supplies, or letters of credit, including waiving credit that is ordinarily required. Assisted minority businesses in obtaining the same unit pricing with the bidder's supplies in order to help minority businesses in establishing credit. 9. Negotiated joint venture and partnership arrangements with minority businesses in order to increase opportunities for minority business participation on a public construction or repair project when possible. 10. Provided quick pay agreements and policies to enable minority contractors and suppliers to meet cash-flow demands. Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Identification of Minority Business Participation 9 a'� Kn(' TT k) C Do hereby certify that on this project, we will use the following minority business enterprises as construction subcontractors, vendors, suppliers or providers of professional services. Firm Name, Address and Phone # Work Type *Minority Category d �� V t'S 'Minority categories: Black, African American (B), Hispanic (H), Asian American (A), American Indian (1), Female (F), Socially and Economically Disadvantaged (D) The total value of minority business contracting will be $ 1 -L-) oUU,"� This equals to 9 0 Ir- % of contract. Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid I AFFIDAVIT A — Listing of the Good Faith Efforts Davidson County, North Carolina Affidavit of (Bidder) I have made a good faith effort to comply under the following areas checked: (A minimum of 5 areas must be checked in order to have achieved a "good faith effort') 0 1- Contracted minority businesses that reasonably could have been expected to submit a quote and that were known to the contractor, or available on State or local government maintained lists, at least 10 days before the bid date and notified them of the nature and scope of the work to be performed. 2- Made the construction plans, specifications and requirements available for review by prospective minority businesses or providing these documents to them at least 10 days before the bids are due. 0 3- Broken down or combined elements of work into economically feasible units to facilitate minority participation. 4- Worked with minority trade, community, or contractor organizations identified by the Office of Historically Underutilized Businesses and included in the bid documents that provide assistance in recruitment of minority businesses. 0 5- Attended pre-bid meetings scheduled by the public owner. 6- Provided assistance in getting required bonding or insurance or provided alternatives to bonding or insurance for subcontractors. 7- Negotiated in good faith with interested minority businesses and did not reject them as unqualified without sound reasons based on their capabilities. Any rejection of a minority business based on lack of qualification should have the reasons documented in writing. 8- Provided assistance to an otherwise qualified minority business in need of equipment, loan capital, lines of credit, or joint pay agreements to secure loans, supplies, or letters of credit, including waiving credit that is ordinarily required. Assisted minority businesses in obtaining the same unit pricing with the bidder's supplies in order to help minority businesses in establishing credit. 0 9- Negotiated joint venture and partnership arrangements with minority businesses in order to increase opportunities for minority business participation on a public construction or repair project when possible. 10- Provided quick pay agreements and policies to enable minority contractors and suppliers to meet cash-flow demands. I Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid In accordance with GS 143-128.2 (d) the undersigned will enter into a formal agreement with the firms listed in the Identification of Minority Business Participation schedule conditional upon execution of a contract with the Owner. Failure to abide by the statutory provision will constitute a breach of the contract. The undersigned hereby certifies that he or she has read the terms of the minority business commitment and is authorized to bind the bidder to the commitment herein set forth. Date: SEAL Name of Authorized Officer: Signature: Title: State of North Carolina, County of Subscribed and sworn to before me this day of Notary Public My commission expires 20 I Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid I Attach to Bid Attach to Bid .Attach to Bid Attach to Bid ,Attach to Bid Attach to Bid Attach to Bid Attach to Bid AFFIDAVIT 8 — Intent to Perform Contract with Own Workforce Davidson County, North Carolina Affidavit of I hereby certify that it is our intent to perform 100% of the work required for the Contract. in making this certification, the Bidder states that the Bidder does not customarily subcontract elements of this type project, and normally performs and has the capability to perform and will perform all elements of the work on this project with bidder's own work forces; and The Bidder agrees to provide any additional information or documentation required by the owner in support of the above statement. The undersigned hereby certifies that they have read this certification and is authorized to bind the Bidder to the commitments herein contained. tA�TARY SLAL P UG . . Name of Auttozed Officer: , ES la rj-r— U` Signature: Title: Q State of North Carolina, County of Attwvtn to Subscribed and sworn �tt befope me this l0 day of t, 20 ►� /I Notary Public ws!<J V 2S XAtk,'.S My commission expires 8.19 79 I Attach to Bid Attach to Rid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid Attach to Bid THIS FORM IS NOT TO BE SUBMITTED WITH THE BID DOCUMENTS AFFIDAVIT C Portion of the Work to be Performed by Minority Firms Davidson County, North Carolina L`tha portion of the work to be executed by minority Businesses as defined m GS 143-128.2(g) is equal to or greater than 10% of the bidders total contract price, then the bidder most complete this affidavit. This affidavit shallbe provided by the apparent lowest responsible, responsive bidder within 72 hours after notification ofbeing low bidder. Affidavit of��6) L , yy IffT 1 hereby certify that on the ULD YZoao SCWCi Name of Proleat Project 113 Amount of Bid $2z. I will expend a minimum of --<b—% of the total dollar amount of the contract with minority business enterprises. Minority businesses will be employed as construction subcontractors, vendors, suppliers or providers of professional services. Such work will be subcontracted to the following firms listed below. AFFIDAVIT D — Good Faith Efforts Davidson County, North Carolina If the goal of 10% participation by the minority business is not achieved, the Bidder shall provide the following documentation to the Owner of his good faith efforts: Affidavit of I do certify the attached documentation as true and accurate representation of my good faith efforts. Name and Phone Number I *Minority Category I Work Description I Dollar Value I *Minority categories: Black, African American (B), Hispanic (H), Asian American (A), American Indian (1), Female (F), Socially and Economically Disadvantaged (D) Documentation of the Bidder's good faith efforts to meet the goals set forth in these provisions. Examples of documentation include, but are not limited to, the following evidence: A. Copies of solicitations for quotes to at least three (3) minority business firms from the source list provided by the State for each subcontract to be let under this contract (if 3 or more firms are shown on the source list). Each solicitation shall contain a specific description of the work to be subcontracted, location where bid documents can be reviewed, representative of the Prime Bidder to contract, and location, date and time when quotes must be received. B. Copies of quotes or responses received from each firm responding to the solicitation. C. A telephone log of follow-up calls to each firm sent a solicitation. D. For subcontracts where a minority business firm is not considered the lowest responsible sub -bidder, copies of quotes received from all firms submitting quotes for that particular subcontract. E. Documentation of any contracts or correspondence to minority business, community, or contractor organizations in an attempt to meet the goal. F. Copy of pre-bid roster. G. Letter documenting efforts to provide assistance in obtaining required bonding or insurance for minority business. H. Letter detailing reasons for rejection of minority business due to lack of qualification. I. Letter documenting proposed assistance offered to minority business in need of equipment, loan capital, lines of credit, or joint pay agreements to secure loans, supplies, or letter of credit, including waiving credit that is ordinarily required. Failure to provide the documentation as listed in these provisions may result in rejection of the bid and award to the next lowest responsible and responsive bidder. Date: Name of Authorized Officer: Signature: Title: State of North Carolina, County of Subscribed and sworn to before me this day of Notary Public My commission expires 20 THIS DOCUMENT MUST BE SUBMITTED WITH EACH PAY REQUEST & FINAL PAYMENT APPENDIX E MBE DOCUMENTATION FOR CONTRACT PAYMENTS Prime Contractor / Architect: Address & Phone: Project Pay Application Period: The following is a list of payments to be made to minority business contractors on this project for the above-mentioned period. Firm Name *Minority Category Payment Amount Owner Use Only *Minority categories: Black, African American (B), Hispanic (H), Asian American (A), American Indian (1), Female (F), Socially and Economically Disadvantaged (D) Date: Approved / Certified By: Name Title Signature I THIS DOCUMENT MUST BE SUBMITTED WITH EACH PAY REQUEST & FINAL PAYMENT RULES FOR IMPLEMENTING MEDIATED SETTLEMENT CONFERENCES IN THE COUNTY OF DAVIDSON CONSTRUCTION PROJECTS Table of Rules RULE 1. Initiating Mediated Settlement Conferences A. Purpose of Mandatory Settlement Conferences B. Initiating the Dispute Resolution Process 2. Selection of Mediator A. Selection of Certified Mediator by Agreement of the Parties B. Nomination and Court Approval of a Non -Certified Mediator C. Appointment of Mediator by The County of Davidson D. Mediator Information Directory E. Disqualification of Mediator 3. The Mediated Settlement Conference A. Where Conference is to be Held B. When Conference is to be Held C. Request to Extend Deadline for Completion D. Recesses E. The Mediated Settlement Conference shall not be cause for the Delay of the Construction Project, which is the focus of the Dispute 4. Duties of Parties and Other Participants in Formal Dispute Resolution Process A. Attendance B. Finalizing Agreement C. The Mediation Fee shall be paid in accordance with N.C.G.S. 143-128(fl) D. Failure to Compensate Mediator Authority and Duties of Mediators A. Authority of Mediator. B. Duties of Mediator 6. Compensation of the Mediator A. By Agreement. B. By Appointment Mediator Certification 8. Rule Amendments 9. Time Limits RULE 1. INITIATING MEDIATED SETTLEMENT CONFERENCES A. Purpose of Mandatory Settlement Conferences. Pursuant to N.C.G.S. 143-12811, these Rules are promulgated to implement a system of settlement events, which are designated to focus the parties' attention on settlement rather than on claim preparation and to provide a structured opportunity for settlement negotiations to take place. Nothing herein is intended to limit or prevent the parties from engaging in settlement procedures voluntarily at any time prior to or during commencement of the dispute resolution process. B. Initiating the Dispute Resolution Process 1. Any party to a County of Davidson contract governed by N.C.G.S. 143-128.fl and who is a party to a dispute arising out of the construction process in which the amount in controversy is at least $15,000 may submit a written request to The County of Davidson for mediation of the dispute. 2. Prior to submission of a written request for mediation to The County of Davidson, the parties requesting mediation, a. If a prime contractor, must have first submitted its claim to the Project Designer for review. If the dispute is not resolved through the Project Designer's instructions, then the dispute is eligible for mediation in the Formal Dispute Resolution Process, and the party may submit their written request for mediation to The County of Davidson. b. If the party requesting mediation is a subcontractor, it must first have submitted its claim for mediation to the prime contractor with whom it has a contract. If the dispute is not resolved through the Prime Contractor's involvement, then the dispute is eligible for mediation in the Formal Dispute Resolution Process, and the party may submit its written request for mediation to The County of Davidson. C. If the party requesting mediation is the Project Designer, then it must first submit its claim to The County of Davidson to resolve. If the dispute is not resolved with The County of Davidson's involvement, then the Project Designers' dispute is eligible for mediation in the Formal Dispute Resolution Process, and the Project Designer may submit its written request to The County of Davidson for mediation. RULE 2. SELECTION OF MEDIATOR A. Selection of Certified Mediator by Agreement of the Parties. The parties may select a certified mediator pursuant to the Rules by agreement within 21 days of requesting mediation. The requesting party shall file with The County of Davidson a Notice of Selection of Mediator by Agreement within 10 days of the request; however, any party may file the notice. Such notice shall state the name, address and telephone number of the mediator selected; state the rate of compensation of the mediator; state that the mediator and opposing counsel have agreed upon the selection and rate of compensation; and state that the mediator is certified pursuant to these Rules. B. Nomination and The County of Davidson Approval of a Non -Certified Mediator. The parties may select a mediator who does not meet the certification requirements of these Rules but who, in the opinion of the parties and The County of Davidson is otherwise qualified by training or experience to mediate the action. If the parties select a non -certified mediator, the requesting party shall file with The County of Davidson a Nomination of Non -Certified Mediator within 10 days of the request. Such nomination shall state the name, address and telephone number of the mediator; state the training, experience or other qualifications of the mediator; state the rate of compensation of the mediator; and state that the mediator and opposing counsel have agreed upon the selection and rate of compensation. The County of Davidson shall rule on said nomination, shall approve or disapprove of the parties' nomination and shall notify the parties of its decision. C. Appointment of Mediator by the County of Davidson. If the parties cannot agree upon the selection of a mediator, the party or party's attorney shall notify The County of Davidson and request, on behalf of the parties, that The County of Davidson appoint a mediator. The request for appointment must be filed within 10 days after request to mediate and shall state that the parties have had a full and frank discussion concerning the selection of a mediator and have been unable to agree. The request shall state whether any party prefers a certified attorney mediator, and if so, The County of Davidson shall appoint a certified attorney mediator. If no preference is expressed, The County of Davidson may appoint a certified attorney mediator or a certified non -attorney mediator. D. Mediator Information Directory. To assist the parties in the selection of a mediator by agreement, the parties are free to utilize the list of certified mediators maintained in any county participating in the Superior Court Mediation Settlement Conference Program . E. Disqualification of Mediator. Any party may request replacement of the mediator by The County of Davidson for good cause. Nothing in this provision shall preclude mediators from disqualifying themselves. 3 RULE 3. THE MEDIATED SETTLEMENT CONFERENCE A. Where Conference is to be Held. The mediated settlement conference shall be held in The County of Davidson. The mediator shall be responsible for reserving a place and making arrangements for the conference and for giving timely notice of the time and location of the conference to all attorneys, unrepresented parties and other persons and entities required to attend. B. When Conference is to be Held. The deadline for completion of the mediation shall be not less than 30 days nor more than 60 days after the naming of the mediator. C. Request to Extend Deadline for Completion. A party, or the mediator, may request The County of Davidson extend the deadline for completion of the conference. Such request shall state the reasons the extension is sought and shall be served by the moving party upon the other parties and the mediator. If any party does not consent to the request said party shall promptly communicate its objection to The County of Davidson. The County of Davidson may grant the request by setting a new deadline for completion of the conference. D. Recesses. The mediator may recess the conference at any time and may set times for reconvening. If the time for reconvening is set before the conference is recessed, no further notification is required for persons present at the conference. E. The mediated settlement conference shall not be cause for the delay of the construction proiect which is the focus of the dispute. rd RULE 4. DUTIES OF PARTIES AND OTHER PARTICIPANTS IN FORMAL DISPUTE RESOLUTION PROCESS A. Attendance. All parties to the dispute originally presented to the Designer or Prime Contractor for initial resolution must attend the mediation. Failure of a party to a construction contract to attend the mediation will result in The County of Davidson's withholding of monthly payment to that party until such party attends the mediation. 2. Attendance shall constitute physical attendance, not by telephone or other electronic means. Any attendee on behalf of a party must have authority from that party to bind it to any agreement reached as a result of the mediation. 3. Attorneys on behalf of parties may attend the mediation but are not required to do so. 4. Sureties or insurance company representatives are not required to attend the mediation unless any monies paid or to be paid as a result of any agreement reached as a result of mediation require their presence or acquiescence. If such agreement or presence is required, then authorized representatives of the surety or insurance company must attend the mediation. B. Finalizing Agreement. If an agreement is reached in the conference, parties to the agreement shall reduce the terms to writing and sign it along with their counsel. C. Mediation Fee. The mediation fee shall be paid in accordance with N.C.G.S. 143- 128.1(g). D. Failure to compensate mediator. Any party's failure to compensate the mediators in accordance with N.C.G.S. 143-128.1(g) shall subject that party to a withholding of said amount of money from the party's monthly payment by The County of Davidson. 5 RULE 5. AUTHORITY AND DUTIES OF MEDIATORS A. Authority of Mediator. 1. Control of Conference. The mediator shall at all times be in control of the conference and the procedures to be followed. 2. Private Consultation. The mediator may communicate privately with any participant or counsel prior to and during the conference. The fact that private communications have occurred with a participant shall be disclosed to all other participants at the beginning of the conference. 3. Scheduling the Conference. The mediator shall make a good faith effort to schedule the conference at a time that is convenient with the participants, attorneys and mediator. In the absence of agreement, the mediator shall select the date for the conference. B. Duties of Mediator 1. The mediator shall define and describe the following at the beginning of the conference: a. The process of mediation; b. The difference between mediation and other forms of conflict resolution; C. The costs of the mediated settlement conference; d. That the mediated settlement conference is not a trial, the mediator is not a judge, and the parties retain their legal rights if they do not reach settlement; e. The circumstances under which the mediator may meet and communicate privately with any of the parties or with any other person; f. Whether and under what conditions communications with the mediator will be held in confidence during the conference; g. The inadmissibility of conduct and statements as provided by N.C.G.S. 7A-38.1; h. The duties and responsibilities of the mediator and the participants; and i. That any agreement reached will be reached by mutual consent. 2. 2. Disclosure. The mediator has a duty to be impartial and to advise all participants of any circumstance bearing on possible bias, prejudice or partiality. 3. Declaring Impasse. It is the duty of the mediator to timely determine that an impasse exists and that the conference should end. 4. Reporting Results of Conference. The mediator shall report to The County of Davidson within 10 days of the conference whether or not an agreement was reached by the parties. If an agreement was reached, the report shall state the nature of said agreement. The mediator's report shall inform The County of Davidson of the absence of any party known to the mediator to have been absent from the mediated settlement conference without permission. The County of Davidson may require the mediator to provide statistical data for evaluation of the mediated settlement conference program. 5. Scheduling. and Holding the Conference. It is the duty of the mediator to schedule the conference and conduct it prior to the deadline of completion set by the Rules. Deadlines for completion of the conference shall be strictly observed by the mediator unless said time limit is changed by a written order from The County of Davidson. RULE 6. COMPENSATION OF THE MEDIATOR A. By Agreement. When the mediator is stipulated by the parties, compensation shall be as agreed upon between the parties and the mediator provided that the provision of N.C.G.S. 143-128.1(g) are observed. B. By Apmointment. When the mediator is appointed by The County of Davidson, the parties shall compensate the mediator for mediation services at the rate in accordance with the rate charged for Superior Court mediation. The parties shall also pay to the mediator a one-time per case administrative rate in accordance with the rate charged for Superior Court mediation, which is due upon appointment. 7 RULE 7. MEDIATOR CERTIFICATION. All mediators certified in the Formal Dispute Resolution Program shall be properly certified in accordance with the rules certifying mediators in Superior Court in North Carolina. (Except when otherwise allowed by The County of Davidson upon the request of the parties to the mediation.) When selecting mediators, the parties may designate a preference for mediators with a background in construction law or public construction contracting. Such requirements, while preferred, are not mandatory under these Rules. All mediators chosen must either demonstrate they are certified in accordance with the Rules Implementing Scheduled Mediated Settlement Conference in Superior Court or must gain the consent of The County of Davidson to mediate any dispute in accordance with these Rules. RULE 8. RULE MAKING. These Rules are subject to amendment by The County of Davidson at any time the County deems it appropriate. RULE 9. TIME LIMITS. Any time limit provided for by these Rules may be waived or extended by the mediator it appoints for good cause shown. If the mediator has not yet been appointed, the Designer of Record shall decide all waivers or extensions of time for good cause shown. H U O H 0 c ti � e 0 O •• 9 y n � W F3 F y M O A 6 � ° Z 0 z° � � d G O o o v o. � � t 9 a w a 6 � m Q1 ¢ > w s. � C 6 O w° G C T U O H 0 ti e H •• 9 y n � W y 6 e 5 A 6 � ° 0 0 g � � O O � €an � � 1 9 a 6 � A u ❑ 6 rp � C 6 O G C T o + T 6 ❑ c c c 4 d" a❑ fi le 2 E u ❑ a O } C mc�'9 xxz�a�y� a m z z V U U v a e Z Z Z V c ¢ a s a u Ci 0 e •• •• E•• E y 5 A 6 5 0 0 g 5 � O O � O a 6 � A u tq 6 v� L L O G C T 6 c c c 4 a O a m z v a e •• •• E•• E 5 A 6 5 0 0 5 � O O � O a 6 � A u tq 6 v� L L G C T c c c 4 e c A 6 a MW `a AF a Mill 11111111111111111111111111111 A F 'a 16 f� 0 O 0 w N O z Z O U %Q F Z O U W Q F N 0 d )pW F 6' a O >U 2 W 1' U m jF Z = E Z 0 w D L O � N � L �= t O GS `o O � C — O �y w —0 p j C Q O m nw£ P D C d y d O m � Y E � T m M O C 2Enm N 7 £ O � O U y;o 0 C £ oor m O 8m _ V O Q y m n O 0 t m O W� d .1 LD m � L 0 � m m O m Eqo, O�nc c C d a o a x N oZ 5 m i L p C O n U N ca nc x o _ =c£ m ami E o .t a n n x m c m C y v Oma > n v S m m t � m n> 0 N � .0 N r x m - 2 E mL 0 T D _y £ E 0 a v c w a 0 I ffi h i Certificate of Substantial Completion Project: Owner. I Dwners Comma No.:: Davidson County comma: Engineer's Projea No.: This [tentative] [definitive] Certificate of Substantial Completion applies to: ❑ All Work under the Contract Documents: ❑ The following specified portions: Date of Substantial Completion The Work to which this Certificate applies has been inspected by authorized representatives of Owner, Contractor and Engineer, and found to be substantially complete. The Date of Substantial Completion of the Project or portion thereof designated above is hereby declared and is also the date of commencement of applicable warranties required by the Contract Documents, except as stated below. A [tentative] [revised tentative] [definitive] list of items to be completed or corrected, is attached hereto. This list may not be all- inclusive, and the failure to include any items on such list does not alter the responsibility of the Contractor to complete all Work in accordance with the Contract Documents. The responsibilities between OWNER and CONTRACTOR for security, operation, safety, maintenance, heat, utilities, Insurance and warranties shall be as provided in the Contract Documents except as amended as follows: ❑ Amended Responsibilities ❑ Not Amended Owner's Amended Responsibilities: Contractor's Amended Responsibilities: The following documents are attached to and made part of this Certificate: This Certificate does not constitute an acceptance of Work not in accordance with the Contract Documents nor is it a release of Contractor's obligation to complete the Work in accordance with the Contract Documents. Executed by Engineer Date Accepted by Contractor Date Amepted by Owner Date 3097-F: 04/20/15 00625-1 Certificate of Substantial Completion EJCDC No. C-625 (2007 Edition) Prepared by the Engineers' Joint Contract Documents Committee and endorsed by the Construction Specifications Institute. Date of Issuance: Project: Contract: Contractor: Effective Date: Contract No.: of Contract: Project No.: Change Order No. The Contract Documents are modified as follows upon execution of this Change Order: Description: Attachments (list documents supporting change): CHANGE IN CONTRACT PRICE: CHANGE IN CONTRACT TIMES: Original Contract Price: Original Contract Times: ❑ Working days ❑ Calendar days Substantial completion (days or date): $ Ready for final payment (days or date): [Increase] [Decrease] from previously approved [Increase] [Decrease] from previously approved Change Orders Change Orders No. to No. No. to No. Contract Price prior to this Change Order: [Increase] [Decrease] of this Change Order: Substantial completion (days): _ Ready for final payment (days): Contract Times prior to this Change Order: Substantial completion (days or date): _ Ready for final payment (days or date): _ [Increase] [Decrease] of this Change Order: Substantial completion (days or date): Ready for final payment (days or date): Contract Price incorporating this Change Order: Contract Times with all approved Change Orders: Substantial completion (days or date): _ Ready for final payment (days or date): RECOMMENDED: ACCEPTED: ACCEPTED: LE Engineer (Authorized Signature) Date: LE Owner (Authorized Signature) Date: Approved by Funding Agency (if applicable): LE Contractor (Authorized Signature) Date: Date: EJCDC C-941 Change Order Change Order No. [ ] Prepared by the Engineers Joint Contract Documents Committee and endorsed by the Construction Specifications Institute. Page 1 of 2 Change Order Instructions A. GENERAL INFORMATION This document was developed to provide a uniform format for handling contract changes that affect Contract Price or Contract Times. Changes that have been initiated by a Work Change Directive must be incorporated into a subsequent Change Order if they affect Price or Times. Changes that affect Contract Price or Contract Times should be promptly covered by a Change Order. The practice of accumulating Change Orders to reduce the administrative burden may lead to unnecessary disputes. If Milestones have been listed in the Agreement, any effect of a Change Order thereon should be addressed. For supplemental instructions and minor changes not involving a change in the Contract Price or Contract Times, a Field Order should be used. B. COMPLETING THE CHANGE ORDER FORM Engineer normally initiates the form, including a description of the changes involved and attachments based upon documents and proposals submitted by Contractor, or requests from Owner, or both. Once Engineer has completed and signed the form, all copies should be sent to Owner or Contractor for approval, depending on whether the Change Order is a true order to the Contractor or the formalization of a negotiated agreement for a previously performed change. After approval by one contracting party, all copies should be sent to the other party for approval. Engineer should make distribution of executed copies after approval by both parties. If a change only applies to price or to times, cross out the part of the tabulation that does not apply. EJCDC C -vat Change order Change Order No. [ ] Prepared by the Engineers Joan Contract Documents Co ttee and eralmed by the Consnuc[ion Specifications hnsshnne. Pane 2 of 2 RUNRR North Carolina Department of Environment and Natural Resources Pat McCrory Governor March 17, 2015 Mr. Alan Carson, Manager City of Lexington 28 West Center Street Lexington, NC 27292 Subject: Permit No. WQ0037658 City of Lexington Old Salisbury Road Sewer Wastewater Collection System Extension Permit Davidson County Dear Mr. Carson: Donald R. van der Vaart Secretary In accordance with your application received March 12, 2015, we are forwarding herewith Permit No. WQ0037658 dated March 17, 2015, to the City of Lexington (Permittee) for the construction and operation upon certification of the subject wastewater collection system extension. This permit shall be effective from the date of issuance until rescinded and shall be subject to the conditions and limitations as specified therein. This cover letter shall be considered a part of this permit and is therefore incorporated therein by reference. Please pay particular attention to the following conditions contained within this permit: Condition I.1: This permit shall not be automatically transferable; a request must be made and approved. Condition IA: Requires that the wastewater collection facilities be properly operated and maintained in accordance with 15A NCAC 2T.0403 or any individual system -wide collection system permit issued to the Permittee. It shall be responsibility of the Permittee to ensure that the as -constructed project meets the appropriate design criteria and rules. Failure to comply may result in penalties in accordance with North Carolina General Statute §143-215.6A through §143-215.6C, construction of additional or replacement wastewater collection facilities, and/or referral of the North Carolina -licensed Professional Engineer to the licensing board. 450 West Hanes Mill Road, Suite 300, Winston-Salem, NC 27105 Phone: 336-776-9800 \ Internet: www.ncwatercluality.org An Equal Opportunity \ Affirmative Action Employer—Made in part by recycled paper City of Lexington Permit No. WO0037658 If any parts, requirements, or limitations contained in this permit are unacceptable, you have the right to request an adjudicatory hearing upon written request within 30 days following receipt of this permit. This request must be in the form of a written petition, conforming to Chapter 1506 of North Carolina General Statutes, and filed with the Office of Administrative Hearings, 6714 Mail Service Center, Raleigh, NC 27699-6714. Unless such demands are made, this permit shall be final and binding. If you need additional information concerning this matter, please contact Mike Mickey at (336) 776- 9697 or via e-mail at mike.mickey@ncdenr.gov. Sincerely, for S. Jay Zimmerman, Director Division of Water Resources, NCDENR by Sherri V. Knight, PE, Assistant Regional Supervisor Water Quality Regional Operations Section Winston-Salem Regional Office Division of Water Resources, NCDENR cc: John Grey, PE (The Wooten Company, 350 N, Cox Street, Suite 26, Asheboro, NC 27203) Winston-Salem Regional Office Files Water Resources Central Files PERCS (electronic copy) Page 2 of 8 A NCDENR STATE OF NORTH CAROLINA ENVIRONMENTAL MANAGEMENT COMMISSION DEPARTMENT OF ENVIRONMENTAND NATURAL RESOURCES WASTEWATER COLLECTION SYSTEM EXTENSION PERMIT In accordance with the provisions of Article 21 of Chapter 143, General Statutes of North Carolina as amended, and other applicable Laws, Rules, and Regulations, permission is hereby granted to the City of Lexington Davidson County for the construction and operation of approximately 2,991 linear feet of 8 -inch gravity sewer to serve a 90 employee business as part of the Old Salisbury Road Sewer project, and the discharge of 3,150 gallons per day of collected domestic wastewater into the City of Lexington's existing sewerage system, pursuant to the application received March 12, 2015, and in conformity with 15A NCAC 2T; the Division's Gravity Sewer Minimum Design Criteria adopted February 12, 1996 as applicable; the Division's Minimum Design Criteria for the Fast -Track Permitting of Pump Stations and Force Mains adopted June 1, 2000 as applicable; and other supporting data subsequently filed and approved by the Department of Environment and Natural Resources and considered a part of this permit. This permit shall be effective from the date of issuance until rescinded and shall be subject to the specified conditions and limitations contained therein. for S. Jay Zimmerman, Director Division of Water Resources, NCDENR By Authority of The Environmental Management Commission Permit Number: WQ0037658 Permit Issued: March 17, 2015 Page 3 of 8 SUPPLEMENT TO PERMIT COVER SHEET City of Lexington is hereby authorized to: Construct, and then operate upon certification the aforementioned wastewater collection extension. The sewage and wastewater collected by this system shall be treated in the City of Lexington Wastewater Treatment Facility in accordance with Permit Number NC0055786. Permitting of this project does not constitute an acceptance of any part of the project that does not meet 15A NCAC 2T; the Division's Gravity Sewer Minimum Design Criteria adopted February 12, 1996 as applicable; and the Division's Minimum Design Criteria for the Fast -Track Permitting of Pump Stations and Force Mains adopted June 1, 2000 as applicable, unless specifically mentioned herein. Division approval is based on acceptance of the certification provided by a North Carolina -licensed Professional Engineer in the application. It shall be the Permittee's responsibility to ensure that the as -constructed project meets the appropriate design criteria and rules. Construction and operation is contingent upon compliance with the Standard Conditions identified below. II. STANDARD CONDITIONS 1. This permit shall not be transferable. In the event there is a desire for the wastewater collection facilities to change ownership, or there is a name change of the Permittee, a formal permit request shall be submitted to the Division accompanied by documentation from the parties involved, and other supporting materials as may be appropriate. The approval of this request shall be considered on its merits and may or may not be approved. [15A NCAC 027.0104; G.S 143-215.1(d3)) 2. This permit shall become voidable unless the wastewater collection facilities are constructed in accordance with the conditions of this permit; 15A NCAC 2T; the Division's Gravity Sewer Minimum Design Criteria adopted February 12, 1996 as applicable; the Division's Minimum Design Criteria for the Fast -Track Permitting of Pump Stations and Force Mains adopted lune 1, 2000 as applicable; and other supporting materials unless specifically mentioned herein. [15A NCAC 02T.0110) 3. This permit shall be effective only with respect to the nature and volume of wastes described in the application and other supporting data. [15A NCAC 02T.01101 4. The wastewater collection facilities shall be properly maintained and operated at all times. The Permittee shall maintain compliance with an individual system -wide collection system permit for the operation and maintenance of these facilities as required by 15A NCAC 2T .0403. If an individual permit is not required, the following performance criteria shall be met: [15A NCAC 02T .0108(b)]: The sewer system shall be effectively maintained and operated at all times to prevent discharge to land or surface waters, and to prevent any contravention of groundwater standards or surface water standards. b. A map of the sewer system shall be developed and shall be actively maintained. Page 4 of 8 c. An operation and maintenance plan including pump station inspection frequency, preventative maintenance schedule, spare parts inventory and overflow response has been developed and implemented. d. Pump stations that are not connected to a telemetry system shall be inspected every day (i.e. 365 days per year). Pump stations that are connected to a telemetry system shall be inspected at least once per week. e. High-priority sewer lines shall be inspected at least once per every six -months and inspections are documented. f. A general observation of the entire sewer system shall be conducted at least once per year. g. Overflows and bypasses shall be reported to the appropriate Division regional office in accordance with 15A NCAC 2B .0506(a), and public notice shall be provided as required by North Carolina General Statute 4143-215.1C. h. A Grease Control Program is in place as follows: 1. For public owned collection systems, the Grease Control Program shall include at least biannual distribution of educational materials for both commercial and residential users and the legal means to require grease interceptors at existing establishments. The plan shall also include legal means for inspections of the grease interceptors, enforcement for violators and the legal means to control grease entering the system from other public and private satellite sewer systems. 2. For privately owned collection systems, the Grease Control Program shall include at least bi- annual distribution of grease education materials to users of the collection system by the permittee or its representative. 3. Grease education materials shall be distributed more often than required in Parts (1) and (2) of this Subparagraph if necessary to prevent grease -related sanitary sewer overflows. Right-of-ways and easements shall be maintained in the full easement width for personnel and equipment accessibility. j. Documentation shall be kept for Subparagraphs (a) through (i) of this Rule for a minimum of three years with exception of the map, which shall be maintained for the life of the system. 5. The Permittee shall report by telephone to a water resources staff member at the Winston-Salem Regional Office, telephone number (336) 776-9800, as soon as possible, but in no case more than 24 hours, following the occurrence or first knowledge of the occurrence of either of the following: a. Any process unit failure, due to known or unknown reasons, that renders the facility incapable of adequate wastewater transport, such as mechanical or electrical failures of pumps, line blockage or breakage, etc.; or b. Any S50 and/or spill over 1,000 gallons; or c. Any SSO and/or spill, regardless of volume, that reaches surface water Page 5 of 8 Voice mail messages or faxed information is permissible, but this shall not be considered as the initial verbal report. Overflows and spills occurring outside normal business hours may also be reported to the Division of Emergency Management at telephone number (800) 858-0368 or (919) 733-3300. Persons reporting any of the above occurrences shall file a spill report by completing and submitting Part I of Form CS-SSO (or the most current Division approved form) within five days following first knowledge of the occurrence. This report must outline the actions taken or proposed to be taken to ensure that the problem does not recur. Part II of Form CS-SSO (or the most current Division approved form) can also be completed to show that the SSO was beyond control. [G.S. 143- 215.1C(al)] 6. Construction of the gravity sewers, pump stations, and force mains shall be scheduled so as not to interrupt service by the existing utilities nor result in an overflow or bypass discharge of wastewater to the surface waters of the State. [15A NCAC 02T.0108(b)] 7. Upon completion of construction and prior to operation of these permitted facilities, the completed Engineering Certification form attached to this permit shall be submitted with the required supporting documents to the address provided on the form. A complete certification is one where the form is fully executed and the supporting documents are provided as applicable. Any wastewater flow made tributary to the wastewater collection system extension prior to completion of this Engineer's Certification shall be considered a violation of the permit and shall subject the Permittee to appropriate enforcement actions. If the permit is issued to a private entity with an Operational Agreement, then a copy of the Articles of Incorporation, Declarations/Covenants/Restrictions, and Bylaws that have been appropriately filed with the applicable County's Register of Deeds office shall be submitted with the certification. A complete certification is one where the form is fully executed and the supporting documents are provided as applicable. Supporting documentation shall include the following: a. One copy of the project construction record drawings (plan & profile views of sewer lines & force mains) of the wastewater collection system extension. Final record drawings should be clear on the plans or on digital media (CD or DVD disk) and are defined as the design drawings that are marked up or annotated with after construction information and show required buffers, separation distances, material changes, etc. b. One copy of the supporting applicable design calculations including pipe and pump sizing, velocity, pump cycle times, and level control settings, pump station buoyancy, wet well storage, surge protection, detention time in the wet well, and force main, ability to flush low points in force mains with a pump cycle, and downstream sewer capacity analysis. If a portable power source or pump is dedicated to multiple stations, an evaluation of all the pump stations' storage capacities and the rotation schedule of the portable power source or pump, include travel timeframes, shall be provided. c. Changes to the project that do not result in non-compliance with this permit, regulations, or the Minimum Design Criteria should be clearly identified on the record drawings, on the certification in the space provided, or in written summary form. Page 6 of 8 Prior to Certification (Final or Partial): Permit modifications are required for any changes resulting in non-compliance with this permit (including pipe length increases of 10% or greater, increased flow, pump station design capacity design increases of 5% or greater, and increases in the number/type of connections), regulations, or the Minimum Design Criteria. Requested modifications or variances to the Minimum Design Criteria will be reviewed on a case-by-case basis and each on its own merit. Please note that variances to the Minimum Design Criteria should be requested and approved during the permitting process prior to construction. After -construction requests are discouraged by the Division and may not be approved, thus requiring replacement or repair priorto certification & activation. [15A NCAC 02T.0116] 8. Gravity sewers installed greater than ten percent below the minimum required slope per the Division's Gravity Sewer Minimum Design Criteria shall not be acceptable and shall not be certified until corrected. If there is an unforeseen obstacle in the field where all viable solutions have been examined, a slope variance can be requested from the Division with firm supporting documentation. This shall be done through a permit modification with fee. Such variance requests will be evaluated on a case-by-case basis. Resolution of such request shall be evident prior to completing and submitting the construction certification. [ 15A NCAC 02T.0105(n)] 9. A copy of the construction record drawings shall be maintained on file by the Permittee for the life of the wastewater collection facilities. [15A NCAC 02T.01161 10. Failure to abide by the conditions and limitations contained in this permit; 15A NCAC 2T; the Division's Gravity Sewer Design Criteria adopted February 12, 1996 as applicable; the Division's Minimum Design Criteria for the Fast -Track Permitting of Pump Station and Force Mains adopted June 1, 2000 as applicable; and other supporting materials may subject the Permittee to an enforcement action by the Division, in accordance with North Carolina General Statutes §143-215.6A through §143-215.60, construction of additional or replacement wastewater collection facilities, and/or referral of the North Carolina -licensed Professional Engineer to the licensing board. [15A NCAC 02T.0104; 15A NCAC 02T .0108(b -c)] 11. In the event that the wastewater collection facilities fail to perform satisfactorily, including the creation of nuisance conditions, the Permittee shall take immediate corrective action, including those as may be required by this Division, such as the construction of additional or replacement facilities. [15A NCAC 02T.0110; 15A NCAC 02T .0108(b)] 12. The issuance of this permit shall not exempt the Permittee from complying with any and all statutes, rules, regulations, or ordinances that may be imposed by the Division any other Federal, State, or Local government agencies which have jurisdiction or obtaining other permits which maybe required by the Division or any other Federal, State, of Local government agencies. [G.S. 143-215.1(b)] Page 7 of 8 FAST TRACK SEWER ENGINEERING CERTIFICATION PERMITTEE: City of Lexington PERMIT#: WQ0037658 PROJECT: Old Salisbury Road Sewer ISSUE DATE: March 17, 2015 This project shall not be considered complete nor allowed to operate in accordance with Condition 7 of this permit until the Division has received this Certification and all required supporting documentation. It should be submitted in a manner that documents the Division's receipt. Send the required documentation the Regional Supervisor, Water Quality Regional Operations Section at the address at the bottom. Any wastewater flow made tributary to the wastewater collection system extension prior to completion of this Certification shall be considered a violation of the permit and shall subject the Permittee to appropriate enforcement actions. The Permittee is responsible for tracking all partial certifications up until a final certification is received. A Final Certification shall be a complete set of record drawings and design calculations regardless of whether partials have been submitted. PERMITTEES CERTIFICATION I, the undersigned agent for the Permittee, hereby state that this project has been constructed pursuant to the applicable standards & requirements, the Professional Engineer below has provided applicable design/construction information to the Permittee, and the Permittee is prepared to operate & maintain the wastewater collection system permitted herein or portions thereof. Printed Name, Title Signature Date ENGINEER'S CERTIFICATION I, as a dui registered Professional En ineer in the State of North Carolina, having been authorized to observe (periodically, ❑ weekly, "full time) the construction of the project name and location as referenced above for the above Permittee hereby state that, to the best of my abilities, due care and diligence was used in the observation of the construction such that the construction was observed to be built within substantial compliance of this permit; 15A NCAC 02T; the Division of Water Resources' (Division) Gravity Sewer Minimum Design Criteria adopted February 12, 1996 as applicable; the Division's Minimum Design Criteria for the Fast -Track Permitting of Pump Stations and Force Mains adopted June 1, 2000 as applicable; and other supporting materials. North Carolina Professional Engineer's Seal w/signature & date: ❑ Final ❑ Partial (include description) Certification Comments/Qualifiers (attach if necessary): NC DAR - Water Quality Regional Operations Section 450 West Hanes Mill Road, Suite 300, Winston-Salem, NC 27105 Winston-Salem Regional Office Phone: (336) 776-9800 FAX: (336)-776-9797 LWWA 4 �3 NCDENR North Carolina Department of Environment and Natural Resources Pat McCrory Governor April 22,2015 LETTER OF APPROVAL Robert Hyatt Davidson County PO Box 1067 Lexington NC 27293 RE: Project Name: Old Salisbury Road Sewer Acres Approved: 2.8 Project ID: DAVID -2015-015 County: Davidson, City: Lexington Address: Old Salisbury Road River Basin: Yadkin -Pee Dee Stream Classification: Other Submitted By: Robert Hyatt Date Received by LQS: Apri120, 2015 Plan Type: Utilities - Revised Dear Mr. Hyatt: Donald R. van der Vaart Secretary RECEIVED APR 2 71015 The Wooten Company Asheboro Branch This office has reviewed the subject erosion and sedimentation control plan. We find the plan to be acceptable and hereby issue this Letter of Approval. The enclosed Certificate of Approval must be posted at the job site. This plan approval shall expire three (3) years following the date of approval, if no land -disturbing activity has been undertaken, as is required by Title 15A NCAC 4B.0129. Please be aware that your project will be covered by the enclosed NPDES Construction Stormwater General Permit NCG010000. Please become familiar with all the requirements and conditions of this permit in order to achieve compliance. Title 15A NCAC 4B .0118(a) requires that a copy of the approved erosion control plan be on file at the job site. Also, this letter gives the notice required by G.S. 113A -61.1(a) of our right of periodic inspection to insure compliance with the approved plan. Division of Energy, Mineral, and Land Resources Energy Section • Geological Survey Section • Land Quality Section 450 West Hanes Mill Road, Suite 300, Winston-Salem, NC 27105• Phone: 336-776-9800 • FAX: 336-776-9798 Intemet: htta:lloortad.nodenr.orahvebhrt An Equal Opportunity 1 Affirmative Action Employer - 50% Recycled 110% Post Consumer Paper Letter of Approval Robert Hyatt April 22, 2015 Page 2 of 2 North Carolina's Sedimentation Pollution Control Act is performance -oriented, requiring protection of existing natural resources and adjoining properties. If, following the commencement of this project, the erosion and sedimentation control plan is inadequate to meet the requirements of the Sedimentation Pollution Control Act of 1973 (North Carolina General Statute 113A-51 through 66), this office may require revisions to the plan and implementation of the revisions to insure compliance with the Act. Acceptance and approval of this plan is conditioned upon your compliance with Federal and State water quality laws, regulations, and rules. In addition, local city or county ordinances or rules may also apply to this land -disturbing activity. This approval does not supersede any other permit or approval. Please note that this approval is based in part on the accuracy of the information provided in the Financial Responsibility Form, which you provided. You are requested to file an amended form if there is any change in the information included on the form. In addition, it would be helpful if you nog fy this ,offs ef�therproposed starting date for this project. Please notify us if you plan to have $ Preconstr A5ikrence. Your cooperation is:appreciated. Sincerely, Matthew E. Gantt, PE Regional Engineer Land Quality Section Enclosures: Certificate of Approval NPDES Permit cc: John Grey, P.E. The Wooten Company 350 North Cox Street, Suite 26 Asheboro, NC 27203 RECEIVED Meo STATE OF NORTH CAROLINA APR 0 8 2915 DEPARTMENT OF TRANSPORTA'/ooten Company PAT MCCRORY Ashe OMMATA GOVERNOR SECRETARY April 1, 2015 Davidson County Subject: Right -of -Way Encroachment Contract —R/W 16.6 SR 1353 — Park Drive Davidson County and the City of Lexington Encroachment No. 15 -024 -DE Mr. John Grey The Wooten Company 350 North Cox Street Suite 26 Asheboro, NC 27203 Dear Mr. Grey: Attached hereto, for your file, is a copy of a properly executed Right -of -Way Encroachment Contract. This contract covers the following: Installation of 50 LF of 18" steel encasement and 8" DIP sewer line crossing SR 1353 — Park Drive, in Davidson County. Approval is granted subject to the following conditions: I. Written notice shall be given to Chris T. Corriher, P. E., District Engineer, at 4770 South Main Street, Salisbury, NC 28147-9386 at least five (5) working days prior to beginning of work. 2. Written notice shall be given to Chris T. Corriher, P. E., District Engineer, at 4770 South Main Street, Salisbury, NC 28147-9386 when all work contained herein has been completed. 3. Any work requiring equipment or personnel within five feet (5') of the edge of the travel lane shall require a lane closure with appropriate tapers. 4. That during installation, proper traffic control devices, signs, etc. be installed to ensure public safety in accordance with the latest edition of the Manual on Uniform Traffic Control Devices and any supplements thereto. Substandard traffic control at the construction site will result in the immediate suspension of the work being done. 5. That all materials and workmanship shall conform to the NCDOT Standard Specifications for Roads and Structures manual. 6. That all disturbed areas are to be fully restored to the N.C. Department of Transportation's minimum roadway standards. R E C F I V52�C 7. Excavations shall not be left open or unsafe overnight. APR 0 2 2995 Div. 9 ulaiQ,w office DIVISION 9— 375 SILAS CREEK PARKWAY, WINSTON SALEM, NC 27127 Telephone: 336-747-7800 Fax: 336-703-6693 A " Mr Grey Pagetwo April 1, 2015 i ' 8. The Department of Tgatisporta6on does not guarantee the right of way on this road, nor will it be `res nsi6le,fo a4 claim for damages brought po r'�f� g gh by any property owner by reason of the installation. 9. The grade of top of pipe or casing within highway rights of way shall provide minimum burial as follows: a. Longitudinal installations ------------------- ---- ------ -------- 3 feet b. Crossings under roadways (below travel surface) ------------- 3 feet c. Crossings under ditches (paved and unpaved) ----------------- 2 feet 10. That any driveway or drainage structure disturbed or damaged shall be restored to its original condition as directed by the County Maintenance Engineer. 11. That vehicle circulation on site shall not restrict or impede the ingress flow of traffic. 12. An executed copy of this encroachment agreement shall be present at the construction site at all times during construction. if safety, traffic conditions or utility location warrant such an action, NCDOT reserves the right to further limit, restrict or suspend operations within the right of way. 13. The trench backfill material should meet the Statewide Borrow Criteria. The trench should be backfilled in accordance with Section 300-7 of the 2000 NCDOT Standard Speciflcarions for Roads and Structures, which basically requires the backfill material to be placed in layers not to exceed 6 inches loose and compacted to at least 95% of the density obtained by compacting a sample in accordance with AASHTO T99 as modified by NCDOT. 14. All excavations must be outside the theoretical 1:1 slope from the existing edge of pavement to the bottom of the nearest excavation wall. 15. The encroaching party (not the utility contractor) should make arrangements to have a qualified inspector, under the supervision of a Professional Engineer registered in North Carolina, on site at all times. The Professional Engineer shall be required to certify that the utility was installed in accordance with the encroachment agreement. 16. The length of the parallel excavation should be limited to the length necessary to install and backfill one joint of pipe at a time, not to exceed twenty-five (25) feet. 17. Vegetative cover shall be established on all disturbed areas in accordance with the recommendations of the Division Roadside Environmental Engineer. 18. Temporary and permanent measures shall be used to control erosion and sedimentation in accordance with local, State, and Federal regulations. 19. All roadway signs that are removed due to construction shall be reinstalled as soon as possible. 20. No access, parking or material storage shall be allowed on NCDOT right of way. 21. During non -working hours equipment shall be parked as close to the right of way line as possible and be properly barricaded in order not to have any equipment obstruction within the Clear Recovery Area. 22. That the installation will not adversely affect or interfere with the normal maintenance of the roadway, ditches, or shoulders. Mr. Grey Page three April 1, 2015 23. That any vault, valve or meter box, hydrant or other appurtenances be located at the right-of-way line. 24. Any construction beyond the property limits of the encroaching party and the N. C. Department of Transportation will require an encroachment agreement with the property owners involved. 25. Excavated material shall not be placed on the pavement. Drainage structures shall not be blocked with excavated materials. 26. The encroaching party is required to contact the appropriate Utility Companies involved and make satisfactory arrangements to adjust the utilities in conflict with the proposed work prior to beginning construction. 27. Ingress and egress shall be maintained to all businesses and dwellings affected by the project. Special attention shall be paid to police and fire stations, fire hydrants and hospitals. 28. It is the responsibility of the contractor to prevent any mud/dirt from tracking onto the roadway. Any dirt which may collect on the roadway pavement from equipment and / or truck traffic on site shall be removed to avoid any unsafe traffic conditions. 29. The encroaching party shall comply with all state and federal environmental regulations, and shall obtain all necessary state and federal environmental permits, including but not limited to, those related to sediment control, stormwater, wetland, streams, endangered species, and historical sites. 30. The Contractor shall be limited to working during daylight hours only unless approved by the District Engineer. 31. Strict compliance with the Policies and Procedures for Accommodating Utilities on Highway Rights - of -Way manual shall be required. 32. That prior to beginning construction, a meeting with Mr. Mark Crook, County Maintenance Engineer, (telephone -336-224-3200) be held. Failure to contact Mr. Crook prior to beginning construction and after completing the installation shall make the encroachment agreement null and void. Sincerely, S Division Engineer SPUtlb Attachment(s) cc: Mr. Chris T. Corr iher, PE, District Engineer Mr. Mark Crook, PE, County Maintenance Engineer ROUTE SR 1147, SR 1353 PROJECT Old Salisbury Rd COUNTY OF Sewer DEPARTMENT OF TRANSPORTATION -AND- Davidson CI -AND- City of Lexington STATE OF NORTH CAROLINA Davidson THREE PARTY RIGHT OF WAY ENCROACHMENT AGREEMENT ON PRIMARY AND SECONDARY SYSTEM THIS AGREEMENT, made and entered into this the I day of AM 2015 , by and between the Department of Transportation, party of the first part; and County of Davidson party of the second part; and City of Lexington party of the third part, WITNESSETH THAT WHERAS, the party of the second part desires to encroach on the right of way of the public road designated as Route SR 1147 and SR 1353, located from Old Salisbury Rd, SR 1147 southwest of the City of Lexington with the construction and/or erection of: Approximately 2,850 linear feet of 8 -inch gravity sewer pipe, gravity sewer manholes and 50 linear feet of 18 - inch steel encasement pipe bored and jacked under SR 1353 with 8 -inch DIP carrier pipe in casing. WHEREAS, it is to the materief advantage of the party of the second part to effect this encroachment, and the party of the first part in the exercise of authority conferred upon It by statute, is willing to permit the encroachment within the limits of the right of way as indicated, subject to the conditions of this agreement; NOW, THEREFORE, IT IS AGREED that the party of the first part hereby grants to the party of the second part the right and privilege to make this encroachment as shown on attached plan sheet(s), specificaflons and special provisions which are made a part hereof upon the following conditions, to vitt: That the [retaliation, operallon, and maintenance of the above described facility will be accomplished in accordance with the party of the first parts latest POLICIES AND PROCEDURES FOR ACCOMMODATING UTILITIES ON HIGHWAY RIGHTS-OF-WAY and such revisions and amendments thereto as may be In effect at the date of this agmemerd. Information as to these policies and procedures may be obtained from the Division Engineer or Slate Utility Agent of the party of the first part That the said parry of the second part binds and obligates himself to install and maintain the encroaching facility in such safe and proper condition that it will not interfere with or endanger travel upon said highway, nor obstruct nor interfere Win the proper maintenance thereof, to reimburse the party of the flrst part for the cost incurred for any repairs or maintenance to its roadways and Structures necessary due to the Installation and existence of the facilities of the party of the second pert, ant if at any time the party of the first part shall require the removal of or charges in the location of the said facilities, that the said party of the second part binds himself, his successors and assigns, to promptly remove or after the said facilities, in order to conform to the said requirement, without any cost to the party of the first part. That the party of the second part agrees to provide during construction and any subsequent maintenance proper signs, signal lights, fiagmen and other warning devices for the protection of traffic In conformance with the latest Manual on Uniform Traffic Control Devices for Streets and Hiphwevs and Amendments or Supplements thereto. Information as to the above rules and regulations may be obtained from the Division Engineer of the party of the first part That the party of the second part hereby agrees to indemnify and save harmless the pant of the first part from all damages and claims for damage that may arise by reason of the installation and maintenance of this encroachment. That the party of the second par agrees to restore et areas disturbed during irhstallation and maintenance to the satisfaction of the Division Engineer of the party of the first part. The Party of the second pert agrees to exercise every reasonable precaution during construction and maintenance to prevent eroding of soil; sifting or pollution of dve s, streams, lakes, reservoirs, other water impoundments, ground surfaces or other property; or pollution of the air. There shall be compliance with applicable rules and regulations of the North Carolina Division of Environmental Management, North Carolina Sedimentation Control Commission, and with ordinances and regulations of various counties, municipalities and other official agencies relating to pollution prevention and control. When any Installation or maintenance operation disturbs the ground surface and existing ground cover, the party of the second part agrees to remove and replace the sod or otherwise reestablish the grass cover to meet the satisfaction of the Division Engineer of the parry of the first part That the parry of the second part agrees to assume the actual cost of any inspection of the work considered to be necessary by the Division Engineer of the parry of the first Pam That the party of the second part agrees to have available at the construction site. at all limes during conviction, a copy of this agreement showing evidence of approval by the parry of the first part. The party of the first part reserves the right to stop all work unless evidence of approval can be shown. Provided the work contained in this agreement is being performed on a completed highway open to baffle the party of the second part agrees to give written notce to the Division Engineer of the party of the first part when all work contained herein has been completed. Unless specifically requested by the party of the first part, written notice of completion of work on highway projects under construction will not be required. That in the case of noncompllance with the terms of this agreement by the parry Of the Second part, the panty of the flit part reserves the right to stop all work until the facility has been brought Into compliance or removed from the right ofway at no, cost to the party of the first pert. That it Is agreed by both partes that this agreement shall become void If actual construction of Ure work contemplated herein is not begun within one (1) year from the date of authorization by the party of the first part unless written waiver is secured by the parry of the second par from the parry of the first part. During the performance of this contract, the second party, for itself. Its assignees and successors In interest (hereinafter referred to as the 'contracton ), agrees as follows: a. Compliance with Regulations: The contractor shall comply with the Regulation relative to nondiscrimination in Federally. assisted programs of the U. S. Department of Transportation, Title 49, Code of Federal Regulations, Pad 21, as they may be amended from time to time, (hereinafter referred to as the Regulations), which are herein Incorporated by reference and FORM RNV 16.6 Rev. July 1, 1977 made apart of this contract. b. Nondiscrimination: The contractor, with regard to the work performed byr: during the contract, shall not discriminate an the grounds of rats, color, or national oflgin In the selection and retention of subcontractors, including procurements of materials and leases of equipment. The contractor shall not participate either directly or indirectly in the discrimination prohibited by Section 21.5 of the Regulations, including employment practices when the contract covers a program set forth in Appendix a of the Regulations. c. Solicitations for Subcontracts includlm Procurements or Materials and Equipment In all solicitations either by competitive bidding or negotiation made by the contractor for work to be performed under a subcontract, including procurements of materials or leases of equipment, each Potential subcontractor or supplier shall be notilied by the contractor of the contractors obligations under this contract and the Regulations relative to nondiscrimination on the grounds of race, color, or national origin. all. Information and Reports: The contractor shall provide all information and reports required by the Regulations, or directives Issued pursuant thereto, and shall permit access to Its books, records, accounts, other sources of Information, and its facilities as may be determined by the Department of Transportation or the Federal Highway Administration a be pertlnerk to ascertain compliance with such Regulations or directives. Where arty Information required of a contractor is in the exclusive possession of another who falls or refuses to furnish this Information, the contractor shall so tartly to the Department of Transportation, or the Federal Highway Administration as appropriate. and shall set forth what efforts it has made to obtain the Information. e. Sanctions for Nonoomdianco: In the event of the contractors noncompliance with the nondiscrimination provisions of this contract, the Department of Transportation shall Impose such contract sanctions as it or the Federal Highway Administration may determine to be appropriate, including, but rat limited to, (1) withholding of payments to the contractor under the contract until the contractor compiles, and/or (2) cancellation, termination or suspension of the contract, In whole or in part. f. Incorporation of Provisions: The contractor shall Include the provisions of paragraphs'a' through'Y in every subcontract, including procurements of materials and leases of equipment, unless exempt by the Regulations, or directives issued pursuant thereto. The contractor shell take such action with respect a any subcontract or procurement as the Department of Transportation or the Federal Highway Administration may direct as a means of enforcing such provisions including sanctions for noncompliance: Provided, however, that, in the event a contractor becomes involved In, or is threatened with, litigation with a subcontractor or supplier as a result of such direction, the contractor may request the Department of Transportation to enter Into such litigation to protect the Interests of the Stale, and, in addition, the contractor may request the United Stales to enter Into such litigation to protect the interests of the Voted States. That when We to the subject that constitutes the aforesaid encroachment passes from the party of the second part and vests in the party of the third part, the party of the third part agrees to assume all responsibilities and rights and to perform all obligations as agreed to herein by the party of the Second part IN WITNESS WHEREOF, each of the parties to this agreement has caused the same to be executed the day and year first above written. WITNESS: � 3.2o1S 9,(� fo AL O rlr7t WITNESS: MFSA ��/. 7 .J• I Lor DEPARTMENT OF TRANSPORTATION BY: , , . _ /�. DIVWTON'ENOMEER d3 zo s R Bert C. Hyatt County Manager Alan Carson City Manager Second Party Third Party RLW (166) : Party of the Secord Part certifies that this agreement is true and accurate copy of the form RAY (166) Incorporating all revisions to data. K p/ 9 Lb FM R -L yodny ledpiunyy WIBUIXOI ZSZT '' ZBZT HBTT Zb' TTS t /sp zs ' SSTT Z6TL / csec [' F ssrr se F6iE / ZZTf' zo sna y is 't i STiT / 1. i ZTZT / 4 SSZT\ 6'� � SSET •. i6TE\ � 4� I w OTT z" / / ZTiT ro ro' LIN saTT J waaz uv�kga 9RT p� / SRT os' T [Z[ / TRT T / SRT tyu 9� �e Pfz�[ iSTi / SECTION 01100 SUMMARY OF WORK PART GENERAL 1.01 WORK COVERED BY CONTRACT DOCUMENTS A. Work described in this Project Manual includes the provision of labor, materials, equipment, and services required to complete the Old Salisbury Road Sewer project for Davidson County, North Carolina. 1.02 CONTRACTS A. Project construction will be let under one Contract with construction including, but not limited to, the following major work items: Approximately 3,100 linear feet of 8 - inch sanitary sewer and associated appurtenances. 1.03 WORK SEQUENCE A. Contractor is responsible for all bypass pumping required to construct the project as shown. Construction activities that interfere with normal operation of existing facilities shall be specifically noted on construction schedule. For each of these activities provide a detailed construction sequence showing the bypass pumping arrangement. B. Indicate switchovers and cut -ins between new work and existing facility on the construction schedule. Submit proposed date for switchover in writing to Engineer and Owner a minimum of seven (7) days and again 24 -hours in advance of actual field work. Owner shall have the right to delay Work due to operational requirements, without additional cost to Owner. C. Perform switchovers and cut -ins during low flow periods at the facility. This shall normally require night / weekend operations by Contractor at no additional compensation. 1.04 CONTRACTOR USE OF SITE A. Work is located within Rights-of-way of the NC Department of Transportation. Requirements of the owners of the rights-of-way must be complied with and specifically as required in the permits attached to Section, Supplementary General Conditions. B. Only Owner's right to perform construction and maintenance operations with its own forces and to employ separate contractors on portions of the Project limits contractor's use of site during the construction period. Work at the Project site by Owner will be coordinated with the Contractor. C. Contractor shall provide his own staging area as necessary for his Work. D. Contractor's use of the site during the construction period may be limited by Owner's necessity to operate the existing facilities. PART2 PRODUCTS Not Used 3097-F: 04/30/15 01100-1 Summary of Work PART 3 EXECUTION Not Used END OF SECTION Summary of Work 01100-2 3097-F: 04/30/15 SECTION 01270 UNIT PRICES PART GENERAL 1.01 SECTION INCLUDES A. Delineation of measurement and payment criteria applicable to Work performed under Contract by the unit price payment method. 1.02 FIELD MEASUREMENT A. Take measurements and compute quantities for submittal of the monthly pay request unless specified otherwise in the measurement paragraphs as indicated in this Section. 1.03 CHANGE IN QUANTITIES A. Increase in the quantity of a bid item above what is indicated in the Bid Form shall only be made by a Change Order as required by the Contract Documents. B. A final adjusting Change Order shall be made for adjustment of the actual quantities installed prior to submittal of the final pay request. 1.04 GENERAL A. Items with a "(X)" in the title of the following bid items represents the size or depth as indicated on the Bid Form. B. Method of measurement for the individual Bid Items shall be as specified below. C. Payment for each item shall be in accordance with the Contract Unit Price times the number of units installed in accordance with the Contract Documents. D. Work for each bid item shall include, but not be limited to, the work listed below and the labor, materials, equipment, and services required and reasonably implied by the Contract Documents for a complete installation. 1.05 MOBILIZATION (BID ITEM 1) A. Measurement shall not be made for this item. B. Work shall include administrative cost including, but not limited to, mobilization, bonds, insurance, project signage, shop drawing submittal, as -built documentation, and construction trailers. General office administration for the Project construction shall be included in the individual unit price items. C. Bid Price for Mobilization shall not exceed 3 percent of the total bid. Half of the mobilization may be requested on the first pay request and the remainder on the second. 1.06 UTILITY PIPING (BID ITEMS 2 — 13) A. Measurement: Measure horizontally or from station to station as shown or indicated on the Drawings for the various types and sizes of pipes installed. 1. (X) inch Sanitary Sewer, Depth (X) -(X) ft: Measure pipe from center to center of manholes. No deduction will be made for space occupied by manholes. Measure depth of pipe vertically from pipe invert to original grade as shown on the Drawings. 3097-F: 05/18/15 01270-1 Unit Prices B. Work shall include, but not be limited to (unless specifically noted otherwise on the Bid Form and this specification Section), the following: 1. Clearing and grubbing where necessary. 2. Traffic control. 3. Temporary removal and restoration or temporary support of, but not limited to, existing mail boxes, signs, fences, shrubs, plants (under 6 feet in height), guard rails, power and telephone poles. 4. Excavating, shoring and bracing where required, dewatering as required, installing, backfilling (including Class I material as specified for the pipe bedding, haunching, and initial backfill). 5. Installation of warning / identification tape over utilities. 6. Installation of tracer wire on non-metallic utilities. 7. Temporary support and protection of existing underground facilities. 8. Pipe, concrete blocking and encasement, connection to existing piping, and fittings. 9. Flushing and testing. 10. Repair to damaged new and existing utilities. 11. Cutting and removal of existing paved surfaces. Patching of existing paved surfaces shall be paid as indicated in the paragraph, "Concrete Pavement Patching." 12. Grade disturbed areas to original surface profile prior to seeding. 13. Clean up and seeding. C. Payment: The first Application for Payment will be approved based on the utilities installed during the agreed upon payment period without testing. Subsequent Application for Payments shall not be approved by the Engineer unless utilities installed during the previous payment period have passed the specified tests and clean up and seeding is complete. 1.07 BID ITEMS LISTED BY THE UNIT "EACH" (EA) (BID ITEMS 19,20 AND 24— 27) A. Measurement: By the number installed. B. Sanitary sewer work items: 1. 6 inch Sanitary Sewer Service: Excavation, backfilling, and compacting, 6 inch service pipe and fittings from main to right-of-way or the location as indicated on the Drawings, tap to manhole and pipe boot, and vertical 4 inch cleanout to grade with concrete collar. 2. Connect New 8" Sanitary Sewer to Existing Manhole: Coring of existing manhole, pipe boot, reworking of existing manhole bottom if necessary, and temporary by-passing of sewer if necessary. C. Erosion control work items: 1. Temporary Stream Crossing: Excavation, riprap maintenance during construction, final removal and drawings. 2. Temporary Construction Entrance: Excavation, during construction, and final removal and cleanup 3. Stone Outlet: Excavation, riprap, #5 washed construction, and final removal and clean up. 4. Rock Check Dam: Excavation, riprap, #5 washes construction, and final removal and clean up. , stone, culvert pipe, cleanup. As specified on washed stone, maintenance stone, maintenance during stone, maintenance during Unit Prices 01270-2 3097-F: 05/18/15 1.08 (X)' DIA. MANHOLES, DEPTH (X) —(X) FT (BID ITEMS 15 — 18) A. Measurement: By the number of various sizes and at the depth installed. Measure depths from manhole cover to lowest pipe invert. B. Work: Excavating, backfilling, stone sub base, concrete sections as required for the depth, top adjusting rings, steps, pipe boots, and ring and cover. 1.09 (X) INCH STEEL ENCASEMENT PIPE BY BORE AND JACK WITH (X) INCH (CARRIER PIPE) INSTALLED IN ENCASMENT PIPE (BID ITEM 14) A. Measurement: Along the centerline of the various sizes of steel encasement pipes installed. B. Work: Excavation and backfilling for bore pit, encasement pipe, and carrier pipe installed in encasement pipe with spacers and casing seals. Include costs for the provision of bonds, insurance and inspection fees required by the respective agency or authority in charge of inspection of the encasement pipe. 1.10 ROCK EXCAVATION (BID ITEM 21) A. Measurement 1. Pipe: Measure along the centerline of the trench, times the depth from the top of rock profile to the specified depth below the pipe, times the pipe OD plus two feet. 2. Structure: Measure two feet beyond the outside of the structure (excluding extended base) and to a depth of one foot greater than the bottom of the structure. 3. General: Take measurements in the presence of the Engineer. Maintain daily log sheets of measured quantities. Log sheets must be signed by the Engineer and submitted with payment request. Payment shall not be made for quantities that have not been field verified by the Engineer. B. Work: Complete removal and disposal of excavated rock material including, but not limited to, drilling, blasting, monitoring, excavating, loading, hauling, and properly disposing of excavated material. Providing specified material for backfilling shall include, but not be limited to, material, loading, hauling, placing and compacting. 1.11 UNDERCUT UNSTABLE PIPE FOUNDATION (BID ITEM 22) A. Measurement: Measure along the centerline of the trench times the undercut depth below the pipe bedding as approved by Engineer times the pipe OD plus two feet. Measure unstable soils at manholes on the maximum basis of 1 foot greater diameter than the outside diameter of the manhole and a depth as approved by the Engineer. Measurement shall be based on the actual quantities removed but not exceeding the maximum specified trench dimensions. Take measurements in the presence of the Engineer. Maintain daily log sheets of measured quantities. Log sheets must be signed by Engineer and submitted with payment request. Payment shall not be made for quantities that have not been field verified by the Engineer. B. Work: Complete removal and disposal of unstable soil including, but not limited to, excavating, loading, hauling, properly disposing of excavated material, and providing stone for backfill. Providing stone material for backfilling shall include, but not be limited to, material, loading, hauling, placing and compacting. 3097-F: 05/18/15 01270-3 Unit Prices 1.12 SELECT BACKFILL (BID ITEM 23) A. Measurement: Select backfill shall be agreed to by Engineer or Representative before installing material. Measure along the centerline of the trench times the depth as approved by Engineer times the pipe OD plus two feet. Measure select backfill at manholes on the maximum basis of 1 foot greater diameter than the outside diameter of the manhole and a depth as approved by the Engineer. Measurement shall be based on the actual quantities installed but not exceeding the maximum specified trench dimensions. Take measurements in the presence of the Engineer. Maintain daily log sheets of measured quantities. Log sheets must be signed by Engineer and submitted with payment request. Payment shall not be made for quantities that have not been field verified by the Engineer. B. Work: Complete removal and disposal of unsuitable backfill soil including, but not limited to, excavating, loading, hauling, properly disposing of excavated material, and providing stone for backfill. Providing select material for backfilling shall include, but not be limited to, material, loading, hauling, placing and compacting. 1.13 SILT FENCE (BID ITEM 28) A. Measure along the base of the silt fence installed. B. Work: Posts, wire mesh, fabric, base trench, stone, and maintenance during construction, removal and clean up. 1.14 CLASS "B" RIPRAP(BID ITEM 29) A. Measurement shall be the length and width of class "B" riprap actually installed. B. Payment for class "B" riprap shall be in accordance with the Contract unit price per square yard for the riprap furnished and installed as required by the Contract Documents. Payment shall be for all the labor, material and accessories required for a complete installation including, but not be limited to, the cost of fine grading, bedding stone, and class "B" riprap. C. Work: Filter fabric under stone, stone, hauling, and placement. 1.15 EROSION CONTROL MATTING (BID ITEM 30) A. Measurement: Erosion control matting shall be measured along the centerline of the ditch by the width of matting installed as indicated on the drawings. B. Payment for the erosion control matting shall be in accordance with the Contract unit price per square yard installed. Payment shall be for labor, material, and accessories required for a complete installation including, but not limited to, fine grading of ditch, liner material, and maintenance during construction. PART PRODUCTS Not Used PART 3 EXECUTION Not Used END OF SECTION Unit Prices 01270-4 3097-F: 05/18/15 SECTION 01312 PROJECT COORDINATION PART GENERAL 1.01 SECTION INCLUDES A. This Section specifies administrative and supervisory requirements necessary for Project coordination including, but not necessarily limited to: 1. Coordination. 2. Administrative and supervisory personnel. 3. General installation provisions. 4. Cleaning and protection. 1.02 GENERAL COORDINATION REQUIREMENTS A. Responsibilities of Contractor: 1. Coordinate construction activities for the Project to assure efficient and proper installation of each part of the Work. 2. Where availability of space is limited, coordinate installation of components to assure maximum accessibility for maintenance. Make adequate provisions to accommodate components scheduled for later installation. 3. Where necessary, prepare memoranda for distribution to each party involved outlining special procedures required for coordination. Include such items as required notices, reports, and attendance at meetings. A copy of all memoranda shall be submitted to the Engineer. B. Administrative Procedures: Coordinate scheduling and timing of required administrative procedures with other construction activities to avoid conflicts and ensure orderly progress of the Work. Such administrative activities include, but are not limited to, the following: 1. Preparation of schedules. 2. Installation and removal of temporary facilities. 3. Delivery and processing of submittals. 4. Progress meetings. 5. Installation meetings. 6. Project Close-out activities. C. Conservation: Coordinate construction activities to ensure that operations are carried out with consideration given to conservation of energy, water, and materials. 1. Salvage materials and equipment involved in performance of, but not actually incorporated in, the Work. Refer to other sections for disposition of salvaged materials that are designated as Owner's property. PART2 PRODUCTS NOT USED 3097-F: 05/06/15 01312-1 Project Coordination PART 3 EXECUTION 3.01 SPECIAL REQUIREMENTS A. Contractor shall not disturb building located near Station 11+50. B. Church sign located near Station 24+50. C. Church access shall remain open at all times near Station 24+25. D. Contractor shall take all effort possible to avoid damage to Church concrete drive. Any damage shall be repaired as indicated by Owner and Engineer and will be at contractor's expense. END OF SECTION Project Coordination 01312-2 3097-F: 05/06/15 SECTION 01314 PROJECT MEETINGS PART GENERAL 1.01 MEETINGS A. Pre -construction conference shall be held prior to the beginning of the Work. B. Construction progress meetings shall be held monthly. C. Project close-out conference shall be held during the final phases of the Work. D. Engineer may schedule additional meetings. E. Meetings scheduled by the Engineer shall be held at the Commissioners Room, Fourth Floor, 913 Greensboro St, Lexington NC. F. Contractor's project superintendent shall attend meetings. G. Notify suppliers and subcontractors to attend meetings as appropriate or as required by Engineer. H. Contractor shall schedule pre -installation conferences as required in the individual specification sections. I. Notify Engineer of project meetings scheduled by the Contractor. J. Engineer will schedule and administer meetings throughout the progress of the Work, except for meetings held by the Contractor for normal coordination of the Work. K. Meeting agenda shall include, but not be limited to, the following: Project Administration, Submittals, Construction Schedules and Methods, Safety and Health Regulations, Project Coordination, Payment Application, Change Orders, and Site Inspections. L. Engineer will prepare agenda with copies to participants, preside at meetings, prepare minutes and distribute to participants for meetings scheduled by the Engineer. PART2 PRODUCTS NOT USED PART 3 EXECUTION NOT USED END OF SECTION 3097-F: 04/30/15 01314-1 Project Meetings PART GENERAL 1.01 SECTION INCLUDES 1.02 SECTION 01330 SUBMITTAL PROCEDURES A. This Section includes, but is not limited to, 1. Submittal procedures. 2. Construction progress schedule. 3. Schedule of values. 4. Proposed product list. 5. Project record documents. 6. Certificates of compliance. 7. Catalog data. 8. Shop drawings. 9. Manufacturer's installation procedures. requirements for the following: 10. Samples. 11. Test reports. 12. Operation and maintenance instructions. 13. Warranties. 14. Spare parts and maintenance materials. SUBMITTAL PROCEDURES A. Transmit each submittal with cover letter to Engineer at The Wooten Company, 350 North Cox Street Suite 26 Asheboro, NC 27203. B. Sequentially number transmittal forms. Re -submittals to have original number with an alphabetic suffix. C. Cover letter for each submittal package shall list the following: 1. Contractors name: 2. Owners name: Davidson County 3. Project name: Old Salisbury Road Sewer 4. Wooten Job No.: 3097-F D. Individual submittals shall each be listed by the following information: 1. Submittal reference no. 2. Specification section number. 3. Drawing and detail number when appropriate. 4. Equipment. 5. Type submittal. 6. Supplier. 7. Manufacturer. E. Apply Contractor's stamp to each submittal, signed or initialed and dated, certifying that Contractor has reviewed submittal for conformance with requirements of Contract Documents, and has coordinated submittal with related work. F. Schedule submittals to expedite Project, and deliver to coordinate submission of related items. Allow a minimum of fifteen (15) working days for Engineer's review. 3097-F : 01/26/15 01330-1 Submittal Procedures G. Identify variations from Contract Documents and Product limitations as they relate to the satisfactory performance of the Project. H. Provide space for Contractor and Engineer review stamps. Revise and resubmit submittals as required; identify changes made since previous submittal. J. Distribute copies of reviewed submittals to concerned parties. Instruct parties to promptly report inability to comply with provisions. K. Work requiring submittal review by Engineer shall not be started until review has been obtained. L. Engineer's review of submittals shall not relieve Contractor of responsibility for complete compliance with Contract Documents. 1.03 ADMINISTRATIVE SUBMITTALS A. Construction Progress Schedule 1. Submit five (5) copies of the initial progress schedule 15 days after date of Owner -Contractor Agreement. One copy shall be returned to the Contractor. 2. Progress schedule shall be, as a minimum, a horizontal bar chart with a separate line for each major section of Work. Identify the first work day of each week. 3. Show complete sequence of construction by activity, identifying Work of separate stages and other logically grouped activities. Indicate the early and late start, early and late finish, float dates, and duration. 4. Indicate the expected monthly pay requests. 5. Submit revised schedule with each Application for Payment as required for updating, identifying changes since previous version. Indicate estimated percentage of completion for each item of Work at each submission. 6. Indicate submittal dates required for critical shop drawings, product data, samples, and product delivery dates . 7. Indicate specific work sequences and requirements as indicated in Section, Summary of Work. B. Schedule of Values 1. Submit three (3) copies of the schedule of values at least three (3) weeks prior to the first partial payment request. Schedule shall divide the lump sum contract items into major work tasks. Use the table of contents as a guide for itemizing the schedule. Schedule will be used only as a basis for review of the Contractor's request for payment. 2. Engineer may request additional delineation of work tasks and supporting data of the values, as he deems appropriate. Revise schedule and resubmit. 3. Revise schedule to list approved Change Orders, with each request for payment. C. Project Record Documents 1. Maintain on site, one set of the following record documents; record actual revisions to the Work: a. Contract Drawings. b. Project Manual. c. Addenda. d. Change Orders and other Modifications to the Contract. e. Reviewed submittals. Submittal Procedures 01330-2 3097-F: 01/26/15 2. Store Record Documents separate from documents used for construction. 3. Record information concurrent with construction progress. 4. Specifications: Legibly mark and record at each Product section description of actual Products installed, including the following: a. Manufacturer's name and product model and number. b. Product substitutions or alternates utilized. c. Changes made by Addenda and Modifications. 5. Record Documents and Shop Drawings: Legibly mark each item to record actual construction including: a. Measure elevations of structures in relation to bench mark datum. b. Measure and reference horizontal and vertical locations of underground utilities and appurtenances to existing permanent surface improvements that are indicated on the Drawings. c. Field changes from construction Drawings. d. Details not on original Contract Drawings. 6. Submit documents to Engineer with final Application for Payment. 1.04 TECHNICAL SUBMITTALS A. General 1. Submit the following as required by the individual sections of the technical specifications. 2. Unless noted otherwise, submit the number of copies that Contractor requires, plus three (3) copies that will be retained by Engineer. B. Certificates of Compliance 1. Certificates shall certify that the Products delivered to the project are in conformance with the specifications. 2. Certificates may be recent or previous test results on Product, but must be acceptable to Engineer. 3. Certification shall not relieve the Contractor of responsibility for complying with requirements of the specifications. C. Catalog Data 1. When shop drawings are not required, the catalog data shall include the following as a minimum: a. Parts schedule that identifies the materials to be used in each of the various parts. b. Sufficient detail to serve as a guide for assembly and disassembly of the product and to serve as guide for ordering parts. 2. Mark each copy to identify applicable products, models, options, and other data. Supplement manufacturers' standard data to provide information unique to this Work in the Shop Drawing submittal. D. Shop Drawing 1. Shop drawings shall consist of drawings, diagrams, illustrations, schedules, performance charts, brochures and other data, prepared specifically for a portion of the Work. 2. Shop drawings shall indicate the type, size, quantity, arrangement, location, mode of operation, component materials, utility connections, wiring and control diagrams, anchorage's, supports, factory applied coatings, and other information necessary to ensure satisfactory fabrication, installation and operation of the completed Work. 3097-F: 01/26/15 01330-3 Submittal Procedures 3. Shop drawings shall establish the actual detail of manufactured or fabricated items, indicate proper relation to adjoining work, amplify design details of mechanical and electrical equipment in proper relation to physical spaces in the structure, and incorporate minor changes to design and construction to suit actual requirements. E. Manufacturer's Installation Procedures 1. Installation procedures should indicate manufacturer's recommendations for proper installation of Product. F. Samples 1. Submit samples as required by the individual specification sections. Samples shall be physical examples to illustrate the materials and workmanship. Submit in sufficient size and quantity to clearly illustrate the functional characteristics of the Product, with integrally related parts and attachment devices, and the full range of color to be provided. G. Test and Start -Up Reports 1. Submit three (3) copies of report to the Engineer within seven (7) days of performing the test. 2. Report shall include the following as a minimum: a. Owners name: Davidson County b. Project name: Old Salisbury Road Sewer c. Wooten job number: 3097-F d. Firm performing work. e. Individual performing work. f. Specification section no.: g. Product tested or started. h. Date and time of work. i. Type of test or start-up. j. Specific location in the Project: (i.e. Structure name and location within the structure by a rough sketch.) k. Results. I. Opinion of firm doing the work as to the test or start-up being in compliance with the Contract Documents. 3. When requested by Engineer, the testing or start-up firm shall provide additional interpretation of results. H. Operation and Maintenance Instructions 1. Submit three (3) copies of operation and maintenance instructions within 45 days after approval of the shop drawings. 2. Submit instructions in a navy blue vinyl, loose leaf binder containing the name of the equipment covered on the front and the spine of the binder. Provide tab dividers appropriately labeled. 3. As a minimum, the submittal shall contain complete operation and maintenance instructions, drawings, and complete parts list. 4. In addition, for equipment requiring periodic lubrication, provide two (2) lubrication charts; one shall be included in the binder, and the other shall be provided in weatherproof 10 mil. laminated plastic and shall be permanently affixed to the equipment. Charts shall contain pertinent information concerning the lubricating requirements including manufacturer's name, name of equipment, recommended service interval, and recommended lubricant, location of each of the points of lubrication. Submittal Procedures 01330-4 3097-F: 01/26/15 Warranties 1. Provide duplicate notarized copies. 2. Assemble documents from Subcontractors, suppliers, and manufacturers. 3. Provide Table of Contents and assemble in three D side ring binder with durable plastic cover. 4. Submit prior to final Application for Payment. 5. For items of Work delayed beyond date of Substantial Completion, provide updated submittal within 10 days after acceptance, listing date of acceptance as start of warranty period. J. Spare Parts and Maintenance Materials 1. Provide products, spare parts, maintenance, and extra materials in quantities specified in individual specification Sections. 2. Provide recommended manufacturer's list of spare parts, maintenance, and extra material as specified in individual specification sections. 3. Submit to Engineer. PART2 PRODUCTS Not Used PART 3 EXECUTION Not Used END OF SECTION 3097-F: 01/26/15 01330-5 Submittal Procedures SECTION 01450 QUALITY CONTROL PART GENERAL 1.01 SECTION INCLUDES A. Quality assurance and control of installation. B. Inspection and testing laboratory services. C. References. D. Field samples. E. Manufacturers' field services and reports. 1.02 QUALITY ASSURANCE/CONTROL OF INSTALLATION A. Manufacturer shall have the minimum number of years of proven successful experience required in each section in the design, manufacture, and servicing of Products specified. B. In lieu of the required experience, manufacturer may provide a cash deposit or bond equal to the cost of the Product, but pro -rated to the number of years of actual experience. C. Products from a manufacturer who does not meet the experience requirements must meet technical requirements. D. Monitor quality control over suppliers, manufacturers, Products, services, site conditions, and workmanship, to produce Work of specified quality. E. Comply fully with manufacturers' instructions, including each step in sequence. F. Should manufacturers' instructions conflict with Contract Documents, request clarification from Engineer before proceeding. G. Comply with specified standards as a minimum quality for the Work except when more stringent tolerances, codes, or specified requirements indicate higher standards or more precise workmanship. H. Perform work by persons qualified to produce workmanship of specified quality. I. Secure Products in place with positive anchorage devices designed and sized to withstand stresses, vibration, physical distortion, or disfigurement. 1.03 INSPECTION AND TESTING LABORATORY SERVICES A. Owner will employ, and pay for services of an independent firm to perform inspection and testing for the following specific items. 1. Soil testing. 2. Concrete testing. B. Contractor shall provide the services of an independent firm to perform inspection and testing specified in the individual specification sections that are not listed above. C. The same independent firm shall perform retesting. Contractor shall pay for retesting required by the failure of the initial test to meet the requirements of the specifications. 3097-F: 01/27/15 01450-1 Quality Control 1.04 CONTRACTOR RESPONSIBILITIES A. Unless specified otherwise, deliver to laboratory at designated location, adequate samples of materials proposed to be used that require testing. The proposed mix designs shall be included with delivery. B. Cooperate with laboratory personnel, and provide access to the Work and to manufacturer's facilities as specified. C. Provide incidental labor and facilities to provide access to Work to be tested, to obtain and handle samples at the site and at source of products to be tested, to facilitate tests and inspections, storage, and curing of test samples. D. Notify Engineer and laboratory 24 hours prior to expected time for operations requiring inspection and testing services. PART2 PRODUCTS Not Used PART 3 EXECUTION Not Used END OF SECTION Quality Control 01450-2 3097-F: 01/27/15 SECTION 01500 TEMPORARY FACILITIES AND CONTROLS PART GENERAL 1.01 SECTION INCLUDES A. Temporary Utilities: Electricity, lighting, telephone service, water, and sanitary facilities. B. Work on public right-of-way. C. Traffic control. D. Temporary Controls: Barriers, enclosures and fencing, water control, dust control, erosion and sediment control, and protection of the work. E. Construction Facilities: Access roads, parking, progress cleaning, project signage, and field offices. 1.02 TEMPORARY UTILITIES A. Electricity 1. Provide and pay for required power service for construction from Utility source. B. Lighting 1. Provide and maintain lighting for construction operations as required by Contractor. 2. Provide and maintain lighting to exterior staging and storage areas after dark for security purposes as required by Contractor. C. Telephone Service 1. Provide, maintain and pay for telephone service to field office as required by Contractor. D. Water 1. Provide, maintain, and pay for suitable quality water, including any necessary service(s) required for construction operations. Exercise measures to conserve water during construction. E. Sanitary Facilities 1. Provide and maintain required facilities and enclosures as necessary to comply with the laws and ordinances of the authority having jurisdiction and the State of North Carolina. 2. General Contractor shall provide the above sanitary facilities for all contractors, sub -contractors, Owner and Engineer at the Project Site. 3. Existing facilities shall not be used. 1.03 WORK ON PUBLIC RIGHTS-OF-WAY A. Work on this Project is along rights-of-way under jurisdiction of the following N.C. Department of Transportation (NC DOT) office and Owner: 1. Work in Davidson County: 2. Division 9, District 1 3. Chris Corriher, PE, District Engineer 4. 4770 South Main Street Salisbury NC 27127 3097-F : 04/30/15 01500-1 Temporary Facilities B. Work shall comply with requirements of the Encroachment Agreement(s) and Driveway Permit as attached to Project Supplementary Conditions. C. Post Bonds as required by Encroachment Agreement. D. Prior to start of Work notify the Office of the N.C. Department of Transportation as indicated in the encroachment agreement and driveway permit. Also notify the Owner. E. Work shall conform to the requirements and be subject to the approval of the above agency(ies). F. Submit letter to the above District Engineer(s) when work is complete as required by the Encroachment Agreement. G. Submit letter of approval for completed Work from the above agency(ies) with Final Payment Request. H. Clean rights-of-way as work progresses and daily. I. Power broom existing pavement as work progresses. J. Work shall be in accordance with the latest edition of the N.C. Division of Highways, "Policies and Procedures for Accommodating Utilities on Highway Right -of -Way." K. Consult with the above agency(ies) in establishing public thoroughfares to be used for haul routes and site access. L. Confine construction traffic to designated haul routes. M. Provide traffic control along haul routes to regulate traffic and to minimize interference with public. N. Provide and maintain access to fire hydrants, free of obstructions. 1.04 TRAFFIC CONTROL A. On public and private road rights-of-way provide traffic control devices when construction encroaches within the right-of-way. Devices shall include, but not be limited to, cones, drums, flares, warning signs, temporary pavement marking, warning lights, and flagman. B. Traffic control devices shall provide the following: 1. Protection of motorists, pedestrians and workers from accident hazards. 2. Advance public information of proposed work sites. 3. Establishment of an orderly and safe flow of traffic and to minimize traffic congestion. 4. Provision of access for emergency vehicles. C. Traffic control devices shall be used in accordance with the latest edition of the NC DOT "Manual on Uniform Traffic Control Devices for Streets and Highways (MUTCD)." D. Provide personnel trained in traffic control. 1.05 TEMPORARY CONTROLS A. General 1. Temporary controls shall be the responsibility of each Contractor for their respective work unless noted otherwise. Temporary Facilities 01500-2 3097-F: 04/30/15 B. Barriers 1. Provide barriers to prevent unauthorized entry to construction areas for the safety of the public, the protection of the work, and to protect existing facilities and adjacent properties from damage from construction operations. 2. Provide protection for plant life designated to remain. Replace damaged plant life. 3. Protect vehicular traffic, stored materials, site, and structures from damage. C. Water Control 1. Grade site to drain. Provide, operate, and maintain pumping equipment to maintain excavations free of water. 2. Protect site from running water. D. Dust Control 1. Execute Work by methods designed to minimize raising dust from construction operations. 2. Provide positive means to prevent airborne dust from dispersing into atmosphere. E. Erosion and Sediment Control 1. Provide Erosion and Sediment Control as indicated on the Drawings and specified in Section, Erosion Control. F. Protection of Installed Work 1. Protect installed Work and provide special protection where specified in individual specification Sections. 2. Provide temporary and removable protection for installed Products. Control activity in immediate work area to minimize damage. 3. Prohibit traffic from landscaped areas. 1.06 CONSTRUCTION FACILITIES A. General 1. Construction facilities shall be the responsibility of each Contractor for their respective work unless noted otherwise. B. Access Roads 1. Contractor shall construct and maintain temporary drives as necessary to access public thoroughfares and existing drives to serve the construction area. 2. Provide means of removing mud from vehicle wheels before entering streets. C. Parking 1. When site space is not adequate, arrange for temporary off site surface parking areas to accommodate construction personnel. 2. Do not allow vehicle parking in existing right-of-way or to block existing drives. 3. Do not allow vehicle parking on private property without prior approval. D. Progress Cleaning 1. Maintain areas free of waste materials, debris, and rubbish. Maintain site in a clean and orderly condition. 2. Remove waste materials, debris, and rubbish from site periodically and dispose off site. 1.07 REMOVAL OF UTILITIES, FACILITIES, AND CONTROLS A. Remove temporary above grade or buried utilities, equipment, facilities, and materials, prior to Final Inspection. 3097-F: 04/30/15 01500-3 Temporary Facilities B. Clean and repair damage caused by installation or use of temporary work. C. Restore existing facilities used during construction to original condition. Restore permanent facilities used during construction to specified condition. PART 2 PRODUCTS Not Used PART 3 EXECUTION Not Used END OF SECTION Temporary Facilities 01500-4 3097-F: 04/30/15 SECTION 01600 PRODUCT REQUIREMENTS PART GENERAL 1.01 SECTION INCLUDES A. Products. B. Transportation and handling. C. Storage and protection. D. Product options. E. Substitutions. 1.02 PRODUCTS A. Products: Means new material, machinery, components, equipment, fixtures, and systems forming the Work. Does not include machinery and equipment used for preparation, fabrication, conveying, and erection of the Work. Products may also include existing materials or components specified in the Contract Documents for reuse. 1.03 TRANSPORTATION AND HANDLING A. Transport and handle Products in accordance with manufacturer's instructions. B. Ship fabricated assemblies in largest sections permitted by carrier regulations and properly marked for ease of field erection. C. Promptly inspect shipments to assure that Products comply with specified requirements, quantities are correct, and Products are undamaged. D. Provide equipment and personnel to handle Products by methods to prevent soiling, disfigurement, or damage. 1.04 STORAGE AND PROTECTION A. Keep on site storage of material to a minimum. B. Store and protect Products in accordance with manufacturer's instructions in unopened original packages, with seals and labels intact and legible. Store sensitive Products in weather -tight, climate -controlled enclosures. C. For exterior storage of fabricated Products, place on sloped supports, above ground. D. Provide off site storage and protection when site does not permit on site storage. E. Cover Products subject to deterioration with impervious sheet covering. Provide ventilation to avoid condensation. F. Store loose granular Products on solid flat surfaces in a well drained area. Prevent mixing with foreign matter. G. Arrange storage of Products to permit access for inspection. Periodically inspect to assure Products are maintained under specified conditions. 3097-F : 01/27/15 01600-1 Product Requirements 1.05 DAMAGED PRODUCTS A. Remove damaged Products from Project site. 1.06 PRODUCT OPTIONS A. Products Specified by Reference Standards: Product meeting standard and specific requirements of these specifications. B. Products Specified by Naming One or More Manufacturers: Products of manufacturers named and meeting specifications, no options or substitutions allowed. C. Products Specified by Naming Three Manufacturers with an "or equal' Provision for Substitutions: Submit a request for substitution for manufacturer not named during the shop drawing submittal. 1.07 SUBSTITUTIONS A. Engineer will consider requests for Substitutions only within 30 days after date of Owner -Contractor Agreement. B. Substitutions may be considered when a product becomes unavailable through no fault of the Contractor. C. Document each request with complete data substantiating compliance of proposed Substitution with Contract Documents. D. Request constitutes a representation that Contractor: 1. Has investigated proposed product and determined that it meets or exceeds the quality level of the specified product. 2. Shall provide same warranty for Substitution as for specified product. 3. Shall coordinate installation and make changes to other Work which may be required for the Work to be complete with no additional cost to Owner. 4. Waives claims for additional costs or time extension that may subsequently become apparent. 5. Shall reimburse Owner for review or redesign services associated with reapproval by authorities. E. Substitutions will not be considered when they are indicated or implied on shop drawing or product data submittals, without separate written request, or when acceptance will require revision to the Contract Documents. F. Substitution Submittal Procedure: 1. Submit three copies of request for Substitution for consideration. Limit each request to one proposed Substitution. 2. Submit shop drawings, product data, and certified test results attesting to proposed product equivalence. 3. Engineer will notify Contractor, in writing, of decision to accept or reject request. PART2 PRODUCTS Not Used Product Requirements 01600-2 3097-F: 01/27/15 PART 3 EXECUTION Not used END OF SECTION 3097-F: 01/27/15 01600-3 Product Requirements SECTION 01700 EXECUTION REQUIREMENTS PART GENERAL 1.01 SECTION INCLUDES A. Examination. B. Cutting and patching. C. General installation provisions. D. Cleaning and protection. E. Final inspection and tests. F. Adjusting. G. Close-out procedures. 1.02 EXAMINATION A. Verify that existing site conditions and substrate surfaces are acceptable for subsequent Work. Beginning new Work means acceptance of existing conditions. B. Verify that existing substrate is capable of structural support or attachment of new Work being applied or attached. C. Examine and verify specific conditions described in individual specifications sections. D. Verify that utility services are available, of the correct characteristics, and in the correct locations. 1.03 CUTTING AND PATCHING A. General 1. Do not cut, or alter the work of other contractors without written approval of the Engineer. 2. Work removed shall be replaced or repaired by the Contractor who removed or damaged the work, and a craftsman, skilled in the trade that the particular replacement requires, shall do the work. (i.e.: A mason, not an electrician, shall replace masonry removed by the Electrical Contractor.) 3. Conduct removal operations in a manner that will eliminate hazards to persons and property and prevent the release of dust and rubbish into the air. Existing work, which is to remain and is damaged by contract operations shall be replaced with new materials at no additional cost to the Owner. 4. For replacement of work removed, comply with specifications for type of work to be done. B. Inspection 1. Inspect existing conditions of work including elements subject to movement or damage during cutting and patching, and excavating and backfilling. 2. After uncovering work, inspect conditions affecting installation of new products. C. Preparation prior to cutting 1. Provide shoring, bracing, and support as required to maintain structural integrity of project. 3097-F: 04/30/15 01700-1 Execution Requirements 2. Provide protection for other portions of project. 3. Provide protection from elements. D. Performance 1. Execute fitting and adjustment of products to provide finished installation to comply with specified tolerances, finishes. 2. Execute cutting and demolition by methods to prevent damage to other work and provide proper surfaces to receive installation of repairs and new work. 3. Execute excavating and backfilling as specified in Section, Trenching for Utilities. 4. Restore work, which has been cut or removed; install new products to provide completed work in accordance with requirements of contract documents. 5. Refinish entire surfaces as necessary to provide an even finish. a. Continuous Surfaces: To nearest intersections. b. Assembly: Entire Refinishing. 1.04 GENERAL INSTALLATION PROVISIONS A. Require Installer of each major component to inspect conditions under which Work is to be performed. Clean substrate surfaces prior to applying next material or substance. Do not proceed until unsatisfactory conditions have been corrected. B. Comply with manufacturer's recommendations to the extent that they are more explicit or stringent than requirements contained in Contract Documents. C. Provide attachment and connection devices and methods necessary for securing Work. Secure Work true to line and level. Allow for expansion and building movement. D. Provide uniform joint widths in exposed Work. Arrange joints in exposed Work to obtain the best visual effect. Refer questionable choices to the Engineer for final decision. E. Check dimensions before starting each installation. F. Install each component during weather conditions and Project status that will ensure the best possible results. Isolate each part of the completed construction from incompatible material as necessary to prevent deterioration. G. Coordinate temporary enclosures with required inspections and tests, to minimize the necessity of uncovering completed construction for that purpose. H. Where mounting heights are not indicated, install individual components at standard mounting heights recognized within the industry for the particular application indicated. Refer questionable mounting height decisions to the Engineer for final decision. 1.05 CLEANING AND PROTECTION A. During handling and installation, clean and protect construction in progress and adjoining materials in place. Apply protective covering where required to ensure protection from damage or deterioration. B. Clean and maintain completed construction as frequently as necessary through the construction period. Adjust and lubricate components as required to ensure proper operation. C. Limiting Exposures: Supervise construction activities to ensure that no part of the construction, completed or in progress, is subject to harmful, or dangerous exposure Execution Requirements 01700-2 3097-F: 04/30/15 during the construction period. Where applicable, such exposures include, but are not limited to, the following: 1. Excessive static or dynamic loading. 2. Excessive internal or external pressures. 3. Excessively high or low temperatures. 4. Thermal shock. 5. Air contamination or pollution. 6. Water or ice. 7. Abrasion. 8. Heavy traffic. 9. Misalignment. 10. Improper shipping or handling. 11. Theft. 12. Vandalism. D. Clean Project prior to final inspection. Project clean up shall include, but not be limited to, the following: 1. Clean debris from drainage systems. 2. Sweep paved areas. 3. Rake clean landscaped surfaces. 4. Remove waste and surplus materials. 5. Remove temporary construction facilities. 1.06 FINAL INSPECTION AND TESTS A. Complete punch list items within 30 days of receipt from Engineer. Owner may have work not completed within 30 days performed by others with the cost deducted from Contractor's final payment. Additional engineering and inspection services required as a result of Contractor not completing punch list within 30 days shall be at Contractor's expense. 1.07 ADJUSTING A. Adjust operating Products and equipment to ensure smooth and unhindered operation. 1.08 CLOSE-OUT PROCEDURES A. Submit written certification that Contract Documents have been reviewed, Work has been inspected, and is complete in accordance with Contract Documents and ready for Engineer's inspection. B. Provide submittals to Engineer that are required by governing or other authorities. C. Submit set of Record Documents indicating changes during construction as required in Section, Submittal Procedures. D. Submit final Application for Payment identifying total adjusted Contract Sum, previous payments, and final amount due. E. Submit the following with final Application for Payment: 1. Affidavit of Release of Liens 2. Consent of Surety for Final Payment 3. Affidavit of Payment of Debts and Claims 3097-F: 04/30/15 01700-3 Execution Requirements PART2 PRODUCTS Not Used PART 3 EXECUTION Not Used END OF SECTION Execution Requirements 01700-4 3097-F: 04/30/15 SECTION 02230 CLEARING AND GRUBBING PART1 GENERAL 1.01 SECTION INCLUDES A. Work shall include, but not be limited, to the following: 1. Access roads. 2. Clearing and grubbing. 3. Removal of surface debris. 4. Demolition and removal of existing paving and structures. 5. Temporary and permanent ground cover. 1.02 RELATED SECTIONS A. The following Sections have work that is directly related to this Section. This does not relieve the Contractor of his responsibility of proper coordination of all the work: 1. Section 02370 Erosion Control 2. Section 02920 Lawns and Grasses. 1.03 WARRANTY AND FINES A. Contractor is liable for damages to public and private property and fines as may be placed on the Project by the governing agencies due to failure to provide adequate erosion control devices. PART2 PRODUCTS Not Used PART 3 EXECUTION 3.01 PROTECTION A. Take reasonable care during construction to avoid damage to vegetation outside of the construction limits. Temporarily tie back ornamental shrubbery and tree branches, where appropriate, to minimize damage. Trees that receive damage to branches shall be trimmed of those branches to improve the appearance of the tree. Treat tree trunks damaged by equipment with a tree dressing. B. Locate and protect property corners and survey control stakes prior to start of clearing operations. C. Provide temporary gates and fences as necessary to prevent unauthorized vehicular access to the site. D. Mark clearing limits. E. Refer to paragraph 4.04 of the General Conditions and 4.04.A.2 of the Supplementary Conditions concerning the protection of Underground Facilities. 3097-F: 04/30/15 02230-1 Clearing and Grubbing 3.02 INSTALL EROSION CONTROL DEVICES A. Clear areas required to install erosion control devices, which shall be in place and operational prior to other land disturbing activity. Install erosion control devices in accordance with Section, Erosion Control. 3.03 BORROW AND DISPOSAL AREAS A. Obtain and pay for erosion control permit for borrow and disposal areas as required by Contractor. B. Install and maintain erosion control devices in accordance with Contractor's approved plan. 3.04 CLEARING AND GRUBBING A. Clear total width of permanent easement. Clear within temporary construction easement only as necessary for construction. B. Grub within the permanent easement only as necessary for the installation of the work. Do not grub within the temporary construction easement. C. Clearing shall consist of cutting and removal of vegetation to the existing ground surface and removal of debris. Debris shall include, but not be limited to, fences, steps, walls, chimneys, footings, foundation slabs, basements, signs, junked vehicles, and other rubble. D. Grubbing shall consist of the removal of roots over 3 inches in diameter, matted roots, stumps, and other vegetable matter to 12 inches below existing grade. E. Do not precede grading operation by grubbing operation by more than seven days. F. Fill holes and depressions and bring cleared and grubbed area to a uniform contour to match existing grade. Provide positive drainage. G. Remove and properly dispose of cleared and grubbed material from the site. Make reasonable effort to channel timber resulting from clearing operations into a beneficial use. H. Burning of combustible materials is permitted provided required permits and approvals are obtained from local authorities. Locate burning to prevent damage to vegetation or improvements to remain. Attend materials until fire has been extinguished. END OF SECTION Clearing and Grubbing 02230-2 3097-F: 04/30/15 SECTION 02315 TRENCHING FOR UTILITIES PART GENERAL 1.01 SCOPE A. Provide labor, equipment, and material to perform required excavating, backfilling, and compacting for utilities and related structures as specified herein and indicated on the Drawings. Work shall include, but not be limited to, the following: 1. Survey staking as required for construction. 2. Protection of existing improvements. 3. Location of installed utilities. 4. Use of explosives. 5. Dewatering. 6. Excavating, backfilling, and compacting for utilities. 7. Installation of warning / identification tape and tracer wire. 8. Borrow material. 9. Disposal of surplus material. 1.02 RELATED SECTIONS A. The following Sections have work that is directly related to this Section. This does not relieve the Contractor of his responsibility of proper coordination of all the work: 1. Section 02230 Clearing and Grubbing 2. Section 02370 Erosion Control 3. Section 02530 Sanitary Sewer System 4. Section 02920 Lawns and Grasses 1.03 MEASUREMENT AND PAYMENT A. Include work specified in this Section in the lump sum or unit price cost for the utility installation as appropriate unless specifically specified elsewhere in the specifications. B. The following work shall be paid by the unit price as indicated in the Bid Form: 1. Undercut of unstable soils: Cu Yd 2. Rock excavation: Cu Yd C. Take measurements for determination of unit price quantities in the presence of the Engineer. Maintain daily log sheets of measured quantities. Log sheets must be signed by Engineer and submitted with payment request. Payment shall not be made for unit price quantities that have not been field verified by the Engineer. Measurement shall be based on the actual quantities removed but not exceeding the maximum trench dimensions as specified herein. D. Payment for the unit price items shall be for all labor, materials, equipment, and services required or reasonably implied by the Contract Documents and shall include, but not be limited to, the following: 1. Undercut of unstable soils: Complete removal and disposal of undercut material including, but not limited to, excavating, loading, hauling, and properly disposing of excavated material. Providing Class I material for backfilling shall include, but not be limited to, material, loading, hauling, placing and compacting in accordance with these specifications. 3097-F: 04/30/15 02315-1 Trenching for Utilities 2. Rock excavation: Complete removal and disposal of excavated rock material including, but not limited to, drilling, blasting, excavating, loading, hauling, and properly disposing of excavated material. Rock excavation for manholes shall be paid for on the maximum basis of 1 -foot greater diameter than the outside diameter of the manhole and to a depth of 1 foot greater than the bottom of the manhole. Providing Class I material for backfilling shall include, but not be limited to, material, loading, hauling, placing and compacting in accordance with these specifications. 1.04 REFERENCED STANDARDS A. The latest revision, at the time of bidding, of the publications listed below form a part of this specification to the extent referenced. The publications are referred to in the text by basic designation only. 1. N.C. Department of Transportation - Standard Specifications for Roads and Structures (NCDOT). 2. American Society of Testing Materials (ASTM) a. D698 Moisture -Density Relations of Soils and Soil -Aggregate Mixtures Using 5.5 -Ib (2.49 Kg) Rammer and 12 -inch Drop (Standard Proctor). b. D1556 Density of Soil in Place by the Sand -Cone Method. c. D1586 Penetration Test and Spilt -Barrel Sampling of Soils. d. D2049 Test for Relative Density of Cohesionless Soils. e. D2216 Laboratory Determination of Water (Moisture) Content of Soil, Rock, and Soil -Aggregate Mixtures. f. D2487 Classification of Soils for Engineering Purposes. 3. Uni-Bell PVC Pipe Association a. B-5-89 Recommended Practice for the Installation of Polyvinyl Chloride (PVC) Sewer Pipe. 1.05 DEFINITIONS A. Backfill: A specified material used in filling the excavated trench and placed at a specified degree of compaction. 1. Materials: Materials listed herein include processed materials plus the soil classifications listed under the Unified Soil Classification System, (USCS) (Method D2487 and Practice D2488). The soil materials are grouped into five broad categories according to their suitability for this application. a. Class I: Angular, 6 to 40 -mm (1/4 to 1 -1/2 -in), graded stone, including a number of fill materials that have regional significance such as coral, slag, cinders, crushed stone, and crushed shell. b. Class II: Coarse sands and gravels with maximum particle size of 40 mm (1-1/2 in.), including various graded sands and gravels containing small percentages of fines, generally granular and noncohesive, either wet or dry. Soil Types GW, GP, SW, and SP are included in this class. c. Class III: Fine sand and clayey gravels, including fine sands, sand -clay mixtures, and gravel -clay mixtures. Soil Types GM, GC, SM, and SC are included in this class. d. Class IV: Silt, silty clays, and clays, including inorganic clays and silts of medium to high plasticity and liquid limits. Soil Types MH, ML, CH and CL are included in this class. These materials shall not be used for bedding, haunching, or initial backfill. e. Class V: This class includes the organic soils OL, OH, and PT as well as soils containing frozen earth, debris, rock larger than 40 mm (1 1/2 in.) in Trenching for Utilities 02315-2 3097-F: 04/30/15 diameter, and other foreign materials. These materials shall not be used for bedding, haunching, or initial backfill. 2. Backfill Zones: Each backfill zone shall extend the full width of the trench bottom. a. Foundation: Extending down from the bottom of bedding zone as defined below. b. Pipe Embedment 1) Bedding: Extending from 4 inches below the pipe bottom to the pipe bottom for 30 -inch diameter and smaller and 6 inches below the pipe bottom for pipes larger than 30 inches in diameter. 2) Haunching: Extending from the bedding (bottom of the pipe) to the pipe spring line. 3) Initial Backfill: Extending from the haunching (pipe spring line) to 1 foot above the top of the pipe. c. Final Backfill: Extending from the initial backfill to the finish ground elevation. B. Laying Conditions: 1. Type 1: Flat bottom trench with loose backfill. 2. Type 2: Flat bottom trench with backfill lightly consolidated to centerline of pipe. 3. Type 3: Pipe bedded in 4 inches minimum of loose soil and backfill lightly consolidated to top of pipe. 4. Type 4: Pipe bedded on Class I material to 1/8 pipe diameter (4 inch minimum) Backfill compacted to top of pipe a minimum of 80 percent of standard proctor. 5. Type 5: Pipe bedded in compacted Class I material to pipe centerline with 4 - inch minimum under pipe. Backfill to top of pipe with Class I, II, or III and compact to 90 percent of standard proctor. C. Compaction: Process of mechanically stabilizing a material by increasing its density at a controlled moisture condition. "Degree of compaction" shall be expressed as a percentage of the maximum dry density obtained by the test procedure presented in ASTM D698 (Standard Proctor). D. Excavation: The removal of soil or rock to obtain a specified depth or elevation. E. Hard Material: Solid, homogeneous material which is not included in the definition of "rock" but which may require the use of heavy excavation equipment with ripper teeth. Amount must exceed 1 cubic yard in volume. Material having a standard penetration resistance as determined by ASTM D1586 between 60 and 150 blows per foot is defined as "hard material." F. Lift: Layer of soil placed on top of a previously prepared or placed soil G. Rock: Solid, homogeneous material which cannot be removed without the systematic drilling and blasting exceeding 1 cubic yard in volume. Material having a standard penetration resistance as determined by ASTM D1586 greater than 150 blows per foot is defined as "rock." Removal of "hard material" will not be considered rock excavation because of intermittent drilling and blasting that is performed merely to increase production. H. Pipe Springline: A line running horizontally through the center of the pipe I. Topsoil: Natural, friable soil, representative of productive soils in the vicinity of the site. Topsoil shall be free from roots, stones larger than 1 inch, objectionable weed seeds, toxic substances, and materials that hinder grading, planting, and maintenance operations. 3097-F : 04/30/15 02315-3 Trenching for Utilities 1.06 SUBMITTALS A. Submit the following in accordance with Section, Submittal Procedures: 1. Catalog Data: Submit manufacturer's standard drawings or catalog cuts for the following. Clearly indicate equipment to be furnished for the Project including options to be provided. a. Warning / Identification tape. PART2 PRODUCTS 2.01 STONE A. Class I material shall be #67 or #78M stone in accordance with NCDOT specifications Section 1005, General Requirements for Aggregate. 2.02 WARNING AND IDENTIFICATION TAPE A. Tape shall be a minimum 3 -inch wide polyethylene plastic tape manufactured specifically for identification of buried utilities with means of enabling detection by a metal detector to a minimum depth of 3 feet. Tape shall be color coded and continuously imprinted with warning and identification markings in bold black letters to read "CAUTION - BURIED (utility) LINE BELOW." Color and printing shall be permanent, unaffected by moisture or soil and shall be as follows: Utility Color Marking 1. Water Blue Caution - Buried Water Line Below 2. Gravity Sewer Green Caution - Buried Sewer Line Below 3. Force Main Green Caution - Buried Force Main Below 4. Electric Red Caution - Buried Electric Line Below 5. Gas Yellow Caution - Buried Gas Line Below 6. Telephone Orange Caution - Buried Telephone Line Below 7. SCADA Orange Caution - Buried SCADA Line Below B. Tape shall be by Blackburn Manufacturing, Joseph G. Pollard Co., or Reef Industries Inc. 2.03 TRACER WIRE A. Tracer wire shall be #12 solid copper wire. All connections shall be by wire nuts and taped. B. Splices in tracer wire are to be kept to a minimum and joined with copper split nuts of appropriate size. PART 3 EXECUTION 3.01 PROJECT SAFETY A. Contractor is responsible for Project safety. B. Perform work in conformance with applicable State and Federal safety regulations including, but not limited, to the following: 1. North Carolina Safety and Health Standards for the Construction Industry (29CFR 1926 Subpart P). 2. NC OSHA Industry Guide No. 14, Excavations. 3. NC OSHA Industry Guide No. 20, Crane Safety. Trenching for Utilities 02315-4 3097-F: 04/30/15 C. Provide barriers, warning lights, and other protective devices at excavations as necessary for safety of workers and the public. D. Provide sloping of bank, shoring, sheeting, or other means of maintaining the stability of the trench in accordance with the requirements of the Associated Contractor's Manual of Accident Prevention OSHA, Part 1926.P. 3.02 PROTECTION OF UNDERGROUND FACILITIES A. Refer to paragraph 4.04 of the General Conditions and SC -4.04.A.2 of the Supplementary Conditions concerning the protection of Underground Facilities. B. Approximate locations of existing underground facilities at the site are indicated on the Drawings based on information available to the Engineer. Engineer and Owner do not take responsibility for the accuracy of the information. C. Investigate underground facility locations prior to the start of construction. D. Repair damage to existing facilities at no additional cost to the Owner. E. A change in conditions may be considered due to the location of the existing facilities as allowed in the General Conditions. This does not include the cost for repair of damaged facilities not properly located in advance of construction. F. Separation distances shall be in accordance with utilities requirements. 3.03 CONSTRUCTION STAKING A. Provide construction staking as indicated in paragraph 4.05 of the General Conditions. Engineer will only provide key reference points and benchmarks. B. Provide construction staking. Owner will provide key reference points and benchmarks for construction, which in the Engineer's judgment are necessary to enable Contractor to proceed with the Work. Contractor shall be responsible for laying out the Work as necessary for construction. Contractor shall protect and preserve the established reference points and property monuments. C. Contractor shall report to Engineer whenever a reference point or property monument is lost or destroyed or requires relocation because of necessary changes in grades or locations. Contractor shall be responsible for the accurate replacement or relocation of such reference points or property monuments by a registered professional surveyor in the State of North Carolina. 3.04 LOCATION OF INSTALLED UTILITIES A. Contractor shall be responsible for locating contract installed utilities as requested by third parties proposing to dig in the contract area until the date that the entire contract is recommended for final payment by Engineer to Owner. 3.05 WATER CONTROL A. Prevent surface water from entering the trench. B. When trench bottom is below the existing ground water table, install a dewatering system to maintain water table 1 foot below trench bottom. Provide a man experienced in dewatering work at the job site. C. Maintain dewatering until backfilling has proceeded above the existing ground water level. D. Dispose of water from dewatering operations in accordance with the North Carolina Sedimentation Pollution Control Act. 3097-F: 04/30/15 02315-5 Trenching for Utilities 3.06 USE OF EXPLOSIVES A. Obtain required permits for blasting. B. Store, handle, and use explosives in accordance with local and state regulations, or in the absence of such, in accordance with the provisions of the "Manual of Accident Prevention and Construction" of the Associated General Contractors of America, Inc. C. Conduct survey and document existing conditions of facilities prior to blasting. Provide seismographic monitoring during progress of blasting operations. D. Use explosives in such a way to minimize vibration to existing utilities and structures. E. Provide only experienced men for blasting in accordance with accepted practices. F. Contractor is responsible for safety of life and damage to property resulting from the use of explosives. 3.07 EXCAVATING A. Excavation shall be by open cut, unless otherwise indicated on the Drawings or specified herein. Short sections of trench may be tunneled or direct bored with the approval of the Engineer. B. Stockpile excavated material in such a manner that it will not obstruct the flow of runoff, streams, endanger Work, impair the use or appearance of existing facilities, or be detrimental to the completed Work. C. Contractor shall segregate excavated material so as to maintain material suitable for backfill separate from material that is unsuitable. D. Trench dimensions at the pipe embedment and foundation zone unless noted otherwise shall be as follows: 1. Minimum width: Pipe outside diameter plus 18 inches. 2. Maximum width: Pipe outside diameter plus 24 inches. 3. Sides shall be vertical to a minimum of one foot above the top of pipe. E. Shape trench bedding to provide uniform bearing for the full pipe length. Bottom shall be free of protrusions that could cause point loading on pipe. Provide bell holes as required for properly making pipe joint. F. Do not over excavate. Excavation below grade without approval of Engineer shall be backfilled with Class I material at no additional cost. G. Undercut soils that become unsatisfactory by construction activity or by being left exposed to the weather and backfill with Class I material at no additional cost. H. Remove shoring, bracing, and sheeting, unless otherwise noted, as the trench is backfilled. Engineer shall have the authority to require that the sheeting be left in place. I. Excavation of trench shall not advance more than 200 feet ahead of the installation. In no case should the excavation extend beyond that which can be backfilled by the end of the workday. Trenching for Utilities 02315-6 3097-F: 04/30/15 J. Correct unstable soil conditions encountered at trench foundation by one of the following methods: 1. Excavate below grade as approved by Engineer and backfill with Class I material or approved substitute material at unit price as indicated in Section, Unit Prices. K. Rock and Hard Material 1. Excavate rock and hard material to a minimum depth of 4 inches below the pipe for pipes smaller than 30 inches and 6 inches for pipes 30 inches and larger. L. Gravity Lines: 1. Excavate trench to the alignment and grade indicated on the Drawings. M. Utility Structures: Provide a minimum of 12 inches below subgrade and backfill with Class I compacted to 95 percent maximum density. If the soil conditions are found to be unsuitable for structural stability of the manhole, Engineer may require additional depth of Class I material. 3.08 BACKFILLING A. Weather Limitations: Proceed with backfill operations based on the following weather conditions: 1. Temperature must be above freezing and rising. 2. In windy, hot, or and conditions with a high rate of evaporation add moisture to the material to maintain the optimum moisture content. 3. Do not proceed in rain or on saturated subgrade. 4. Do not place material on surfaces that are muddy, frozen, or contain frost. B. General 1. Maintain backfill operation within 200 feet from pipe laying operation. 2. Backfill trench to existing ground surface with select excavated material at the specified compaction. 3. If excavated material is unsuitable to obtain specified compaction, provide suitable off-site borrow material for backfill. 4. Re -excavate trenches improperly compacted. Backfill and compact as specified. 5. Provide appropriate tamping equipment, and water to obtain proper moisture content, to achieve specified compaction of backfill. 6. Conduct operation of heavy equipment above pipe installation as to prevent damage to pipe. 7. Install warning / identification tape over utilities. Bury tape one foot below finished grade above the utility. 8. Install tracer wire for non-metallic pressure pipe. Bury tracer wire with pipe. Wire shall be looped into valve boxes to allow access for direct contact location. C. Backfill in pipe embedment zone (bedding, haunching, and initial backfill). 1. General: a. Backfill with material as specified below. Material shall be free from objects larger than 2 inches. b. Where rock and hard material has been excavated below pipe bottom, backfill and compact bedding with Class I material. Class II or III material may be used for bedding with Engineer's approval. c. Place backfill material to assure placement of material under pipe haunches. 3097-F: 04/30/15 02315-7 Trenching for Utilities d. Take care during placement and compacting of material to avoid movement of pipe. 2. Place backfill in bedding and haunching zones in 6 inch maximum lifts and compact to 90 percent density. Place initial backfill in one lift do not compact. Provide backfill material in pipe embedment zone as specified below. a. Pressure Lines (Flexible and Rigid Pipe) 1) Excavation in Class I, Class II, and Class III soils suitable for bedding, the bedding surface shall provide a firm foundation of uniform density. Backfill with select excavated material. 2) Excavation in Class IV or Class V, running water, and other unstable soil conditions, excavate a minimum of 4 inches below pipe bottom and provide Class I material for bedding and haunch zone. Backfill with Class I, II, or III material in initial backfill. b. Gravity Sewer Lines, Rigid pipe (concrete and ductile iron) 1) Excavation in Class I, Class II, Class III, and stable Class IV soils suitable for bedding, the bedding surface shall provide a firm foundation of uniform density. Backfill with select excavated material. 2) Excavation in Class V, unstable Class IV soils, running water, and other unstable soil conditions, excavate a minimum of 4 inches below pipe bottom and provide Class I material for bedding and haunch zone. Backfill with Class I, 11, or III material in initial backfill. 3) Ductile Iron over 16 inch i) Depth 0 - 12 feet: Type 2 laying conditions same as for pressure pipe. ii) Depth over 12 feet: Provide Class I material for bedding and 4 inches up from bottom of pipe. c. Gravity Sewer Lines, Flexible (PVC SDR 26 and Schedule 40) 1) Depth 0 to 14 ft: Provide Class I material for bedding and haunching. Backfill with Class I, II, or III material in initial backfill. 2) Depth over 14 ft: Provide Class I material for bedding, haunching, and initial backfill. d. Gravity Sewer Lines, Semi-rigid pipe (PVC and ABS Truss Pipe) 1) Depth 0 to 14 ft: Provide Class I material for bedding and haunching. Backfill with Class I, 11, or III material in initial backfill. 2) Depth over 14 ft: Provide Class I material for bedding, haunching, and initial backfill. D. Final Backfill 1. Backfill with materials free of stones and free of debris larger than 6 inches in dimension. Place backfill in lifts not exceeding the thickness and compacted to the minimum density specified below. 2. Trench backfilled with noncohesive materials may be compacted with water flooding; except under roadways, shoulders of roadways, and other areas subject to vehicular movement, provided the method of compaction is approved by the Engineer and provides the degree of compaction required. 3. Lifts and density: a. Undeveloped areas (i.e., forests, fields, and, croplands): Trench may be filled with bulldozer blade provided material fall will not damage pipe. Mound soil over the trench area sufficiently to settle level over time. Degree of compaction shall be 85 percent. b. Lawns: Backfill in 12 -inch lifts and compact to 90 percent. Top 12 inches shall be free of material with a dimension over 2 inches. Trenching for Utilities 02315-8 3097-F: 04/30/15 c. Roads (including Rights-of-way) within 20 feet), and adjacent tc compact to 95 percent. d. Within 20 feet of foundations: percent. drives, parking areas (including areas existing utilities: Backfill in 6 inch lifts Backfill in 6 -inch lifts compacted to 95 E. Utility Structures: Bring backfill to grade in even lifts on all sides. Lift depths and compaction densities shall be as specified according to area of installation for pipe above. Backfill against cast -in-place concrete structure only after concrete has attained the specified 28 -day compressive strength. 3.09 SOIL TESTING A. Compaction tests may be made at the option of Engineer. An independent testing laboratory will perform tests. Owner will pay for cost of the initial tests. B. For each test that fails the compaction requirements, the testing firm at the direction of the Engineer shall make two additional tests. Contractor shall pay cost of additional tests made because of failure of compaction test. C. Correct deficiencies in compaction. 3.10 PAVEMENT PATCHING A. Repair damaged pavement structure. B. Cut existing pavement for utility installation in straight lines generally parallel to the utility. Properly dispose of removed pavement structure. C. Extend pavement patch 1 foot beyond each side of trench on firm subgrade. Slope new surface to drain. D. Asphalt Pavements: Replace asphalt pavement with a pavement structure no less than as detailed on the Drawings. For roadways under NC Division of Highways jurisdiction, pavement shall be replaced in accordance with the requirements of the encroachment agreement. E. Concrete Pavements: Replace concrete pavement with pavement structure equal to existing but no less than as detailed as Drawings. Concrete shall be minimum 3,000 psi. When existing concrete joint is within 5 feet of trench remove existing concrete to joint. Provide expansion joint at edge of existing concrete. Surface treatment shall match existing. F. Curbs, Gutters, and Sidewalks: Replace curbs and gutters, and sidewalks removed or damaged with similar sections to match the existing. Remove to nearest existing joint. G. Approval of Other Authorities: Pavements under the jurisdiction of the NC Division of Highways shall be subject to the approval of a representative of that Division. H. Raise existing and new manholes and valve boxes to finished pavement grade. Excavate around top of existing manhole and valve box as necessary. Remove existing top ring, and install new grade ring(s) as necessary. Install existing cover. Raise existing valve box. Provide concrete collar around manhole ring and valve box. I. Pavement patching shall include the cost to adjust existing and new manhole and valve boxes to finished pavement elevations. 3097-F: 04/30/15 02315-9 Trenching for Utilities 3.11 GRADING AND CLEAN-UP: A. Provide for testing and clean up as soon as practicable, so these operations do not lag far behind the pipe installation. Perform preliminary clean up and grading as soon as backfill is complete. B. Provide positive drainage of finished grade and drain away from structures. Finished grade shall be reasonably smooth, compacted, free from irregular surface changes and comparable to the adjacent existing ground surface. C. Seed disturbed areas in accordance with Section, Lawns and Grasses. D. Upon completion of backfilling, remove and properly dispose of excess material and waste. END OF SECTION Trenching for Utilities 02315-10 3097-F: 04/30/15 SECTION 02370 EROSION CONTROL PART GENERAL 1.01 SECTION INCLUDES A. Work shall include, but not be limited to, the following: 1. Erosion control at project site. 2. Erosion control at borrow and disposal areas as required by Contractor. Cost shall include erosion control permits as necessary for borrow and disposal areas. 3. Removal of surface debris. 4. Temporary and permanent ground cover. 5. Maintain and remove erosion control devices. 6. Self Inspection and Monitoring 1.02 RELATED SECTIONS A. The following Sections have work that is directly related to this Section. This does not relieve the Contractor of his responsibility of proper coordination of all the work: 1. Section 02920 Lawns and Grasses 1.03 REFERENCED STANDARDS A. "Erosion and Sediment Control Planning and Design Manual," issued by the N. C. Sedimentation Control Commission. 1.04 QUALITY ASSURANCE A. Conform to rules and regulations of the Erosion Control Laws of the State of North Carolina, specifically the Sedimentation Pollution Control Act of 1973 (G.S. 113A) as amended, and the local jurisdiction where the project is located. B. Post a copy of the approved erosion control permit, furnished by Owner, at the site prior to starting work. Maintain a copy of the approved erosion control plan at the site. C. Provide permanent ground cover as soon as possible, and no later than 15 working days after completion of work in a specific area. 1.05 WARRANTY A. Contractor is liable for damages to public and private property and fines as may be placed on the Project by the governing agencies due to failure to provide adequate erosion control devices. PART2 PRODUCTS 2.01 MATERIALS A. Matting / Erosion Control Fabric (ECF): Matting and ECF shall be a 70% straw and 30% coconut blanket encased in a medium weight plastic netting (both sides). Matting shall be fully degradable but suitable until vegetation has been established. Installation of ECF shall be done with staples per temporary liner detail in the 3097-F: 04/30/15 02370-1 Erosion Control construction drawings. Commercially available ECFs may be used upon approval of the engineer. Approval of fabrics will require manufacturer's design data regarding velocity, shear strength, ditch slopes, method of installation, decay cycle, repair techniques, and grass growth enhancement characteristics. B. Wire Staples: 16 gauge steel wire, with minimum of 3" top and 4" long legs. C. Gravel for Stone Filters: #57 crushed stone. D. Filter Fabric: 7-1/2 oz. burlap fabric or other silt filtering fabric. E. Riprap: 1. Class A: Stone shall conform to NCDOT standards and shall range in size from 2 to 6 -inches with the stone gradation being equally distributed within the required size range. 2. Class B: Stone shall conform to NCDOT standards and shall range in size from 5 to 12 -inches with the stone gradation being equally distributed within the required size range. 3. Type 1: Stone shall conform to NCDOT standards and shall range in size from 5 to 17 -inches with the stone gradation being equally distributed within the required size range. PART 3 EXECUTION 3.01 INSTALL EROSION CONTROL DEVICES A. Install erosion control devices, which shall be in place and operational prior to other land disturbing activity. B. After installing erosion control devices as indicated on the Drawings, verify that reasonable measures have been taken to prevent the sedimentation of nearby watercourses, existing and new facilities, and adjacent property. C. Should Contractor believe that additional measures are necessary to adequately prevent erosion, immediately notify Engineer. If rain is predicted before the Engineer can be notified, take measures as necessary to prevent siltation of nearby water courses and work will be paid for as provided in the General Conditions. D. After installing erosion control devices, request an inspection by the local agency having jurisdiction and the Engineer. E. Incorporate permanent erosion control work into the project at the earliest practicable time. Coordinate temporary erosion control measures with permanent erosion control measures and other work on the project to assure effective and continuous erosion control throughout the construction and post construction period. F. Maintain erosion control devices during construction until the disturbed areas are stabilized and the agency having jurisdiction and the Engineer have approved the removal of the erosion control devices. 3.02 BORROW AND DISPOSAL AREAS: A. Obtain and pay for erosion control permit for borrow and disposal areas as required by Contractor. B. Install and maintain erosion control devices in accordance with Contractor's approved plan. Erosion Control 02370-2 3097-F: 04/30/15 3.03 MAINTENANCE A. Inspect erosion control devices after each rainfall. Make required repairs immediately. Remove sediment deposits when deposits reach approximately one- half of the capacity of the erosion control device. B. Respread accumulated sediments on the project site in a manner that will not adversely affect erosion control facilities and permanent ground cover. C. Silt Fence: Should the filter fabric decompose or become ineffective before approval of its removal by the Engineer, replace fabric immediately at no additional cost to the Owner. D. Temporary Construction Entrance: Maintain entrance in a condition that will prevent tracking or flow of mud onto public rights-of-way. This may require periodic top dressing with 2 inches of stone, as conditions require, at no additional cost to the Owner. 3.04 SEEDING A. Disturbed areas not covered by new construction shall be seeded. B. Provide temporary and permanent seeding in accordance with Section, Lawns and Grasses. 3.05 STABILIZATION AND CLEAN-UP A. Remove erosion control devices upon the approval of the permanent stabilization of this site by the agency having jurisdiction of the area and the Engineer. Dress sediment deposits remaining in place after the erosion control devices are removed to conform to the existing grade, prepared and seeded. Include cost of removal and cleanup in the cost of the installation of the device. 3.06 SELF INSPECTION AND MONITORING A. Provide self -inspection and reporting as required by the Sedimentation Pollution Control Act for the duration of the project. These inspections will performed to ensure that the approved sedimentation and erosion control measures on the Drawings are installed, maintained, and working adequately. 1. The inspections need to be conducted after each phase of the project, and continue until permanent ground cover is established. 2. The self -inspection forms and information regarding this program are available at the following website: httl):Hportal.ncdenr.om/web/Ir/erosion 3. Documentation of inspections shall be recorded on a single copy of the approved erosion and sedimentation control drawings. These Drawings and inspection reports shall be made available at the project site. B. Provide weekly self-monitoring in accordance with the NPDES Stormwater permit for all construction activities. END OF SECTION 3097-F : 04/30/15 02370-3 Erosion Control SECTION 02445 BORE AND JACK OF CONDUITS PART GENERAL 1.01 SCOPE A. Provide, complete in place, carrier pipe installed within steel encasement pipe under highways as indicated on the Drawings. 1.02 RELATED SECTIONS A. The following Sections have work that is directly related to this Section. This does not relieve the Contractor of his responsibility of proper coordination of all the work: 1. Section 02315 Trenching for Utilities 2. Section 02530 Sanitary Sewer System 1.03 INDUSTRY REFERENCES A. The latest revision, at the time of bidding, of the publications listed below form a part of this specification. 1. Highway Crossing: Install pipe under highways in accordance with "Policies and Procedures for Accommodating Utilities on Highway Rights -of -Way," NC Department of Transportation, as a minimum. 1.04 SUBMITTALS A. Submit the following in accordance with Section, Submittal Procedures: 1. Affidavit of Compliance: Affidavit shall attest that supplied products conform to the referenced standard and this specification and that all tests set forth in each applicable referenced publication have been performed and that all test requirements have been met. Submit for each of the following materials: a. Encasement Pipe. 2. Catalog Data: Submit manufacturer's standard drawings or catalog cuts for the following. Clearly indicate equipment to be furnished for the Project including options to be provided. a. Pipe support. b. Casing seal. 1.05 QUALITY ASSURANCE A. Work covered in this Section of the specifications is within the right(s)-of-way of the following: 1. N.C. Department of Transportation (NCDOT) a. All Work in DavidsonCounty b. Division 9, District 1 c. Chris T. Corriher — District Engineer 4770 South Main Street Salisbury, NC 28147 Phone: 704-630-3200 B. Bear costs, including but not limited to, bonds, insurance, coordination, inspection fees, flagmen, permanent and temporary signage, etc. as required by the respective agency indicated above. Specific agency requirements are indicated in the Encroachment Agreement as attached to Section, Supplementary Conditions. 3097-F: 05/18/15 02445-1 Bore & Jack of Conduits C. Comply with requirements of the Encroachment Agreement(s). D. Prior to start of Work provide notifications as indicated in the Encroachment Agreement. E. Work shall conform to the requirements and be subject to the approval of the above agency. PART2 PRODUCTS 2.01 MATERIALS A. Encasement Pipe: Encasement pipe shall be uncoated, welded steel meeting ASTM A-139, Grade B, with minimum yield strength of 35,000 psi. Pipe length, and size shall be as indicated on the Drawings. The minimum wall thickness shall be as shown below. Encasement thickness shall be stenciled on exterior of pipe. 1. N.C. Department of Transportation Pipe Size (O.D.-inches) Wall Thickness (inches) 4-12-3/4 0.188 16-24 0.250 30 0.312 36 0.375 42 0.500 48 0.500 B. Carrier Pipe: Carrier pipe shall be of the type, size, and joints as indicated on the Drawings and specified in Section, Sanitary Sewer System. C. Pipe Support: Provide pipe supports designed and manufactured for the support of the carrier pipe size and material to be used for the Project within the encasement size indicated on the Drawings. Supports shall be designed to carry the pipe at the support spacing specified and meet the following minimum requirements: 1. Band Width: 8 inches for pipes 14 inches and under and 12 inches for pipes 16 inches and over. 2. Band and Riser Material: 14 gauge steel for band and riser except if the riser is over 6 inches high the steel shall be 10 gauge for riser. Riser shall be of the channel shape. Band with risers shall a fusion bonded PVC coating of a minimum of 10 -mil thickness. Band shall be bolted together with stainless steel bolts, nuts, and washers. 3. Band Liner: Provide PVC liner a minimum of 0.09 inches. 4. Runners: Glass Reinforced Polyester or UHMW Polymer plastic. Runner shall be a minimum of 1 inch wide and not more then 1 inch shorter than the bandwidth. Provide 2 top and 2 bottom runners for pipe sizes through 12 inches and 2 top and 4 bottom runners for pipes over 12 inches. 5. Pipe position within casing: Centered and Restrained. 6. Support Spacing: a. General: 1) Provide a support within one foot on each side of joints. Provide a support within one foot of each end of casing. Bore & Jack of Conduits 02445-2 3097-F: 05/18/15 2) Provide additional supports as needed per manufacturer's recommendations. b. PVC: Provide pipe supports at a maximum of 6 foot spacing along pipe in addition to the above requirement. 7. Supports shall be as manufactured by Advance Products & Systems, Inc., Pipeline Seal and Insulator, Inc or equal. D. Casing End Seal: Provide casing seal designed and manufactured for sealing around the casing and carrier pipe. The seal may be a wrap-around or a pull -on. Seal shall be made of 1/8 -inch thick synthetic rubber. Seal shall be secured with stainless steel banding straps with worm gear tightening device. PART 3 EXECUTION 3.01 GENERAL A. Verify the subsurface conditions at each boring site. Payment will not be made for encasement pipe installed but not usable. B. Stabilize and maintain bore pit bottom to provide proper equipment support and maintain pipe alignment. Dewater as necessary for site. Excavate bore pit in accordance with OSHA regulations. Provide adequate barricades, railings, and warning lights throughout the boring operation. Conduct operation in such a manner so as not to create a hazard to, nor impede the flow of traffic. C. Install encasement pipe by dry boring and jacking. D. Boring auger diameter shall not be greater than the outside diameter of the encasement pipe and shall not extend more than 6 -inches ahead of the cutting edge of the encasement pipe. Fill voids that are formed during the operation with a 1:3 portland cement grout pumped at 50 psi to ensure that there will be no settlement of the roadway. E. As the boring operation progresses, butt weld each new section of the encasement pipe to the section previously jacked into place. Maintain proper alignment. Confirm the grade of the encasement pipe as the Work progresses. F. If an obstruction is encountered during the boring operation, efforts should be made to remove the obstruction. If obstruction cannot be removed, withdraw the encasement pipe and fill the void with 1:3 portland cement grout at 50 psi. If the encasement pipe cannot be withdrawn, seal ends before moving to another bore site. Engineer shall approve location of new bore site. A maximum of two (2) attempts as described above as necessary, including additional bore pits, shall be made by the Contractor at the bid unit price. G. If, after the second attempt, it is found to be impossible to install the encasement pipe by boring due to rock or some other obstruction, a change order will be negotiated for placing the pipeline by appropriate method in accordance with the Contract Documents. H. Provide seals at each end of encasement pipe 3097-F : 05/18/15 02445-3 Bore & Jack of Conduits 3.02 CARRIER PIPE A. Install carrier pipe in Supports shall prevent supports as specified. the encasement pipe using manufactured pipe supports. movement of the carrier pipe within the encasement. Space END OF SECTION Bore & Jack of Conduits 02445-4 3097-F : 05/18/15 SECTION 02530 SANITARY SEWER SYSTEM PART GENERAL 1.01 SECTION INCLUDES A. Work under this section includes, but is not limited to, piping, valves, and appurtenances for a complete sanitary sewer collection system. 1.02 RELATED SECTIONS A. The following Sections have work that is directly related to this Section. This does not relieve the Contractor of his responsibility of proper coordination of all the work: 1. Section 02315 Trenching for Utilities 2. Section 02445 Bore & Jack of Conduits. 1.03 REFERENCES A. Publications are referred to in the text by basic designation only. 1. American Society for Testing and Materials (ASTM) a. A126 Gray iron Castings and Valves, Flanges and Pipe Fittings. b. C361 Reinforced Concrete Low -Head Pressure Pipe. c. C443 Flexible Watertight Joints for Precast Manhole Sections d. C478 Precast Reinforced Concrete Manhole Sections e. C890 Minimum Structural Design Loading for Monolithic or Sectional Precast Concrete Water and Wastewater Structures f. C923 Resilient Connectors Between Reinforced Concrete Manhole Structures, Pipes and Laterals g. C1244 Test Method for Concrete Sewer Manholes by the Negative Air Pressure h. D1248 Polyethylene Plastics Molding and Extrusion Materials i. D1784 Rigid Poly(Vinyl Chloride) (PVC) Compounds and Chlorinated Poly(Vinyl Chloride) (CPVC) Compounds j. D2241 Poly(Vinyl Chloride) (PVC) Pressure Rated Pipe (SDR Series) k. D 2321 Recommended Practice for Underground Installation of Flexible Thermoplastic Sewer Pipe I. D2680 Acrylonitrile -Butadiene -Styrene (ABS) and Poly(Vinyl Chloride) (PVC) Composite Sewer Pipe m. D3034 Type PSM Poly(Vinyl Chloride) (PVC) Sewer Pipe and Fittings n. D3139 Joints for Plastic Pressure Pipes Using Flexible Elastomeric Seals o. D3350 Polyethylene Plastics Pipe and Fittings Materials p. F477 Elastomeric Seals (Gaskets) for Joining Plastic Pipe q. F794 Poly(Vinyl Chloride) (PVC) Profile Gravity Sewer Pipe and Fittings Based on Controlled Inside Diameter r. F949 Poly(Vinyl Chloride) (PVC) Corrugated Sewer Pipe With a Smooth Interior and Fittings s. F894 Specification for Polyethylene (PE) Large Diameter Profile Wall Sewer and Drain Pipe t. F1483 Specification for Oriented Poly(Vinyl Chloride) PVCO, Pressure Pipe 3097-F: 04/30/15 02530-1 Sanitary Sewer System American Water Works Association (AWWA) a. C104 Cement -Mortar Lining for Ductile -Iron Pipe and Fittings for Water b. C105 Polyethylene Encasement for Ductile -Iron Piping for Water and Other Liquids c. C110 Ductile -Iron and Gray -Iron Fittings, 3 inch through 48 inch, for Water and Other Liquids d. C115 Flanged Ductile -Iron Pipe with Threaded Flanges e. C151 Ductile -Iron Pipe, Centrifugally Cast in Metal Molds or Sand -Lined Molds, for Water or Other Liquids f. C153 Ductile -Iron Compact Fittings, 3 inch through 16 inch, for Water and Other Liquids g. C504 Rubber -Seated Butterfly Valves h. C507 Ball Valves, 6 inch through 48 inch i. C508 Swing -Check Valves for Waterworks Service, 2 inch Through 24 inch NPS j. C509 Resilient -Seated Gate Valves for Water Supply Service k. C512 Air -Release, Air / Vacuum, and Combination Air Valves for Waterworks Service I. C550 Protective Epoxy Interior Coatings for Valves and Hydrants m. C600 Standard for Installation of Ductile Iron Water Mains and Their Appurtenances n. C605 Underground Installation of Polyvinyl Chloride (PVC) Pressure Pipe and Fittings for Water o. C900 Polyvinyl Chloride (PVC) Pressure Pipe and Fabricated Fittings, 4 inch through 12 inch, for Water Distribution p. C906 Polyethylene (PE) Pressure Pipe and Fittings 4 inch through 63 inch for Water Distribution q. C909 r. M23 PVC Pipe - Design Installation 3. National Sanitation Foundation (NSF) Standards a. 14 Plastic Piping Components and Related Materials 4. UNI -BELL Plastic Pipe Association (UNI) a. B-5 Recommended Practice for the Installation of Polyvinyl Chloride (PVC) Sewer Pipe b. B-6 Recommended Practice for Low -Pressure Air Testing of Installed Sewer Pipe 1.04 SUBMITTALS A. Submit the following in accordance with Section, Submittal Procedures: 1. Affidavit of Compliance: Affidavit shall attest that supplied products conform to the referenced standard and this specification and that tests set forth in each applicable referenced publication have been performed and that test requirements have been met. Submit for each of the following materials: a. Pipe 1) Ductile iron 2) Polyvinyl Chloride (PVC) gravity sewer pipe i) SDR 26 ii) Schedule 40 3) Cast iron soil pipe b. Pre -cast concrete manholes Sanitary Sewer System 02530-2 3097-F : 04/30/15 2. Catalog Data: Submit manufacturer's standard drawings or catalog cuts for the following. Clearly indicate equipment to be furnished for the Project including options to be provided. a. Pipe 1) Ductile iron 2) Ductile Iron with restrained joints 3) Polyvinyl Chloride (PVC) gravity sewer pipe I) SDR 26 ii) Schedule 40 4) Cast iron soil pipe b. Pre -cast Concrete Manholes and the following appurtenances: 1) Manhole steps 2) Pipe connectors 3) Joint material 4) Castings c. Service saddles 3. Reports: Field test report for each section of pipe for the following: 1) Pressure test for force mains. 2) Low-pressure air test for gravity mains. 3) Vacuum test for manholes. 1.05 DELIVERY, STORAGE, AND HANDLING A. Provide a suitable pipe hook or rope sling when handling the pipe with a crane. Lifting of the pipe shall be done in a vertical plane. Under no conditions shall the sling be allowed to pass through the pipe unless adequate measures are taken to prevent damage to both tongue and groove ends. B. Deliver pipe in the field as near as practicable to the place where it is to be installed. Distribute pipe along the side of the trench opposite to the spoil bank. Where necessary to move the pipe longitudinally along the trench, it shall be done in such a manner as not to injure the pipe or coating. C. Shield PVC pipe and fittings stored on site from the sun's ultraviolet rays by suitable cover, or indoor storage. PART2 PRODUCTS 2.01 DUCTILE -IRON PIPE A. Pipe and fittings shall conform to the following requirements: 1. Size shall be as indicated on the Drawings. 2. Suitable for a system working pressure of 350 psi. 3. Cement -mortar lined with seal coat in accordance with AWWA. B. Ductile -iron pipe for below ground service shall have push -on or mechanical joints, unless noted otherwise on the Drawings, conform to AWWA C151, and to the following requirements: 1. Pipe thickness class shall be suitable for a laying condition as specified in Section, Trenching for Utilities, at the depth indicated on the Drawings, and at the system working pressure specified above. 2. Provide mechanical joint fittings, unless noted otherwise on the Drawings. 3097-F: 04/30/15 02530-3 Sanitary Sewer System 2.02 3. Pipes to be painted shall have only a shop primer on the outside by the manufacturer. Verify that proposed manufacturer's primer is compatible with the proposed paint system. C. Fittings for ductile -iron pipe shall conform to AWWA C110, or C153 and to the following requirements: 1. Joint type shall be as specified above for the supplied ductile -iron pipe. 2. Fittings shall be made of gray -iron or ductile -iron. D. Special Pipe Joints 1. Restrained a. Provide restrained joint pipe at fittings and valves where indicated on the Drawings. Length of restrained pipe shall be as shown. Restrained joints shall be Snap -Lok (Griffin Pipe), Flex Ring and Lok -Ring (American), TR Flex (U.S. Pipe) or approved equal. b. Restrained joint pipe and fittings shall meet all AWWA standards and other requirements as specified above for standard ductile iron pipe and fittings unless addressed herein. c. Field made joints are allowable but should be avoided where possible. Careful planning to locate field cuts in standard pipe sections is preferred. For field made joints in restrained piping, use field weldments or an insert equal to TR Flex Gripper Rings or approved equal. Gasket type field made joints will not be allowed. d. Restrained joint fittings shall be provided by the restrained joint pipe supplier where located within restrained joint pipe sections. Fittings shall be of the same model / type as the pipe supplied from the pipe manufacturer. e. Restrained joint fittings may be push -on joint type. f. Megalugs, Series 1100, as manufactured by EBAA Iron Sales or approved equal shall be allowable for restraint where fittings or valves are not available with restrained joints from the pipe manufacturer. g. Where additional fittings/valves are required and not shown on Drawings, consult with Engineer for length of restrained joint pipe necessary each side of fittings/valve prior to installation of pipe/fitting. h. Contractor shall develop a field layout schedule and drawing for restrained joint pipe installations. POLYVINYL CHLORIDE (PVC) GRAVITY SEWER PIPE A. General 1. Pipe and fitting size shall be as indicated on the Drawings. 2. PVC materials shall comply with ASTM D1784 with a cell classification of 12454-B. 3. Pipe shall have an integral elastomeric-gasket bell end. Gaskets shall be in conformance with ASTM F477. 4. See Section, Trenching for Utilities, for trench bedding and haunching requirements. B. SDR 26: PVC SDR 26 gravity sewer pipe 4 -inch to 15 -inch and related fittings shall conform to ASTM D-3034 and the following requirements: 1. Pipe shall have standard dimension ratio of SDR 26. 2. Nominal pipe length shall be a minimum of 13 feet. Sanitary Sewer System 02530-4 3097-F: 04/30/15 2.03 CAST IRON SOIL PIPE A. General: Pipe and fitting size shall be as indicated on the Drawings. B. Cast iron soil pipe shall be service weight hub and spigot meeting Federal WW -401. C. The joints shall be rubber -type elastomeric as per ASTM C425. 2.04 MANHOLES A. Provide manholes made of precast concrete sections in conformance with ASTM C478, NC Department of Transportation, and the following requirements: 1. General a. Provide manholes to the depth as indicated on the Drawings. Manhole inside diameter shall be 4 feet unless noted otherwise on the Drawings. b. Precast concrete manholes shall be as manufactured by Adams Concrete, Carolina Precast Concrete, Inc., D & M Concrete Specialties, Inc., N. C. Products Corp., Stay Right Tank, Tindall Concrete Products, Inc. or approved substitute. 2. Precast Concrete Sections a. Minimum wall thickness shall be 5 -inches. b. Base: Cast monolithically without construction joints or with an approved PVC waterstop in the cold joint between the base slab and the walls. The width of the base extensions on Extended Base Manholes shall be no less than the base slab thickness. c. Riser: Minimum lay length of 16 inches. d. Eccentric Cone: Top inside diameter shall be 24 inches. Width of the top ledge shall be no less than the wall thickness required for the cone section. e. Transition Cone: Provide an eccentric transition from 60 -inch and larger manholes to 48 -inch diameter risers, cones, and flat slab top sections. Minimum slope angle for the cone wall shall be 45 degrees. f. Transition Top: Provide an eccentric transition from 60 -inch and larger manholes to 48 -inch diameter risers, cones, and flat slab top sections. Transition Top sections shall be furnished with vents as shown on the manhole details. Tops shall not be used in areas subject to vehicle traffic. g. Flat Slab Top: Designed for HS -20 traffic loadings as defined in ASTM C890. Items to be cast into Special Flat Slab Tops shall be sized to fit within the manhole ID and the top and bottom surfaces. Provide a float finish for exterior slab surface. h. Precast or core holes for pipe connections. Diameter of hole shall not exceed outside diameter of pipe by more than 3 -inches. i. Grade Rings: May be used to adjust frame and cover to finished grade. Grade Rings shall be no less than 4 inches in height. j. Lifting Devices: Devices for handling precast components shall be provided by the precast manufacturer and comply with OSHA Standard 1926.704. 3. Joints a. Manufacturer in accordance with tolerance requirements of ASTM C 990 for butyl type joints. b. Minimize number of joints. Do not use riser section for manholes up to 6 feet tall and no more than one riser for each additional 4 feet in height. c. Flexible Joint Sealants: Preformed butyl rubber based sealant material conforming to Federal Specification SS -S -210A, Type B and ASTM C990. 3097-F: 04/30/15 02530-5 Sanitary Sewer System d. External Seal: Polyethylene backed flat butyl rubber sheet no less than 1/16 -inch thick and 6 -inches wide. 4. Inverts a. Brick and mortar or precast concrete invert. b. Form and finish invert channel to provide a consistent slope from inlet(s) to outlet up to 4 -inches. c. Channel walls shall be formed to 3/4 of the height of the outlet pipe diameter. d. Finish benches with a minimum uniform 1.5:12 slope. Provide a 1/4 -inch radius at the edge of bench and trough. 5. Flexible Pipe Connectors: Provide flexible connectors for pipe to manhole that conform to ASTM C923. Location of connectors shall vary from Project Drawings no more than 1/2 -inch vertically and 5 degrees horizontally. Provide stainless steel pipe clamp type band around flexible connection to sewer pipe. 6. Manhole Steps: a. Steps shall be in accordance with ASTM C478 and made of 1/2 -inch grade 60 steel encapsulated by co -polymer polypropylene and have serrated tread and tall end lugs. b. Secure steps to the wall with compression fit in tapered holes or cast -in- place. Align steps along a vertical wall and shall not be located over a pipe opening. First step shall be a maximum of 26 inches from the bottom. c. Steps shall be by American Step Co., Inc., Bowco Industries, Inc., M. A. Industries, Inc. or approved substitute. 2.05 CASTINGS A. General 1. Made of gray iron, ASTM A-48 - class 30, or ductile iron, ASTM A536, grade 65-45-12. 2. Castings shall be free from imperfections not true to pattern. Casting tolerances shall be plus or minus 1/16 -inch per foot of dimension. Top shall set neatly in frame, with edges machined for even bearing and proper fit to prevent rattling and flush with the edge of frame. 3. Castings shall be as manufactured by Neenah Foundry Co., U.S. Foundry & Manufacturing Corp., or Vulcan Foundry B. Manhole Frame and Cover: 1. Minimum clear opening shall be 22 inches. 2. Minimum weight for frame and cover shall be 300 pounds and suitable for Heavy Duty Highway Traffic Loads of H-20. 3. Frame shall have four 3/8 -inch anchor bolt holes equally spaced. 4. Cast "Sanitary Sewer" on the cover. Casting shall bear the name of the manufacturer and the part number. 5. Provide cover with two 1 -inch perforated holes unless noted as watertight on the Drawings. 6. Provide the following where indicated on the Drawings: a. Ring and cover shall be watertight. b. Bolt down cover. Bolt down covers shall be provided with four (4) 3/8 -inch stainless steel hex head bolts at 90 degrees. Sanitary Sewer System 02530-6 3097-F: 04/30/15 2.06 SEWER SERVICE A. Provide PVC service wye the same material as the main. Saddles shall be solvent welded and fastened with double stainless steel bands. B. Inserta Tee or approved equal shall be used for connection to PVC ribbed pipe C. Service saddle for cast iron soil pipe services may be "ROMAC C" sewer saddles consisting of a virgin SBR gasket compounded for sewer service, a ductile iron saddle casting, a 304 stainless steel adjustable strap for fastening the gasket and the saddle casting to the sewer main, and a 304 stainless steel adjustable circle clamp for securing the service line into the SBR gasket. PART 3 EXECUTION 3.01 GENERAL 3.02 A. Pipe installation shall meet the following general guidelines: 1. Lay pipe in the presence of Engineer, unless specifically approved otherwise. 2. Handle pipe and accessories in accordance with manufacturer's recommendations. Take particular care not to damage pipe coatings. 3. Carefully inspect pipe immediately prior to laying. Do not use defective pipe. Replace pipe damaged during construction. 4. Lay pipe to grade and alignment indicated on the Drawings. 5. Provide proper equipment for lowering pipe into trench. 6. Provide tight closure pipe ends when work is not in progress. 7. Keep pipe interior free of foreign materials. 8. Do not lay pipe in water or when the trench or weather conditions are unsuitable for the work. 9. Clean bell and spigots before joining. Make joints and lubricate gasket in accordance with pipe manufacturer recommendation. 10. Block fittings with concrete, or restrained as indicated on the Drawings or as required to prevent movement. B. Gravity Pipe: Gravity pipe installation shall meet the following general guidelines: 1. Lay pipe upgrade from the lower end and at the grades and alignment indicated on the Drawings. RELATION OF WATER MAINS TO SEWERS A. Lateral Separation: Lay water mains at least 10 feet laterally from existing and proposed sewers. Where existing conditions prevent a 10 -foot lateral separation, the following shall be followed with approval of the Engineer: 1. Lay water main in a separate trench, with the elevation of the bottom of the water main at least 18 inches above the top of the sewer. 2. Lay water main in the same trench as the sewer with the water main located at one side on a bench of undisturbed earth, and with the elevation of the bottom of the water main at least 18 inches above the top of the sewer. B. Crossing Separation: Lay bottom of water main at least 18 inches above the top of the sewer. Where existing conditions prevent an 18 -inch vertical separation, construct both the water main and sewer of ferrous materials and with joints that are equivalent to water main standards for a distance of 10 feet on each side of the point of crossing. 3097-F: 04/30/15 02530-7 Sanitary Sewer System C. Crossing a Water Main Under a Sewer: When it is necessary for a water main to cross under a sewer, construct both the water main and the sewer of ferrous materials and with joints equivalent to water main standards for a distance of 10 feet on each side of the point of crossing. A section of water main pipe shall be centered at the point of crossing. 3.03 SEWER PIPE A. Lay sewer pipe to true lines and grades by use of laser beam equipment or other acceptable means. B. Minimum Separation Distances: 1. 100 -foot horizontal separation from wells or other water supplies. 2. 24 -inch vertical separation from storm sewers or ferrous pipe shall be used. 3. For separation from water mains see paragraph 3.02 above. 3.04 DUCTILE IRON PIPE A. Install pipe in conformance with AWWA C600 and the following: 1. For laying pipe in a vertical or horizontal curve, each full length pipe may be deflected by the following offset distance: a. Push -on joint 1) 3 to 12 -inch pipe: 14 -inch offset 2) 14 to 36 -inch pipe: 8 -inch offset b. Mechanical joint 1) 3 to 6 -inch pipe: 20 -inch offset 2) 8 to 12 -inch pipe: 15 -inch offset 3) 14 to 20 -inch pipe: 8 -inch offset 4) 24 to 36 -inch pipe: 6 -inch offset 3.05 MANHOLES A. Set base plumb and level. Align manhole invert with pipe invert. B. Secure pipe connectors to pipe in accordance with manufacturer's recommendation. C. Clean bells and spigots of foreign material that may prevent sealing. Unroll the butyl sealant rope directly against base of spigot. Do not stretch. Follow manufacturer's instructions when using O-ring seals. D. Set precast components so that steps align. E. Plug lift holes using a non -shrink grout. Cover with a butyl sealant sheet on the outside and seal on the inside with an application of an epoxy gel 1/8 -inch thick extending 2 inches beyond the opening. F. Set manhole frames to grade with grade rings. Seal joints between cone, adjusting rings, and manhole frame with butyl sealant rope and sheet. G. Apply external seal to the outside of joint. H. Finish the interior by filling fractures greater than 1/2 -inch in length, width or depth with a sand cement mortar. I. Clean the interior of the manhole of foreign matter. 3.06 SEWER CLEANOUTS A. Sewer cleanouts connected to ductile iron pipe shall also be ductile iron sewer pipe conforming to these specifications. Sanitary Sewer System 02530-8 3097-F: 04/30/15 B. Sewer cleanouts connected to PVC pipe shall also be PVC sewer pipe schedule 40 conforming to ASTM -D-3034 latest revision. Use elastomeric gaskets for pipe joints. C. Service wyes shall be used on new PVC pipe. Service saddles shall be used on existing PVC, solvent welded to the main and fastened with double stainless steel bands. D. Cleanouts shall be a minimum of 4 -inch diameter unless noted otherwise on the Drawings. Provide sewer cleanouts with screw-in watertight brass cap. Installation shall be in accordance with the details as shown on the Drawings. 3.07 SERVICE CONNECTIONS A. Make service connections in accordance with the standard detail on the Drawings. B. Service connections to the main lines shall be perpendicular to the main line to the edge of the right-of-way or easement line. C. Four -inch lines shall have a minimum slope of 1.0 % and have cleanouts every 75 feet at a minimum in addition to a cleanout at the right-of-way line or at the edge of the easement. D. Six-inch lines shall have a minimum slope of 0.60 % and have cleanouts every 100 feet at a minimum in addition to a cleanout at the right-of-way line or at the edge of the easement. E. 6 -inch service lines shall tie directly into a manhole. F. Service lines, which are connected into manholes, shall be installed less than 2.5 feet above the invert or shall be installed as a standard drop. G. Service connections made using a "ROMAC C" sewer saddle shall be made only when the service line is cast iron soil pipe and when the sewer main is 8-, 10-, or 12 -inch diameter concrete, ductile iron, or PVC sewer pipe. This type connection cannot be used on truss sewer pipe. The opening in the sewer main for the "ROMAC C" sewer saddle shall be cut with a hydraulically driven or pneumatically driven circular tapping saw of the same nominal diameter as the sewer service line. 3.08 PAINTING A. Equipment shall receive the manufacturer's standard coating for the intended application. Coatings shall be suitable for the intended application. B. Repaint damaged paint services. C. Above ground piping and piping within vaults shall be painted in accordance with Section, Painting. 3.09 TESTING A. General 1. Clean and flush pipe system of foreign matter prior to testing. 2. Notify Owner and Engineer a minimum of 48 hours prior to testing. 3. Perform tests in the presence of Engineer. 4. Length of line to be tested at one time shall be subject to approval of Engineer. 5. Pipe sections shall not be accepted and placed into service until specified test limits have been met. 6. Repair defects in the pipe system. Make repairs to the same standard as specified for the pipe system. 3097-F: 04/30/15 02530-9 Sanitary Sewer System 7. Retest repaired sections until acceptance. 8. Repair visible leaks regardless of the test results. B. Gravity Sewer Mains 1. Test gravity lines between manholes. 2. Light Testing: Engineer will check for displacement of pipe as follows: a. Alight will be flashed between the ends of the pipe section being tested. b. If the illuminated interior shows misalignment, or other defects as designated by Engineer, defects shall be repaired. 3. General a. Infiltration shall not exceed 100 gallons per inch of diameter, per mile of pipe, per 24 hours. Engineer may require flow measurement for verification of infiltration. b. Verify that maximum infiltration rate shall not be surpassed by air testing as follows. 4. Low Pressure Air Test: a. Air testing of sewer mains shall conform to UNI -B-6 and the following requirements: b. Perform initial air test when each section of main is complete including services to right of way. Test as construction proceeds. c. Wet interior surfaces of porous pipe material prior to testing. d. Safety 1) Provide a superintendent who has experience in low pressure air testing of gravity sewer mains. 2) Follow safety recommendations of air testing equipment manufacturer. 3) Properly brace sewer plugs during testing. Test plugs prior to use in air testing. 4) No one shall be allowed in manhole or trench when pipe is under pressure. 5) Pressurizing equipment shall include a regulator and a pressure relief valve, which are set no higher than 9 psig. Monitor gauges continuously to assure that the pressure does not exceed 9 psig. e. Equipment 1) Sewer plugs shall be specifically designed for low pressure air testing. 2) Use two separate air hoses. i) One to connect the control panel to the sealed line for introducing the air. ii) One from the sealed line to the control panel to provide constant monitoring of the air pressure in the line. iii) If Pneumatic plugs are used a separate line shall be used to inflate the plugs. 3) As a minimum the above ground air testing equipment shall include a shutoff valve, pressure regulating valve, pressure relief valve, input pressure gauge, and a continuous monitoring pressure gauge having a pressure range from 0 to at least 10 psig. 4) Continuous monitoring pressure gauge shall be at least 4 inches in diameter with minimum divisions of 0.10 psi and an accuracy of +/ 0.04 psi. 5) Monitoring gauges shall be subject to calibration as deemed necessary. Sanitary Sewer System 02530-10 3097-F: 04/30/15 6) Air used for testing shall pass through a single above ground control panel. f. Testing 1) Groundwater Determination: Immediately prior to each air test, determine groundwater level by a method acceptable to the Engineer. Adjust pressure used in air test in accordance with groundwater level. 2) Apply air slowly to the test section until the pressure reached is 4.0 psi plus an adjustment of 0.433 psi for each foot of ground water above the crown of the pipe. Internal air pressure, including adjustment for ground water, should never exceed 9.0 psi. 3) When the above required pressure is reached, throttle air supply to maintain internal pressure for at least two minutes to permit stabilization. 4) When pressure has stabilized at required pressure, shut off air supply. 5) While observing the continuous monitoring pressure gauge, decrease pressure approximately 0.5 psi from required pressure. 6) At this reading timing shall commence with a stop watch and allowed to run until pressure has dropped 1.0 psi or allowable time has lapsed. Line shall be "Acceptable" if the pressure drop does not exceed 1 psig in the time prescribed for the test in Table 1, Low Pressure Air Testing for Gravity Sewer Mains, at the end of this section. 5. Deflection Test for SDR 26 PVC pipe. a. Measure for deflection of pipe no sooner than thirty days after installation and backfill. b. Deflection shall not exceed 5 percent of pipe diameter. Maximum allowable long term deflection shall be 5 percent. c. Measure deflection with an approved "GO -NO-GO GAUGE" method or by an approved recording deflectometer. Verify gauge on site prior to testing. C. Vacuum test each manhole in accordance with ASTM C1244 and the following: 1. No personnel shall be allowed in manhole during testing. 2. Test manhole after assembly and prior to backfilling. 3. Plug pipes with suitably sized and rated pneumatic or mechanical pipeline plugs. Brace plugs to prevent displacement. 4. Position vacuum test head assembly to seal against interior surface of the top of cone section in accordance with manufacturer's recommendation. 5. Draw vacuum of 10 inches of mercury on manhole. Shut off the vacuum pump and close valve on vacuum line. 6. Measure time for vacuum to drop to 9 inches of mercury. Manhole shall pass if time meets or exceeds the following: Manhole I.D. (inches) 48 60 72 84 96 120 Seconds 60 75 90 105 120 150 7. If manhole fails test, remove head assembly, coat interior with a soap and water solution, and repeat vacuum test for approximately 30 seconds. Leaking areas will have soapy bubbles. Make necessary repairs to the satisfaction of Engineer and repeat test until manhole passes. END OF SECTION 3097-F: 04/30/15 02530-11 Sanitary Sewer System 0 Z_ F Z W Q F- 0: 0: a w a a0w LL u) (n } w F W � a O C7 J IL O Of 0 W of W aQ 90 aF) O Z rw CL CL LL g LL x0 Q 2 � F Q Z (K J OQ 0 ZQ Of W 5 N 0U) w of O W LL F- Z E m t � T N � w 'p U U U N LO � rn O C O N 0 ro u C 7 O N N E (D-0 a C C m a) 0 m N 0-0 l0 E N a (0 O Oa LO Fuo cy O m o C O N N N N m O_ N E 7 ca E N X N i— E O @ O N E i N Z � �-0 E a) O 7 w 6 N a) w V NN 7 CO V CO MOV V MOj M V r LO '7 O M6 00 LO MM 0(p LO M 0 r r LO N Or� V L O W 1, O r N (0 O r Cl) N w 0 N 0 0 V co 0 V CD N N N O O V V 0 6 N(pNrLOn O (;y �O OLO rr NLO NM 0(00) Or r r V n r O N C w 0 O N r (0 01 N IR O 00 W LO M d' N NOLO W O (O LO coco MIO 00 MOO r r CO V 7 CO C- C' r J 0 0 CO IN 00 V N _ N 04 N N7 ( LO r 0 s c"" C O V U M (000(p MO J j O co MLO r r f� r N N CO CO N LO co 0 0 00 O N r M r n ipOc °> E E w (OO(OM {�Mf�O h N 7 r ... O MLO O O M N F LOO M 0� O V N N M (0 N6 O N C N r N Cl) 7 LO 1� M r r O 'IT � M O V It m V .— Q o N ri LLi - of r r L� r ((i N v M (ri d' r� LO f` (o 00 lr� 0oV000MOr N rN (0 LO OD M V V( M N LO Mton@`- V M (O NM 7 cM 7 C7 LO V CO 0OMON-O V O r-- CD CD ';TV V M N LOO LO M O r r V r I: r Q) r N N W N LO Cl) M V LO 7 r J J J J J J J J J J J J J �O N G7 c 0 O V N�� N M O n V n (O O 0 CO N In 0 0 E O N rn MOLOMVMOV co OO CO co M 0 C� FJJ�"� rN MLO hr O M 1� r LO O N N M -C E N M CSO Ew M0) W M 0) LOO CO 0 W co O OO N 0 O M N N r r r r I'- 0 E V It N�OLL07 V N O N E E M V V ((N O07 C_ F. C M L O f O O64 N N N co co (D r E" V (O W r Or N M aoT N N co M E m t � T N � w 'p U U U N LO � rn O C O N 0 ro u C 7 O N N E (D-0 a C C m a) 0 m N 0-0 l0 E N a (0 O Oa LO Fuo cy O m o C O N N N N m O_ N E 7 ca E N X N i— E O @ O N E i N Z � �-0 E a) O 7 w 6 N a) SECTION 02920 LAWNS AND GRASSES PART GENERAL 1.01 SECTION INCLUDES A. Work shall include, but not be limited to, the following: 1. Surface preparation of subsoil. 2. Addition of lime and fertilizer. 3. Seeding. 4. Maintenance to produce a permanent stand of grass. 1.02 REFERENCES A. N.C. Department of Agriculture - NCDA B. U.S. Department of Agriculture - USDA 1.03 PERFORMANCE REQUIREMENT A. Grassed area shall be considered established when it presents a green appearance from eye level 50 feet away and the grass is vigorous and growing well in each square foot of seeded area. It is not required that the seeded area be thick and heavy as an old established lawn. B. Should the permanent seed not germinate and produce a strand of grass, reseed affected areas until a permanent stand is established. 1.04 QUALITY ASSURANCE A. Quality of fertilizer, lime, and seed, and operations in connection with the furnishing of this material, shall comply with the requirements of the N.C. Fertilizer, Lime and Seed Law; and with the requirements of the rules and, regulations adopted by the NC Department of Agriculture in accordance with the provisions of the said law. B. Seed containers shall bear an official "Certified Seed" label as inspected by the N.C. Crop Improvement Association. C. Packages for soil conditioners and fertilizer shall bear manufacturer's guaranteed analysis. D. Do not apply lime, fertilizer or seed in strong wind, when the soil is extremely wet, or otherwise unworkable. No rolling shall be done if precipitation after seeding would make the operation detrimental to the seed bed. 1.05 DELIVERY, STORAGE, AND PROTECTION A. Deliver grass seed mixture in sealed containers showing percentage of seed mix, year of production, net production, net weight, date of packaging, and location of packaging. B. Deliver fertilizer in waterproof bags showing weight, chemical analysis, and name of manufacturer. 1.06 MAINTENANCE SERVICE A. Water areas seeded between May 1 and July 15 at such intervals as to maintain the seeded area in a moist condition until the grass is established and accepted by the 3097-F: 04/30/15 02920-1 Lawns & Grasses Engineer. Provide equipment to transport and distribute the water to the seeded areas. Areas seeded between September 1 and November 1 need not be irrigated beyond the initial watering water at his own discretion. PART2 PRODUCTS 2.01 MATERIALS specified above except that the Contractor may apply A. Topsoil: Fertile, agricultural soil, typical for locality, capable of sustaining vigorous plant growth, taken from drained site; free of subsoil, clay or impurities, plants, weeds, and roots; pH value of minimum 5.4 and maximum of 7.0. B. Lime: Ground Dolomitic agricultural limestone, not less than 85 percent total carbonates, ground so that 50 percent passes 100 mesh sieve and 90 percent passes 30 mesh sieve. Coarser material will be acceptable, provided the specified rates of application are increased proportionately on the basis of quantities passing No. 100 mesh sieve. C. Fertilizer: Mixed, commercial, fertilizer containing 10-10-10 percentages of available nitrogen, phosphoric acid, and potash respectively, plus superphosphate with 20 percent P2O5 content. Fertilizer shall be dry, in granular (pellet) form, shall be delivered to the site in the manufacturer's original bag or container which shall be plainly marked as to formula. D. Seed: Fresh seed guaranteed 95 percent pure with a minimum germination rate of 85 percent within one year of tests. Provide the following seed mixtures with lime and fertilizer in disturbed areas including NCDOT Rights -of -Way: Planting Dates Grass Type Pounds/Acre Year Round Pensacola Bahia 50 KY 31 Tall Fescue 50 Centipede 5 Lime 4,000 Fertilizer 10-20-20 500 Mulch Straw 4,000 On 2:1 slopes delete Centipede and add 25 pounds / acre of Sericea Lespedeza. E. Matting / Erosion Control Fabric (ECF): Matting and ECF shall be a 70% straw and 30% coconut blanket encased in a medium weight plastic netting (both sides). Matting shall be fully degradable but suitable until vegetation has been established. Installation of ECF shall be done with staples per temporary liner detail in the construction drawings. Commercially available ECFs may be used upon approval of the engineer. Approval of fabrics will require manufacturer's design data regarding velocity, shear strength, ditch slopes, method of installation, decay cycle, repair techniques, and grass growth enhancement characteristics. F. Wire Staples: 16 gauge steel wire, with minimum of 3" top and 4" long legs. G. Mulch: Threshed straw of oats, wheat, or rye; free from seed of obnoxious weeds; or clean salt hay. Straw which is fresh and excessively brittle or straw which is in such Lawns & Grasses 02920-2 3097-F: 04/30/15 an advanced stage of decomposition as to smother or retard growth of grass will not be acceptable. H. Water: Water shall be free from substances harmful to growth of grass. PART 3 EXECUTION 3.01 PREPARATION OF SUBSOIL A. Complete operations in the area to be seeded and prepare subsoil to eliminate uneven areas and low spots. Bring surface to the approximate design contours. B. Scarify subsoil to a depth of 3 inches. Remove weeds, roots, stones and foreign materials 1-1/2 inches in diameter and larger. 3.02 APPLICATION OF LIME A. Liming shall be done immediately after grading has reached the fine grading stage, even though actual seeding may not be done until several months later. B. Spread lime evenly by means of a mechanical distributor. C. When lime is distributed by commercial liming dealers, sales slips showing the tonnage delivered shall be filed with the Engineer and shall show the full tonnage required for the acres treated. D. Incorporate lime in the top 2 to 3 inches of soil by harrowing, disking, or other approved means. 3.03 APPLICATION OF FERTILIZER A. Spread fertilizer not more than 2 weeks in advance of seeding. B. To verify application rate, determine acreage to be fertilized and provide Engineer with total weight of fertilizer applied to the area. C. Provide mechanical spreader for even distribution and spread half of the rate in one direction, and the other half at right angles to the first. Mix thoroughly into upper 2 to 3 inches of soil by disking, harrowing or other approved methods. 3.04 SEEDING A. Accomplish seeding by means of an approved power -drawn seed drill, combination corrugated roller -seeder, approved hand operated mechanical seeder, or other approved methods to provide even distribution of seed. B. Do not seed when ground is excessively wet or excessively dry. After seeding, roll area with a roller, not less than 18 inches in diameter and weighing not more than 210 pounds per foot of width. Upon completion of rolling, water area with a fine spray. C. Immediately following seeding apply mulch or matting. Do not seed areas in excess of that which can be mulched on same day. D. Apply water with a fine spray immediately after each area has been mulched. Saturate to 4 inches of soil depth 3.05 MULCHING AND MATTING A. Apply mulch or matting as required to retain soil and grass, but no less then the following: 3097-F: 04/30/15 02920-3 Lawns & Grasses 1. Slopes from 0 to 20 percent by spreading a light cover of mulch over seeded area at the rate of not less than 85 lbs. per 1000 sq. ft. 2. Slopes greater than 20 percent mulch with matting. Pin matting to the ground with wire staples at 5 foot intervals, immediately after seeding. 3. Use tack to prevent disruption of mulch. B. For tack use an asphalt tie -down of emulsified asphalt grade AE -3 or cut-back asphalt grade RC -2 or other approved equal. The application rate shall be 0.10 gal/sy (11 gal / 1000 sq ft). An approved jute mesh or net may be used in lieu of tacking straw mulch. C. Other types of mulch and anchoring methods may be used upon approval by the Engineer. 3.06 PROTECTION A. Protect seeded areas from damage by barricades, signs, and other appropriate means. Maintain and protect slopes from weather damage. END OF SECTION Lawns & Grasses 02920-4 3097-F : 04/30/15